HomeMy WebLinkAbout4.606 Original Contract
r/
<I. ~OU;
CONTRACT
For Creation of Public Art Work
International Gateway Welcome Mural
THIS CONTRACT is made and entered into by and between the CITY OF PORT
ANGELES, Washington, a municipal corporation (hereinafter referred to as "CITY") and
JACKSON SMART, an individual having his principal place of business at 472 Mt. Pleasant Rd,
Port Angeles, Washington 98362 (hereinafter referred to as "ARTIST").
1. PURPOSE
This Contract states the terms and conditions under which ARTIST shall design, fabricate
and install an art project called "International Gateway Welcome Sign"
2. DESCRIPTION OF SERVICES
ARTIST's services hereunder shall include, but shall not be limited to, the following:
a. DESCRIPTION OF ARTWORK. The ARTIST will create, install and document
the following work of art, hereinafter referred to as the "Artwork."
TITLE: (WORKING TITLE) "International Gateway Welcome Sign"
DIMENSIONS: Approx. 10' x 16'
MEDIA: Aluminum panels
DESCRIPTION OF ARTWORK: A Welcome to Port Angeles mural. Hand
painted on 4- 4'x8' panels with a 2'x16' header. A freestanding baked enamel metal information
sign with pedestal
PERMANENT LOCATION. The permanent location for the Artwork shall be:
101 E. Railroad Avenue, Port Angeles, W A 98362. See Attachment "A"
b. ARTIST shall work closely and cooperate with the CITY in order to fulfill the
purposes of this Contract. The Artist shall create the Artwork in accordance with the proposed
design, as approved by the CITY. Any change in scope, design, or material that significantly
alters the original and approved concept and design of the artwork or affects installation,
scheduling, site preparation, or maintenance for the Artwork shall require prior review and
written approval by City. Final approval of the design shall be at the sole discretion of the City
and shall be communicated by City to Artist in writing as specified in Section 14.
c. DOCUMENT A TION AND RECORDS. Upon installation of the Artwork, and
before final payment shall be made, the Artist shall furnish the City, a final report, and a
completed Documentation Worksheet including: a) four good quality images (slides or jpegs),
two each of two views of the Artwork, b) two black and white glossy photographs of the
Artwork at least 4 x 6 inches capable of reproduction for print media, c) a written technical
description of the Artwork, d) written maintenance instructions for the work, and e) a record of
- 1 -
all persons furnishing labor and material for the work, and lien waivers from any persons
furnishing labor and material for the work, and lien waivers from any persons furnishing labor
and/or materials incorporated into the Artwork, for review and approval. As an expressed
condition of this Contract, ARTIST shall design and install the ARTWORK so that it can be
utilized for display and also provide photographs, models, drawings or other representation of
the Artwork suitable for promotional purposes. ARTIST shall, without additional compensation,
correct or revise any errors, omissions, or other deficiencies in the ARTIST'S performance.
d. ARTIST shall be responsible for any damage to the ARTWORK that may occur
due to fire, explosion, theft, vandalism, flood, power failure, transit or any other cause until
ARTWORK has been delivered to and accepted by the CITY.
3. PERFORMANCE OF SERVICES
ARTIST and its employees, associates or assistants shall perform all the services under
this Contract in a timely, cost effective manner.
4. DATE FOR COMPLETION
This Contract shall be completed 6 months from the date of execution. ARTIST
understands and agrees that time is of the essence. All services are to be completed and
delivered to CITY by the date for completion unless an extension of time, based upon good
reasons presented by ARTIST, is approved in writing by CITY.
5. PAYMENT FOR SERVICES
In consideration of the professional services to be performed by ARTIST under the terms
of this Contract, CITY shall pay ARTIST for services actually performed a fee not to exceed
$11,175.00 which shall constitute full compensation from the City to the Artist for all costs
incurred in the creation of the Artwork, including, but not limited to fees, materials, labor of the
Artist and the Artist's assistants, studio and operating costs applicable to this project, travel costs
for the Artist to visit and research the Site, transportation of the Artwork to the Site, and any
costs incurred by the Artist for installation of the Artwork at the Site. All services shall be
performed to the reasonable satisfaction of CITY, and CITY shall not be liable for any payment
under this Contract for services which are unsatisfactory and which have not been approved by
CITY. The City shall have the sole responsibility for determining when the Artwork has reached
completion.
