Loading...
HomeMy WebLinkAbout4.474 Original Contract -<I. </ 7 ~ I I I I I ,~ PROJECT MANUAL for ELECTRIC UNDERGROUND REBUILD - ELWHA LINE STAGE 2 PROJECT NO. 02-11 B CITY OF PORT ANGELES WASHINGTON JUNE 2004 GLENN A. CUTLER, P.E., DIRECTOR OF PUBLIC WORKS & UTILITIES GARY W. KENWORTHY, P.E., DEPUTY DIRECTOR OF ENGINEERING SERVICES For Information regarding this project, contact' James L. Harper, City of Port Angeles 360-417-4702 PROJECT MANUAL TABLE OF CONTENTS Electric Underground Rebuild - Elwha Line Stage 2 Project No. 02-11 B PART I BIDDING REQUIREMENTS: Vicinity Map ........................................................ 1-1 Advertisements for Bids . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. 1-2 Information for Bidders ............................................... 1-3 Bidders' Checklist ................................................... 1-4 Non-Collusion Affidavit. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. 1-5 Bidders's Construction Experience ....................................... 1-6 List of Proposed Subcontractors ......................................... 1-7 Bid Forms ......................................................... 1-8-9 Bid Bond .......................................................... 1-10 PART II CONTRACT FORMS SUBMITTED FOLLOWING AWARD OF CONTRACT Contract . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. 11-1-6 Performance and Payment Bond . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 11-7 Escrow Agreement for Retained Percentage . . . . . . . . . . . . . . . . . . . . . " . . . . . . . . . . 11-8 Certificate of Insurance (See sample) ....................... [prpvided by bidder] PART III SPECIAL PROVISIONS Special Provisions ........... . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 111-1-3 ATTACHMENT A: STATE PREVAILING WAGE RATES (14 pages) ATTACHMENT B: CONSTRUCTION CHANGE ORDER FORMS (3 pages) ATTACHMENT C: CONTRACTORS APPLICATION FOR PAYMENT FORM (3 pages) ATTACHMENT D: CONSTRUCTION SPECIFICATIONS (17 pages) ATTACHMENT E: RIGHT OF WAY USE PERMIT ATTACHMENT F: CONSTRUCTION STANDARDS (10 pages) ATTACHMENT G: CABLE TAGS & PULL TENSION (2 pages) ATTACHMENT H: PROJECT PLANS (5 pages) PART I BIDDING REQUIREMENTS ." , ELWHA UNDERGROUND REBUILD STAGE 2 CITY OF PORT ANGELES PORT ANGELES, WASHINGTON PROJECT LOCATION LEGEND NEW EXISTING 8y SINGLE TRANSFORMER ern / 3-TRANSFORMER BANK Iq~ H,",",,"" "" KVAR CAPAOTOR BANK / / / / 3 PHASE OH PRIMARY --_# ",-- _..-._~" "-.--.----- UG U /G SERVICE (// I ~ ! \, '. -------- --- -~-_.-- .--- Everett I I I I I I 2 PHASE OH PRIMARY Spokane o / / SINGLE PHASE OH PRIMARY I I I I I lUG / I~G , C/ "'., Who J?" '-'..... '~:::___I ver - P - 3 PHASE U/G PRIMARY 2 PHASE U /G PRIMARY I SINGLE PHASE U/G PRIMARY w ~ ~ ft={j ff !NJ @ If (()) [I!J - OH SERVICE - - - - - - - - - - STREET UGHT SERVICE o ~ -fP- DOUBLE DEADEND W/JUMPER X SPANGUY 0 POLE ~ ANCHOR -@ STREET LIGHT X METER ~ GROUNDED WYE ~ OPEN WYE Y UNGROUNDED WYE D,. UNGROUNDED DELTA ~ GROUNDED DELTA --/- SWlTCH/OISCONNECT ~ CUTOUT PHASING PHASING WIRE SZ ') \ VICINITY MAP NO SCALE DRAWING INDEX LOCA nON MAP NO SCALE DRAWING NO DESCRIPTION E-l E-2 E-3 COVER SHEET VlONITY MAP LOCATION MAP AND DRAWING INDEX ELWHA UNDERGROUND REBUILD STAGE 2 ELWHA UNDERGROUND REBUILD STAGE 2 DETAILS o 02 19 03 ISSUED FOR Btp_~.Q ~S~!:!~!1~_ DES CL D"" ON CK'O me REV SlRUC REV DATE (5,-1:'1, . '" ~ ~ CITY of PORT 12.47KV UNDERGROUND DISTRIBUTION ALE NO PAK01036 w/O 11-00803-10000 D"" NO A"'T""~T T:"C"t ELWHA UNDERGROUND REBUILD STAGE 2 ~I'ORr "l-\( -\. 0 , ' . h Q~ $' " , ' "", (~ ADVERTISEMENT FOR BIDS , ELECTRIC UNDERGROUND REBUILD - ELWHA LINE STAGE 2 PROJECT 02-118 City of Port Angeles Sealed bids will be received by the Director of Public Works & Utilities at 321 East Fifth Street, P. O. Box 1150, Port Angeles, Washington 98362, until 2'30pm, Friday June 25, 2004, and not later, and will then and there be opened and publicly read at that time In the Public Works Conference Room for the construction of the following improvements, Excavate and Install approximately 2900 feet of 2-51nch and 1-4inch condUit and install approximately 2900 cirCUit feet of 12.47 kV underground cable and associated equipment. The City Engineer's estimate for this project is $75,000 to $125,000 The time of completion (performance period) for this Project IS 60 working days. To view detailed plans and specifications (Project Manual), go to www bxwa com on the Internet, or contact the BUilders Exchange of Washington at 425-258-1303. Detailed plans and specifications (Project Manual) may be obtained from the office of the Electrical Engineering Manager, City of Port Angeles, upon payment of a non-refundable fee of $10.00. Informational copies of maps, plans and speCifications are on file for inspection in the office of the City Engineer [Phone 360-417-4700]. Bidders shall be qualified for the type of work proposed. A Bidder's