Loading...
HomeMy WebLinkAbout001101 Original Contract City of Port Angeles Record # 001101 GRANT PROGRAM AGREEMENT BETWEEN City of Port Angeles and Goochy Investments, LLC This Agreement is made between the City of Port Angeles (hereinafter referred to as the "City") and Goochy Investments, LLC (hereinafter collectively called the Grantee) for the fagade improvement project described in this document and its attachments (herein called the Project). WHEREAS, the City allocated Community Development Block Grant (CDBG) program income to a fagade improvement and rehabilitation grant program, which is CDBG-eligible activity; and WHEREAS, the City has awarded a grant to reimburse a part of the costs of fagade improvements for the property located at 824 "C" Street, Port Angeles; Parcel Number 063000025880; and WHEREAS, the Grantee has agreed to perform the work to improve the facade of the above described property; NOW, THEREFORE, the City and Grantee do mutually agree to the following terms and conditions regarding the above mentioned property to be improved using City funds through the Facade Grant Program: 1. SCOPE OF SERVICES The Grantee will complete in a satisfactory and proper manner as determined by the City the work described in the Project Overview that is attached hereto, marked as Attachment A, and incorporated herein by reference. A listing of detailed project tasks is marked as Attachment B, and incorporated herein by reference. 2. GRANTEE'S OBLIGATIONS The Grantee warrants that they are the owner of the above property or has written permission from the Owner of the property to perform the proposed improvements described in Attachment B. The effective date of this agreement will be the date the parties sign. Grantee agrees to complete 'i work described in the attached Plans and Specifications within ONE HUNDRED EIGHTY (180 ) days after the effective date. In the event the Director of Community and Economic Development finds that the Grantee has prosecuted the work with reasonable diligence but, due to factors beyond its reasonable control, the Grantee is unable to complete the work within 180 days, the City Manager is authorized to extend the time to complete the work. All fagade improvements shall be consistent with sign zoning and building codes currently in effect for the City. The Grantee shall assure that any permit or review necessary under City Ordinance shall be approved before the work on the fagade improvement begins. - 1 - The Grantee shall be responsible for the construction and management of the entire project. If the faqade improvements are maintained for at least five years, the Grantee is not obligated to repay any part of the grant to the CITY. If the faqade improvements are not maintained for at least five years, the Grantee shall immediately repay to the CITY the amount of the grant, less 20% of the amount for each year the faqade improvements were maintained. 3. BUDGET The City will reimburse to the Grantee the amount of 50% or $10,000, whichever is less, for eligible incurred costs and expenses for the Project according to the budget shown on the Attachment B. Only the work that is outlined in Attachments A & B will be eligible for reimbursement. It is understood that this agreement is funded with CDBG program income funds. The Grantee acknowledges and agrees that the funds must be used only for CDBG-eligible expenditures. 4. PAYMENT Disbursement of funds shall be made only after the Project is complete and certified by City staff to be in compliance with the approved design. The work must also adhere to any required inspections before funds are disbursed for reimbursement. All documentation for payment must be provided at one time to.the City for one payout, and the receipts must be provided no later than six (6) months after the application has been approved or as stipulated in the request for an extension. Payment will be made to the Grantee by the City within four weeks after City deems all Project costs and documentation to be complete. Payment shall be made only to the Grantee. The Grantee's submission must include itemized invoices detailing the work completed and materials purchased, with proof that payments in full have been made to Contractors and vendors, if applicable. Grantee acknowledges, and agrees to inform its Contractor, that the City has no obligation to pay the Contractor for work performed for the Grantee under this Program. This agreement shall not be construed or deemed to be an agreement for the benefit of any third party or parties, and no third party shall have any claim or right of action hereunder for any cause whatsoever. Unless otherwise agreed to in writing by both parties, the Grantee's total reimbursement under this agreement, including labor and materials, shall not exceed the maximum sum of$10,000.00. The budget for labor and materials is found in Attachment B. Budgets for each line item may be modified upon mutual agreement between the two parties, but in any event, the total payment to Grantee shall not exceed $10,000.00. 