Payments shall be made as follows:
a. Upon approval of written design concept, securing relevant permits,
site placement approval along with purchase orders for all materials
and services. 50%;
b. Upon determining a 60% completion by artist 30%;
c. Upon installation, and acceptance by CITY: Remaining 20%.
- 2 -
Acceptance of the project as complete shall be at the sole discretion of the City and shall
be communicated in writing as set forth in Section 14.
6. INSTALLATION
The ARTIST will coordinate all Site preparation, installation plans, and timetables with
the City Engineer.
7. WARRANTIES
ARTIST warrants that: (a) the ARTWORK being commissioned is the original product
of ARTIST's own creative efforts and is not the subject of an existing patent or copyright owned
by any other person; and (b) unless otherwise stipulated, the ARTWORK is original, that it is an
edition of one (1), and ARTIST shall not sell or reproduce the ARTWORK or design or allow
others to do so without the prior written consent of CITY. The original design remains in the
public domain for all to use in promotion and commerce. (the subject of the mural is a loose
rendition ofthe art from the original plat map of Port Angeles dated June 10, 1890. It is stored in
the Library of Congress in Washington D.C. and is public domain)
ARTIST warrants that the execution and fabrication of the ARTWORK will be
performed in a professional manner and that the ARTWORK, as fabricated and installed, will be
free of defects in material and workmanship, including any defects consisting of "inherent vice"
or qualities which cause or accelerate deterioration of the ARTWORK. The ARTIST shall
guarantee and maintain the ARTWORK from faults of material and workmanship for a period of
one year after the acceptance date.
The warranties stated in this paragraph shall survive the termination of this Contract.
8. MAINTENANCE/CONSERVATION
Upon completion and installation of the ARTWORK, ARTIST shall prepare and submit
to CITY a written recommendation for maintenance of the ARTWORK, describing materials,
procedures, and frequency. Repairs, restoration and/or conservation shall be the responsibility of
CITY. CITY will make every effort to consult with ARTIST prior to performing maintenance or
making repairs, however CITY reserves the right to perform maintenance or make repairs
without consulting ARTIST. .-
9. THE FINISHED ARTWORK
ARTIST's final design and all other work product (including the final ARTWORK itself)
under this Contract shall become the property of the CITY, without restriction on future use,
except as provided below. By execution of this Contract, and at no additional charge to CITY,
ARTIST grants to the CITY a perpetual, irrevocable right to graphically depict, copy, reproduce,
use and display the final ARTWORK for any non-commercial purpose whatsoever; for purposes
of this limitation, any graphic depiction, copy, reproduction, use or display of the final
ARTWORK intended to promote or benefit the CITY, its public services or its public purposes,
- 3 -
regardless of whether or not a fee is charged to the public, or whether revenue is otherwise
received by the CITY, shall be deemed a non-commercial purpose. Notwithstanding the above
limitation, ARTIST agrees and understands that nothing in this paragraph shall affect or limit the
CITY's absolute, unrestricted rights incidental to the CITY's full ownership of the final
ARTWORK to alter, use, reproduce, copy, change, modify, destroy, remove, move, replace,
operate, maintain, transport, sell or transfer, in whole or in part, the final ARTWORK when the
CITY deems it necessary within its discretion, in order to otherwise exercise the CITY's powers
and responsibility in regard to public works and improvements, in furtherance of the CITY's
operations or for any other reason.
ARTIST hereby acknowledges the rights of integrity and attribution conferred by Section
106A (a), paragraphs (2) and (3) of Title 17 of the U.S. Code, and any other rights of the same
nature granted by federal, state or intemationallaws, and of his own free will hereby waives such
rights with respect to the City of Port Angeles' usage or use of the ARTWORK including but not
limited to the right to maintain, remove or destroy the ARTWORK. Provided that these
expressed conditions are (a) reported to, (b) coordinated with, (c) and allowed by the property
owner BlackBall Transport Inc. whose property the mural is installed upon.