Construction Experience Form is included in the Project Manual. All bids shall be submitted on the prescribed Bid Forms and In the manner as stated in this advertisement and in the Project Manual and said bids shall be accompanied by a bid deposit In the form of a cashier's check, postal money order, or surety bond to the City of Port Angeles in the amount of five percent (5%) of the total amount of the bid. If a surety bond is used, said bond shall be issued by a surety authOrized and registered to issue said bonds In the State of Washington. The bond shall specify the surety's name, address, contact and phone number, and shall include a power of attorney appointing the signatory of the bond as the person authOrized to execute it Should the successful bidder fall to enter into the Contract and furnish satisfactory performance bond within the time stated In the Information for Bidders, the bid deposit shall be forfeited to the City of Port Angeles Faxed bids andlor surety bonds will not be accepted. Minority and women owned businesses shall be afforded full opportunity to submit bids in response to this invitation, shall not be discriminated against on the grounds of gender, race, color, age, national origin or handicap In consideration of an award of any contract or subcontract, and shall be actively soliCited for participation In this project by direct mailing of the Invitation to bid to such bUSinesses as have contacted the City for such notification Further, all bidders are directed to solicit and conSider minOrity and women owned bUSinesses as potential subcontractors and material suppliers for this project. The City of Port Angeles reserves the right to accept the bid that is in the best Interest of the City, to postpone the acceptance of bids and the award of the Contract for a period not to exceed sixty (60) days, or to reject any and all bids. If all bids are rejected the City may elect to re-advertise for bids. Subject to the foregoing, the contract Will be awarded to the lowest responsible bidder. Bids must be submitted In a sealed envelope with the outside clearly marked With the bid opening date and time, the project name and number as It appears in this advertisement and the name and address of the bidder. Bids shall be addressed to the Director of Public Works & Utilities, City of Port Angeles, 321 East Fifth Street, P. 0 Box 1150, Port Angel~s, Washington 98362. When awarded the Contract, the successful bidder shall promptly execute the Contract and shall furnish a bond of faithful performance of the Contract in the full amount of the Contract price. Glenn A Cutler, P.E Director of Public Works & Utilities Publish: Peninsula Daily News June 6 & 13, 2004, Daily Journal of Commerce June 4, 2004 1-2 INFORMATION FOR BIDDERS Sealed bids will be received by the City of Port Angeles (herein called "Owner"), at 321 East Fifth Street, Port Angeles, Washington 98362, until the time and date as stated In the ADVERTISEMENT FOR BIDS or as amended through addendum, and then at said office publicly opened and read aloud. Each bid shall be received by the Owner in the manner set forth In the ADVERTISEMENT FOR BIDS. Each bid must be submitted in a sealed envelope, so marked as to indicate its contents without being opened, and addressed In conformance with the instructions of the ADVERTISEMENT FOR BIDS. Each bid shall be submitted on the reqUired bid form contained in Part I of the Project Manual. All blank spaces for bid prices must be filled In, In ink or typewritten, and the Bid Form must be fully completed and executed when submitted. Only one copy of the Bid Form is required. In addition, all other forms included in Part I shall be filled out and completed, Including any addendum(s), and enclosed in a sealed envelope endorsed with the name of the work. Each bid shall be accompanied by a bid deposit In the form of a cashier's check, postal money order, or surety bond to the City of Port Angeles for a sum of not less than 5% of the amount of the bid, and no bid will be considered unless accompanied by such bid deposit The Owner may waive any informalities or minor defects or reject any and all bids. Any bid may be withdrawn prior to the scheduled time for the opening of bids or authorized postponement thereof. Any bid received after the time and date specified shall not be considered. No bidder Will be permitted to withdraw ItS bid between the closing time for receipt of bids and execution of the Contract, unless the award IS delayed for a penod exceeding sixty (60) calendar days. A conditional or qualified bid Will not be accepted The bid award will be made to the lowest responsible bidder. The City of Port Angeles reserves the right to accept the bid that is in the best interest of the City, to postpone the acceptance of bids and the award of the Contract for a period not to exceed sixty (60) days, or to reject any and all bids. If all bids