5. GENERAL CONDITIONS A. General Compliance. The Grantee agrees to comply with all applicable Federal, state and local laws, regulations, and policies, governing the funds provided under this agreement. - 2 - B. Independent Contractor. Nothing contained in this agreement is intended to, or will be construed in any manner, as creating or establishing the relationship of employer/employee between the parties. The Grantee will at all times remain an "independent contractor" with respect to the services to be performed under this agreement. The City will be exempt from payment of all Unemployment Compensation, FICA, retirement, life and/or medical insurance and Workers' Compensation Insurance, as the Grantee is an independent contractor. C. Hold Harmless. The Grantee will hold harmless, defend and indemnify the City from any and all claims, actions, suits, charges and judgments whatsoever that arise out of the Grantee's performance or nonperformance of the services or subject matter called for in this agreement. D. Workers' Compensation. The Grantee will provide Workers' Compensation Insurance Coverage for all of its employees involved in the performance of this agreement. E. Contract with Contractor. Each contractor who is performing the work approved for this Project shall have a valid State of Washington Contractor's License. F. Labor Code/Prevailing Wage. Grantee acknowledges and agrees that the Grantee's improvements to be constructed with the proceeds of the grant constitute construction, alteration, demolition, installation, or repair work done under contract and paid for in whole or in part out of public funds. Grantee shall comply with all requirements of applicable federal, state and local laws and regulations pertaining to labor standards and payment of prevailing wages (collectively, "Prevailing Wage Laws"). Grantee shall (i) require its contractors and subcontractors to submit certified copies of payroll records to Grantee; (ii) maintain complete copies of such certified payroll records; and (iii) make such records available to City and its designees for inspection and copying during regular business hours. Grantee shall defend, indemnify and hold harmless the City and its officers, employees, volunteers, agents and representatives from and against any and all present and future claims, arising out of or in any way connected with Grantee's obligation to comply with all Prevailing Wage Laws, including all claims that may be made by contractors, subcontractors or other third party claimants. G. Funding Source Recognition., The Grantee will insure recognition of the roles of the City in providing services through this agreement. H. Suspension or Termination. The City may suspend or terminate this agreement if the Grantee materially fails to comply with any terms of this agreement, which include (but are not limited to) the following: • Failure to comply with any of the rules, regulations or provisions referred to herein, or such statutes, regulations, guidelines, policies or directives as may become applicable at any time; • Failure, for any reason, of the Grantee to fulfill in a timely and proper manner its obligations under this Agreement; or • Submission by the Grantee to the City of reports that are incorrect or incomplete in any material respect. - 3 - 6. ADMINISTRATIVE REQUIREMENTS A. Financial Management Accounting Standards. The Grantee agrees to adhere to the accounting principles and procedures required therein, utilize adequate internal controls, and maintain necessary source documentation for all costs incurred. B. Documentation and Record Keeping. The Grantee will maintain thorough records pertinent to the activities to be funded under this agreement, including records adequate to document that the funds were