10. INDEMNITY
ARTIST agrees to defend, indemnify and hold CITY, its officers, agents and employees,
harmless against any and all claims, lawsuits, judgments, costs and expenses for: (a) any
infringement of patent or copyright arising out of the services performed by ARTIST under this
Contract regardless of whether or not ARTIST or CITY had knowledge of any existing patents
or copyrights during the com;se of performance of this Contact; and (b) personal injury
(including death), property damage or other harm for which recovery of damages is sought,
suffered by any person or persons, that may arise out of or be occasioned by ARTIST's breach of
any of the terms or provisions of this Contract, or by any negligent act or omission of ARTIST,
its officers, agents, associates, employees or subconsultants, in the performance of this Contract.
The indemnity for personal injury, property damage or other harm caused by ARTIST's
contractual breach or negligence provided in (b) shall not apply to any liability resulting from the
sole negligence of CITY, its officers, agents, employees or separate contractors, and in the event
of joint and concurrent negligence of both the ARTIST and CITY, responsibilities and
indemnity, if any, shall be apportioned comparatively in accordance with the laws of the State of
Washington without waiving any defenses of the parties under Washington law.
11. NONDISCRIMINATION
As a condition of this Contract, ARTIST covenants that ARTIST will take all necessary
actions to insure that, in connection with any work under this Contract, ARTIST, his associates
and subcontractors, will not discriminate in the treatment or employment of any individual or
groups of individuals on the grounds of race, color, religion, national origin, age, sex or handicap
unrelated to job performance either directly, indirectly or through contractual or other
arrangements. In this regard, ARTIST shall keep, retain and safeguard all records relating to this
Contract or work performed hereunder for a minimum period of three (3) years from final
Contract completion, with full access allowed to authorized representatives of the City of Port
- 4 -
Angeles, upon request, for purposes of evaluating compliance with this and other provisions of
the Contract.
12. CONTRACT PERSONAL
This Contract provides for personal/professional services, involving the skill and
creativity of ARTIST. Therefore, the ARTIST shall not assign this Contract, in whole or in part,
without the prior written consent of CITY.
13. TERMINATION
CITY may terminate this Contract, in whole or in part, for cause or the convenience of
CITY, upon ten (10) days written notice to ARTIST with the understanding that all services
being performed under this Contract shall cease upon the date specified in such notice. Upon
notice of termination, ARTIST shall promptly discontinue all services affected (unless otherwise
directed by the notice) and promptly deliver to CITY all data, drawings, specifications,
calculations, reports, estimates, materials and completed or partially completed work produced
by ARTIST under this Contract. ARTIST shall invoice CITY for all services completed and
shall be compensated for all services performed prior to the date of the notice to terminate.
14. NOTICES
All notices, communications, and reports required or permitted under this Contract shall
be personally delivered or mailed to the respective parties by depositing same in the United
States mail, postage prepaid, at the addresses shown below, unless and until either party is
otherwise notified in writing by'the other party, at the following addresses. Mailed notices shall
be deemed communicated as of five (5) days after mailing.
If intended for CITY, to:
City of Port Angeles
Attention: Richard Bonine
Recreation Division
P.O. Box 1150 \ 321 E. Fifth Street
Port Angeles, Washington 98362-0217
If intended for ARTIST, to:
Jackson Smart
472 Mt. Pleasant Rd.
Port Angeles, Washington 98362
15. INDEPENDENT CONTRACTOR
In performing services under this Contract, the relationship between CITY and ARTIST
is that of independent contractor, and CITY and ARTIST by the execution of this Contract do
- 5 -
not change the independent status of ARTIST, ARTIST shall exercise independent judgment in
performing his duties under this Contract and is solely responsible for setting working hours,
scheduling or prioritizing the work flow and determining how the work is to be performed. No
term or provision of this Contract or act of ARTIST in the performance of this Contract shall be
construed as making ARTIST the agent, servant or employee of CITY, or making ARTIST or
any of his employees eligible for the fringe benefits, such as retirement, insurance and worker's
compensation, which CITY provides its employees.
16. GOVERNING LAW AND VENUE
This Contract shall be governed by and construed in accordance with the provisions of
the ordinances of the City and with the laws of the State of Washington, and applicable federal
law. If legal action is necessary to enforce same, exclusive jurisdiction and venue shall lie in the
Superior Court of Clallam County, Washington.
17. ENTIRE AGREEMENT
The Contract embodies the complete agreement of the parties hereto, superseding all oral
or written previous and contemporary agreements between the parties and relating to matters in
this Contract, and except and otherwise provided herein cannot be modified without written
agreement of the parties to be attached to and made a part of this Contract.