are rejected, the City may elect to re-advertise for bids. Subject to the foregoing, the contract will be awarded to the lowest responsible bidder The work will begin within ten (10) calendar days after notice to proceed from the Director of Public Works & Utilities and shall be completed within the time as stated in the Advertisement for bids. The Owner may make such investigations as it deems necessary to determine the ability of the bidder to perform the work, and the bidder shall furnish to the Owner all such information and data for this purpose as the Owner may request. The Owner reserves the nght to reject any bid, If the eVidence submitted by, or investigation of, such bidder falls to satisfy the Owner that such bidder IS properly qualified to carry out the obligations of the Contract and to complete the work contemplated therein The party to whom the Contract IS awarded Will be required to execute the Contract and obtain the Performance and Payment Bond within ten (10) calendar days from the date the notice of award IS delivered to the bidder. Such bond(s) shall be on the form provided by the Owner, specify the name, contact phone, and address of the surety, and shall Include a power of attorney appointing the signatory of the bond(s) as the person authorized to execute it (them). The notice of award Will be accompanied by the necessary Contract and bond forms In case of failure of the bidder to execute the Contract, the Owner may, at its option, conSider the bidder in default, in which case the bid deposit accompanYing the bid shall become the property of the Owner. The Owner, within ten (10) calendar days of receipt of the acceptable Performance and Payment Bond and the Contract signed by the party to whom the Contract was awarded, Will sign the Contract and return to such party an executed duplicate of the Contract Should the Owner not execute the Contract within such penod, the bidder may, by wntten notice, withdraw its signed Contract Such notice of withdrawal Will be effective upon receipt of the notice by the Owner The notice to proceed will be issued within ten (10) calendar days of the execution of the Contract by the Owner Should there be reasons why the notice to proceed cannot be Issued within such penod, the time may be extended by mutual agreement between the Owner and Contractor If the notice to proceed has not been Issued within the ten (10) calendar day period or within the period mutually agreed upon, the Contractor may terminate the Contract without further liability on the part of either party All applicable laws, ordinances, and the rules and regulations of all authorities having junsdictlon over construction of the project shall apply to the Contract throughout. 1-3 BIDDER'S CHECKLIST 1. Has a bid deposit In the form of a surety bond in the proper form, postal money order, or cashier's check been enclosed with your bid? 2 Is the amount of the bid deposit at least five percent (5%) of the total amount of the bid? 3 Have the bid forms been properly signed? 4 Do the written amounts of the bid forms agree with the amounts shown In figures? 5. Have you bid on all Items? 6. Has the non-collusion affidavit been properly executed? 7. Have you shown your contractor's state license number on the bid form? 8. Have you listed Ell Subcontractors that you will use for the project? 9. Have you filled out the bidder's construction experience form? The followmg forms are to be executed after the Contract is awarded: A. Contract - To be executed by the successful bidder and the City B Performance bond - To be executed on the form provided by Owner, by the successful bidder and ItS surety company To include name, contact and phone number, and address of surety and power of attorney of slqnatorv C Insurance certiflcate(s). 1-4 NON-COLLUSION AFFIDAVIT STATE OF WASHINGTON) ) COUNTY OF King ) The undersigned, being first duly sworn on oath, says that the bid herewith submitted is a genuine and not a sham or collusive bid, or made in the interest or on behalf of any person not therein named; and (s)he further says that the said bidder has not directly or indirectly induced or solicited any bidder on the above work or supplies to put in a sham bid, or any other person or corporation to refrain from bidding, and that said bidder has not in any manner sought by collusion to secure to him/her self an advantage over any other bidder or bidders. ~-$. Sign~ur: of Bidder/Contractor Subscribed and sworn to before me this 24th day of June ,2004. ~,"" _---; J. Bt:; "\, ;' ~<<;. .........P-t( \! "" 4J ...~S\ON ~.'. ~ I, ;' ....., ...~ +..()... ,I... I, : :~ ~OTARy ~\ ~ ~ :u _0- (I): ~ I. ~ Pusuc .: : ~ . . " , ~.. .....;::. ~ 't ~>::/!...29-0~.."Acr.;~ t,\;~.~;;ii.S~~":~ ","'.............