expended on CDBG-eligible activities. C. Access to Records and Retention. All such records and all other records pertinent to the work undertaken under this agreement will be retained by the Grantee for a period of six years after the City's final audit of Project, unless a longer period is required to resolve audit findings or litigation. In such cases, the City will request a longer period of record retention. D. Audits and Inspections. All Grantee records with respect to any matters covered by this Agreement will be made available to the City and duly authorized officials of the state and federal government, at any time during normal business hours, as often as deemed necessary, to audit, examine, and make excerpts or transcripts of all relevant data. Any deficiencies noted in audit reports must be fully cleared by the Grantee within 30 days after receipt by the Grantee. Failure of the Grantee to comply with the above audit requirements will constitute a violation of this agreement and may result in the withholding of future payments. E. Reporting. The Grantee, at such times and in such forms as the City may require, will furnish the City such periodic reports as it may request pertaining to the work or services undertaken pursuant to this agreement, the costs and obligations incurred or to be incurred in connection therewith, and any other matters covered by this agreement. 7. PERFORMANCE WAITER The City's failure to act with respect to a breach by the Grantee does not waive its right to act with respect to subsequent or similar breaches. The failure of the City to exercise or enforce any right or provision will not constitute a waiver of such right or provision. 8. ENTIRE AGREEMENT This document states the entire agreement between the City and the Grantee for the use of funds received under this agreement and it supersedes all prior communications and proposals, whether electronic, oral, or written between the City and the Grantee with respect to this agreement. IN WITNESS WHEREOF, the City and the Grantee have executed this agreement as of the date and year last written below. CITY F PORT ANGELES GRANTEE: Goochy Investments, LLC By: By: f�Ak Title: 4°1�3 a Title: (` ._ hQ Ct j a er u Date: Date: M([2 - 4 - Approv as to form: William E. Bloor, City Attorney Attachments: A—Project Overview B —Scope of Work and Budget Application ATTACHMENT A - PROJECT OVERVIEW Grantee: Goochy Investments, LLC Grant No. 16-06 Section A: Brief Description Funds will enable new awnings, exterior lights and repainted facade. Goals/Expected Results/Products: Replace new awnings, add four lights to the Budget front fagade, and repaint facade. Category 21AGeneral The project will result in: See attached Application Admin. ATTACHMENT B - SCOPE OF WORK AND BUDGET Grantees: Goochy Investments, LLC Section C: Project Schedule and Budget: See attached Application Budget Project Activities Project Applicant's City Category Totals Contribution Contribution 21 AGeneralAdmin Materials and Labor $11,018.00 $5,508.00 $5,508.00 - 5 - ATTACHINIENT B June 3,2016 f Mr. Ben Braudrick f Assistant Planner Ci of Port Angeles tY Community and Economic Development Dept. r 321 East Fifth Street Port Angeles, WA 98362-0217 Re: Fagade Improvement Grant Program—824 C Street,Port Angeles Dear Ben Enclosed is our completed application for the above project. Goochy Investments, LLC is the owner of this Property. My brother,Mike Somers, and I are the Co-Managers of this LLC. 824 C Street is located in a busy commercial area near 8h and C . We would like to enhance its appearance by installing new awnings and painting the exterior siding and trim, as well as updating and replacing exterior lighting at entry doors. We believe this will greatly enhance not only this building, but be an improvement to the entire surrounding area as well. It is our goal to complete this project this summer. If we could be scheduled for the July 13, 2016 planning meeting,then I would plan to attend. Assuming approved,the project could start July 18a`, with an estimated 2 week completion. If you should need anything further to review or approve this application,please do not hesitate to contact me. I can be reached by cell(626) 590-6997 or email, keluck 9c-) i il.co i, Sincerely, Croochy Investments, LLC KathyCoLuc CManager g City of Port Angeles -il Facade and signage Improvement Grant Program APPLICATION FORM Applicant Name: `-a� Cit