EXECUTED this I~L day of "j:-I)~., 2009 by the CITY and by ARTIST.
CITY OF PORT ANGELES
ARTIST
By LJ -. a .c~~-
Title: MA..." D ~ ~
BY:~~
Attest:
Ap~ oved as to form:
~J
___ i ^__
e, "i ,~
Senior Assistant City Attorney
G \Legal_ Backup\AGREEMENTS&CClN fRACTS\2009 Agrmts&Contracts\InternatlOnalMural-JacksonSmart Art-on-the- Town 012309 doc
\,
- 6 -
'-
,
,
Kiosk Sign
_t1I!er
Telephone 25"x11 "x84"
23"x11 "x41"
I
I
I
il ~come Sign
I
J
Coho
Parking
Coho Ferry
Office Bldg
Interpretive sign
30"x18"x36"
!
Laurel Street
(jl:pfq At>~
14-' " -z,.SI
IY50 cP .~ -ZOdJo :::. 370
~ tit A<<.ot.Ve'O il'kll.::/ ~ (2~ 4t
::u
t\)
-.
-
-,
o
m
0-
~
CD
fhls design is the sole property of 8' ,
Jacke;on's Signs and may not be I
used Without permission.
^ ^"cY^'^ '^ 'T "W ~~~';':'
412 mount~Ple(Js(Jn~~Ilc:t ' '"
^ ' ^ f ,> '" (w<~ ~> ",.' -\ "- d~-').;: >" ,
'";5~!?,;~~t~ t\n8eI~s:,"w()~'~,a36Z
,',,,;'>~y;,:;;;a:::~.........-J' .~ e::::=::..--;;?:2:.~ :2:.
'<;~!i5~ -~-~/'"~
</. (I) {) t.p
.
CONTRACT
For Creation of Public Art Work
Waterfront Interpretive Signs
THIS CONTRACT is made and entered into by and between the CITY OF PORT
ANGELES, Washington, a municipal corporation (hereinafter referred to as "CITY") and
JACKSON SMART, an individual having his principal place of business at 472 Mt. Pleasant Rd,
Port Angeles, Washington 98362 (hereinafter referred to as "ARTIST").
1. PURPOSE
This Contract states the terms and conditions under which ARTIST shall design, fabricate
and install an art project called "Waterfront Interpretive Signs"
2. DESCRIPTION OF SERVICES
ARTIST's services hereunder shall include, but shall not be limited to, the following:
a. DESCRIPTION OF ARTWORK. The ARTIST will create, install and document
the following work of art, hereinafter referred to as the "Artwork."
TITLE: (WORKING TITLE) "Waterfront Interpretive Signs"
DIMENSIONS: Approx. 18" x 30"
MEDIA: Baked enamel metal signs with freestanding pedestals
DESCRIPTION OF ARTWORK: 6 (six) 18" x 30" Baked enamel signs with metal
freestanding pedestals. Anchored in the wood or concrete pad.
PERMANENT LOCATION. The permanent location for the Artwork shall be: 6 (six)
signs. 3 located on the City pier, 1 sign located on North side of Railroad Ave, 2 signs at the Port
Angeles Estuary. See Attachment "A"
b. ARTIST shall work closely and cooperate with the CITY in order to fulfill the
purposes of this Contract. The Artist shall create the Artwork in accordance with the proposed
design, as approved by the CITY. Any change in scope, design, or material that significantly
alters the original and approved concept and design of the artwork or affects installation,
scheduling, site preparation, or maintenance for the Artwork shall require prior review and
written approval by City. Final approval of the design shall be at the sole discretion of the City
and shall be communicated by City to Artist in writing as specified in Section 14.
c. DOCUMENT A TION AND RECORDS. Upon installation of the Artwork, and
before final payment shall be made, the Artist shall furnish the City, a final report, and a
completed Documentation Worksheet including: a) four good quality images (slides or jpegs),
two each of two views of the Artwork, b) two black and white glossy photographs of the
Artwork at least 4 x 6 inches capable of reproduction for print media, c) a written technical
description of the Artwork, d) written maintenance instructions for the work, and e) a record of
1
..
all persons furnishing labor and material for the work, and lien waivers from any persons
furnishing labor and material for the work, and lien waivers from any persons furnishing labor
and/or materials incorporated into the Artwork, for review and approval. As an expressed
condition of this Contract, ARTIST shall design and install the ARTWORK so that it can be
utilized for display and also provide photographs, models, drawings or other representation of
the Artwork suitable for promotional purposes. ARTIST shall, without additional compensation,
correct or revise any errors, omissions, or other deficiencies in the ARTIST'S performance.
d. ARTIST shall be responsible for any damage to the ARTWORK that may occur
due to fire, explosion, theft, vandalism, flood, power failure, transit or any other cause until
ARTWORK has been delivered to and accepted by the CITY.
3. PERFORMANCE OF SERVICES
ARTIST and its employees, associates or assistants shall perform all the services under
this Contract in a timely, cost effective manner.
4. DATE FOR COMPLETION
This Contract shall be completed 6 months from the date of execution. ARTIST
understands and agrees that time is of the essence. All services are to be completed and
delivered to CITY by the date for completion unless an extension of time, based upon good
reasons presented by ARTIST, is approved in writing by CITY.
5. PAYMENT FOR SERVICES
In consideration of the professional services to be performed by ARTIST under the terms
of this Contract, CITY shall pay ARTIST for services actually performed a fee not to exceed
$18,000.00 which shall constitute full compensation from the City to the Artist for all costs
incurred in the creation of the Artwork, including, but not limited to fees, materials, labor of the
Artist and the Artist's assistants, studio and operating costs applicable to this project, travel costs
for the Artist to visit and research the Site, transportation of the Artwork to the Site, and any
costs incurred by the Artist for installation of the Artwork at the Site. All services shall be
performed to the reasonable satisfaction of CITY, and CITY shall not be liable for any payment
under this Contract for services which are unsatisfactory and which have not been approved by
CITY. The City shall have the sole responsibility for determining when the Artwork has reached
completion.
Payments shall be made as follows:
a. Upon approval of written design concept, securing relevant permits, site
placement approval along with purchase orders for all materials and
services: 50%
b. Upon receiving notification to pick-up finished panels from the
manufacturer and all mounting hardware and concrete pads: 30%
c. Upon installation, and acceptance by CITY: Remaining 20%
2
..
Acceptance of the project as complete shall be at the sole discretion of the City and shall
be communicated in writing as set forth in Section 14.
6. INSTALLATION
The ARTIST will coordinate all Site preparation, installation plans, and timetables with
the City Engineer.
7. WARRANTIES
ARTIST warrants that: (a) the ARTWORK being commissioned is the original product
of ARTIST's own creative efforts and is not the subject of an existing patent or copyright owned
by any other person; and (b) unless otherwise stipulated, the ARTWORK is original, that it is an
edition of one (1), and ARTIST shall not sell or reproduce the ARTWORK or design or allow
others to do so without the prior written consent of CITY.
ARTIST warrants that the execution and fabrication of the ARTWORK will be
performed in a professional manner and that the ARTWORK, as fabricated and installed, will be
free of defects in material and workmanship, including any defects consisting of "inherent vice"
or qualities which cause or accelerate deterioration of the ARTWORK. The ARTIST shall
guarantee and maintain the ARTWORK from faults of material and workmanship for a period of
one year after the acceptance date.
The warranties stated in this paragraph shall survive the termination of this Contract.
8. MAINTENANCE/CONSERVATION
Upon completion and installation of the ARTWORK, ARTIST shall prepare and submit
to CITY a written recommendation for maintenance of the ARTWORK, describing materials,
procedures, and frequency. Repairs, restoration and/or conservation shall be the responsibility of
CITY. CITY will make every effort to consult with ARTIST prior to performing maintenance or
making repairs, however CITY reserves the right to perform maintenance or make repairs
without consulting ARTIST.