t� ly\ye5�Y'+1e oTs LIO, Kctf-�t, Luc V-, t0-Y11Ctnavrr Mailing Address: _ }'(r p1i 1� b�- czli tae Phone: (U� © (fz -� Email Address: Re(UCk5,1-3 RA MC i 1 , corn t Ku t��5 Business Name: (3jam, Business Type/Description: IPaeaae WW10rat(Ke on lOMW(6Ct0 Building Address: Improvement Type: " Fagade ❑ Sign Brief Project Description: Clean-op uldaj'kt C&-n t. (KIA.1 Pwldn } irdujVI- 1ep1+aMA04 Anticipated Start Date: TUI� j ,I')�()( EO Anticipated Completion Date:,_ Yu 1 d 1 4J Estimated Total Project Cost:$ ` ` d® Funding Request(50%or less): The owner(s) of the above property is fully aware and agree to all proposed improvements described in grant application.Applicant must have any changes to project proposal approved by property owner(s) Applicant's Signature: c4� Date: M Owner's Signature: !�"`-' Date: Department of Community and Economic Development 321 E.5'h Street,PO Box 1150 Port Angeles,WA 98362 Application Prepared 3/13/2015 FA(;ADE IMPROVEMENT PROJECT - 824 C Street Awnings Number Product Cost Total Cost zzsrz^ra-^¢a new Dickson 48959 (Londres)(incl. freight&tax) 5 $545.44 $2,728.00 installation labor 15 $100/hr $1,495.00 Paint Number Product Cost Total Cost Paint&material (tape, plastic, rollercovers,caulking,etc)(incl tax) 40 $35.00 $1,888.00 Labor(pressure wash, caulk and paint exterior) 74 $60/hr $4,400.00 Fagade Details Number Product Cost Total Cost new exterior Light fixtures 2 $82.00 $164.00 new exterior Light fixtures 2 $59.00 $118.00 installation Labor 3 $75/hr $225.00 TOTAL PROJECT MATERIAL COST $4,898.00 TOTAL PROJECT LABOR COST $6,120.00 TOTAL PROJECT COST $11,018.00 s 1 N I � z io $; W 5,IMI, I kYE7� g 9 1 i r l ry p�gff-q¢ # z � � tby ;, n: z K jfw4�tl��t � x } E � ss a X � ¢Z � S- -------------- SA g . d � � r k A Z s � Y r r� i c f v t a . 4 s 3 � b l. S i k v g j F 1 " " � 4 " MISS r � t4` F, N �f ti r b a h fy Z hlu� f d � h 4 r \ br r. .` a d a S r F r x� t s: x. 4 � 1 Proposed Color Scheme for 824 "C" Street — White Doors, New black awnings w/It.grey stripe Wood Siding- Light Grey Window and Door Trim - dark grey Hanging roof line & horizontal band — Black Existing brick exterior at street level AAwnings & Sunrooms of Distinction, Inc. 141 Timberline Dr. . Sequim $ WA ® 98382 PROPOSAL: NAME: f = PHONE: - ADDRESS: CITY: ZIP; } The above materials shall be guaranteed with manufacturers specific warranties and all labor warranted for three years from date of proposal. Any costs involved with obtaining necessary building permits shall be reimbursed by customer as an additional charge. The above work shall be completed in a professional manner for the total sum of$ Payments shall be as follows � Commencement of work shall begin approx. �,�h., 'x -� and be completed approx. Acceptance of Proposal The above prices,specifications and conditions are acceptable as stated.You are authorized to commence work as sohedule and weather conditions allow.We understand weather conditions may affect estimated completion date.Payment will be made as outlined above. Signed Submitted by: Date: State Reg. #AAWNII'991DA Phone/Fax 360-681-2727 Sums Construction ESTIMATE T 1727 E. 3rd Street Port Angeles, Wa 98362 360.670.6603 Kathy Luck Estimate# 0000001 C street Estimate Date 06/03/2016 Item Description Unit Price Quantity Amount Service Pressure wash,caulk,and paint exterior of building two coats of customer color. Includes all paint and materials Materials,tape,paper,plastic,roller covers,caulking,paint 1400.00 1.00 1,400.00 Labor 4400.00 1.00 4,400.00 Tax 8.4% 487.20 1.00 487.20 Subtotal 6,287.20 Total 6,287.20 Amount Paid 0.00 Estimate $6,287,20 Llog htl"ng Direct,cans,. A Build.corn Network Site Cart - 5 Items Product Description Price Quantity Total $82.00 UP(—"ltq $164.00 ate% Remove is ier 9023 Sea i lc Siu le Li ht 14" Tall Outdoor Wall Sconce 391 In-Stock Finish/Color- Black V, $8.97 -t-jP(-�a—te $8.97 Bulbrite 6165 White Remove DimmableG2Sha ed�Med�ium t�,26tia�scfla�loen Bqlb Finish/Color- Soft White $59.00 LJp(tate Moor, o Vaxcel Lialiting OW21581 Harwich I Light Outdoor Wall Sconce- 8 Remove Inches Wide 50 In-Stock Finish/Color- Textured Black IS $15.22 –tjPd­"'te $15.22 Bulbrite 1151 ft White Remove Diminable A19 Sha ed Medium E.26 Base Halogen Bulbs Finish/Color- Soft Vvbite Ship to: Port Angeles, WA (98362) Shopping Cart Tools Subtotal: $,24770 9 Cart Weight: 20.19 lbs Shipping: k-J. $5.99 FREE Estimated Tax: U $0,00 Grand Total: 3()