9. THE FINISHED ARTWORK
ARTIST's final design and all other work product (including the final ARTWORK itself)
under this Contract shall become the property of the CITY, without restriction on future use,
except as provided below. By execution of this Contract, and at no additional charge to CITY,
ARTIST grants to the CITY a perpetual, irrevocable right to graphically depict, copy, reproduce,
use and display the final ARTWORK for any non-commercial purpose whatsoever; for purposes
of this limitation, any graphic depiction, copy, reproduction, use or display of the final
ARTWORK intended to promote or benefit the CITY, its public services or its public purposes,
regardless of whether or not a fee is charged to the public, or whether revenue is otherwise
received by the CITY, shall be deemed a non-commercial purpose. Notwithstanding the above
3
,.
limitation, ARTIST agrees and understands that nothing in this paragraph shall affect or limit the
CITY's absolute, unrestricted rights incidental to the CITY's full ownership of the final
ARTWORK to alter, use, reproduce, copy, change, modify, destroy, remove, move, replace,
operate, maintain, transport, sell or transfer, in whole or in part, the final ARTWORK when the
CITY deems it necessary within its discretion, in order to otherwise exercise the CITY's powers
and responsibility in regard to public works and improvements, in furtherance of the CITY's
operations or for any other reason.
ARTIST hereby acknowledges the rights of integrity and attribution conferred by Section
106A (a), paragraphs (2) and (3) of Title 17 of the U.S. Code, and any other rights of the same
nature granted by federal, state or intemationallaws, and of his own free will hereby waives such
rights with respect to the City of Port Angeles' usage or use of the ARTWORK including but not
limited to the right to maintain, remove or destroy the ARTWORK.
10. INDEMNITY
ARTIST agrees to defend, indemnify and hold CITY, its officers, agents and employees,
harmless against any and all claims, lawsuits, judgments, costs and expenses for: (a) any
infringement of patent or copyright arising out of the services performed by ARTIST under this
Contract regardless of whether or not ARTIST or CITY had knowledge of any existing patents
or copyrights during the course of performance of this Contact; and (b) personal injury
(including death), property damage or other harm for' which recovery of damages is sought,
suffered by any person or persons, that may arise out of or be occasioned by ARTIST's breach of
any of the terms or provisions of this Contract, or by any negligent act or omission of ARTIST,
its officers, agents, associates, employees or subconsultants, in the performance of this Contract.
The indemnity for personal injury, property damage or other harm caused by ARTIST's
contractual breach or negligence provided in (b) shall not apply to any liability resulting from the
sole negligence of CITY, its officers, agents, employees or separate contractors, and in the event
of joint and concurrent negligence of both the ARTIST and CITY, responsibilities and
indemnity, if any, shall be apportioned comparatively in accordance with the laws of the State of
Washington without waiving any defenses of the parties under Washington law.
11. NONDISCRIMINATION
As a condition of this Contract, ARTIST covenants that ARTIST will take all necessary
actions to insure that, in connection with any work under this Contract, ARTIST, his associates
and subcontractors, will not discriminate in the treatment or employment of any individual or
groups of individuals on the grounds of race, color, religion, national origin, age, sex or handicap
unrelated to job performance either directly, indirectly or through contractual or other
arrangements. In this regard, ARTIST shall keep, retain and safeguard all records relating to this
Contract or work performed hereunder for a minimum period of three (3) years from final
Contract completion, with full access allowed to authorized representatives of the City of Port
Angeles, upon request, for purposes of evaluating compliance with this and other provisions of
the Contract.
4
~
12. CONTRACT PERSONAL
This Contract provides for personal/professional services, involving the skill and
creativity of ARTIST. Therefore, the ARTIST shall not assign this Contract, in whole or in part,
without the prior written consent of CITY.
13. TERMINATION
CITY may terminate this Contract, in whole or in part, for cause or the convenience of
CITY, upon ten (10) days written notice to ARTIST with the understanding that all services
being performed under this Contract shall cease upon the date specified in such notice. Upon
notice of termination, ARTIST shall promptly discontinue all services affected (unless otherwise
directed by the notice) and promptly deliver to CITY all data, drawings, specifications,
calculations, reports, estimates, materials and completed or partially completed work produced
by ARTIST under this Contract. ARTIST shall invoice CITY for all services completed and
materials purchased and shall be compensated for all services performed and for all materials
purchased for this project for which Artist is legally obligated to pay prior to the date of the
notice to terminate.
14. NOTICES
All notices, communications, and reports required 9r permitted under this Contract shall
be personally delivered or mailed to the respective parties by depositing same in the United
States mail, postage prepaid, at the addresses shown below, unless and until either party is
otherwise notified in writing by the other party, at the following addresses. Mailed notices shall
be deemed communicated as of five (5) days after mailing.
If intended for CITY, to:
City of Port Angeles
Attention: Richard Bonine
Recreation Division
P.O. Box 1150 \ 321 E. Fifth Street
Port Angeles, Washington 98362-0217
If intended for ARTIST, to:
Jackson Smart
472 Mt. Pleasant Rd.
Port Angeles, Washington 98362
15. INDEPENDENT CONTRACTOR
In performing services under this Contract, the relationship between CITY and ARTIST
is that of independent contractor, and CITY and ARTIST by the execution of this Contract do
not change the independent status of ARTIST, ARTIST shall exercise independent judgment in
5
,.
performing his duties under this Contract and is solely responsible for setting working hours,
scheduling or prioritizing the work flow and determining how the work is to be performed. No
term or provision of this Contract or act of ARTIST in the performance of this Contract shall be
construed as making ARTIST the agent, servant or employee of CITY, or making ARTIST or
any of his employees eligible for the fringe benefits, such as retirement, insurance and worker's
compensation, which CITY provides its employees.
16. GOVERNING LAW AND VENUE
This Contract shall be governed by and construed in accordance with the provisions of
the ordinances of the City and with the laws of the State of Washington, and applicable federal
law. If legal action is necessary to enforce same, exclusive jurisdiction and venue shall lie in the
Superior Court ofClallam County, Washington.
17. ENTIRE AGREEMENT
The Contract embodies the complete agreement of the parties hereto, superseding all oral
or written previous and contemporary agreements between the parties and relating to matters in
this Contract, and except and otherwise provided herein cannot be modified without written
agreement of the parties to be attached to and made a part of this Contract.
EXECUTED this &4.. day of \~...~~. ,2009 by the CITY and by ARTIST.
CITY OF PORT ANGELES
ARTIST
By: ~~.
Title: ~"Of(
... . c._____
By:
~~
Attest:
6o~~ .1lptDA
Becky J. U n, . y Clerk
~APprove~rm: ,
I _~,
_is C.. icksofi
Senior A:sStSta..-1{City Attorney
G \Legal_Backup\AGREEMENT~&CONTRACTS\2009 Agrmts&Contracts\Waterfront-JacksonSmart Art-on-the-Town 012309 doc
6
~;':2' J", ='::~
~.
-
-~.~ ~
,~~';~' .=.. ~' 'P' ~
::: ~'1!'}-. -~~ -E=
-~~~:7'::;~fl 1,4 ~ ,'<<;. ,>-p. ,~, /,J ...... -r
( ,,--" ) c..... :.- ,." r , ~ _"-("jo ';-'/, W .&-..
1.~>~~~ ~ ~"~'-~ #E:;~ <t~ ~~~'~ 4~~ ....'~
~r:-~-~~: ~.:;':t'? \::
1~. j ~'~b -~ · '""
-.;~=.:;:- -. %::.. ~ -"",_.' t :,~
---- '--~ ----' '" '''' ...,- -/~.......,..__!, 1 ,,,~;,,.L
Oll~,?~a.~~l,
~,
--.
X
....,.
--;
~ -l!~ f:~' ~
~-,.". \ ,i~. 'J:,c. ,j,
,; 1"'- _ ')4:~
--C ~.~. '>'L ,.[ 1'"
;,....").,~ , ~.i t..
Downtown Port Angeles
Interpretive SIgns
r
,:l:"\\
)\ \ f .A
'~~f~"
~C~'%j,;. 7,', .1
1:::.1 .:::..
,/Jff/T
-----
/ 4~~~@?g~?,gJf
" ~~~I~I~1t~.
;//t,
The U S. Coast Guard Group - Port Angeles
~---~-~-~ ,_..
'-"'-_.~----"- -,
"._~.., ~.._ __v.........
_"_'~_M..,.."'.".
~~
;
fi
.'
41'1 mount Pledsdnt Ud.
Port ftngeles. Wd 98361
c360-4:5;Z6,7C)c3
''- ',.-, - -~.... ._~:- ,
, '.' ~ ;;:}, '~4
_ ,'. _.' C ~~. __""~. .. _
. -~..._---- - .::---~--,-
- ,-......--_.-
:;..7"_~~~..ft:.::_..;::.:..~,..:;~
~~"'---~...-~,-
.,.. _"", _,~_w_~,...._. ......_n
.~-''''''~''''''''''''''-''-~ > -'-"
ft__......."-~.,._"_
. /'
,,",~y~/
,
---------~
4%/
~-;.-'
/>