-- My Comm. Exp.: 8/29/04 1-5 BIDDER'S CONSTRUCTION EXPERIENCE Answer all questions and provIde clear and comprehensive information. Name of bidder: Suoerior Electric Northwest, Inc. RegistratIon No. STJPF.RFN01 fiMK 2 Permanent main office address: 11711 Northcreek Pkwy, D103 Rothpll. WA g8011 3. When organized: 1989 4 Where Incorporated: Washington 5. How many years have you been engaged in the contracting business under your present firm name? 7 years 6.*Contracts on hand. (Schedule these, showing gross amount of each contract and the approximate anticipated dates of completion), contact name and phone number. ~ee ~t-t-~,...npc'l 7 · General character of work performed by your company: Qualitv and safe line construction 8. · Have you ever failed to complete any work awarded to you? If so, where and why? No 9 · Have you ever defaulted on a contract? No 10 · List the more important projects recently completed by your company, stating approximate cost for each, the month and year completed, contact name and phone number. See attached 11 · List your major equipment available for this contract' See attached 12. * Experience of bidder in construction similar to this project in work and importance: See attached 13 Will you, upon request, fill out a detailed financial statement and furnish any other Information that may be required by the City? Yes · Add separate sheets if necessary. The underSigned hereby authorizes and requests any person, firm or corporation to furnish any information requested by the City of Port Angeles. ~ Date. {'/,;}1/o'l _~ _ L___ . BI er' I ature John A. Brown Print Name: John A. Brown Title: Operations Manaqer 1-6 ProVided to Builders Exchange of WA, Inc. For usage Conditions Agreement see www.bxwa.com LISTING OF PROPOSED SUBCONTRACTORS Bidder shall list all subcontractors proposed to be used on the project. FAILURE TO LIST SUBCONTRACTORS SHALL BE CONSIDERED TO BE A NON-RESPONSIVE BID. If there are no subcontractors, write "NO SUBCONTRACTORS WILL BE USED". NAME, ADDRESS AND CONTRACTOR'S DESCRIPTION OF WORK Io(t-(~I~ I<A III IN MI Kemp West Clearing & Grubbing 4911 Bickford Ave. Snohomish, WA 98290 -6j/ - ~- SIGNATURE and TITLE 1-7 Provided to Builders Exchange of WA, Inc. For usage Conditions Agreement see www.bxwa.com BID FORM Honorable Mayor and City Council Port Angeles City Hall 321 East Fifth Street Port Angeles, WA 98362 BIDDER: Superior Electric Northwest, IncREGISTRATION NO. SUPEREN016MK DATE. r,/Jo/locf The undersigned, hereinafter called the bidder, declares that the only person(s) interested in this bid are those named herein; that the bid is in all respects fair and without fraud; and that it is made without any connection or collusion with any other person making a bid on this project. The bidder further declares that it has carefully examined the plan, specifications, and contract documents, hereinafter referred to as the Project Manual, for the construction of the proposed project _, improvement(s); that it has personally inspected the site(s); that it has satisfied itself as to the types and quantities of materials, the types of equipment, the conditions of the work involved, including the fact that the description of and the quantities of work and materials, the types of equipment, the conditions of and the work involved as included herein, are brief and are intended only to indicate the general nature of the work and to identify the said quantities with the corresponding requirements of the Project Manual; and that this bid is made in accordance with the provisions and the terms of the Contract included in the Project Manual. The bidder further agrees that it has exercised its own judgment regarding the interpretation of surface information and has utilized all data which it believes IS pertinent from the City Engineer, hereinafter also referred to as the City or Owner, and such other source of information as it determined necessary in arriving at its conclusion The bidder further certifies that the subcontracting firms or businesses submitted on the LISTING OF PROPOSED SUBCONTRACTORS will be awarded subcontracts for the described portions of the work: If the bidder is awarded a construction contract on this bid, the name and address of the surety who will provide the performance bond is: Continental Casualty Co. Weible & Cahill, LLC Agent 2300 Cabot Dr., Ste 100, Lisle, IL Agent Address Surety CNA Plaza, Chicago, IL 60685 Surety address Laurie Fish 630-245-4602 Surety Contact and Phone Number Patty Kenis 630-245-4600 Agent Contact and Phone Number 1-8 PrOVided to BUilders Exchange of WA, Inc. For usage Conditions Agreement see www.bxwa.com ADDENDA ACKNOWLEDGMENT The bidder hereby acknowledges that it has received Addenda No(s). 1 to this Project Manual. The name of the bidder submitting this bid and its business phone number and address, to which address all communications concerned with this bid and with the Contract shall be sent, are listed below Bidder's firm name Superior Electric Northwest, Inc. Complete address PO Box 808, Bothell, WA 98041-0808 (Street aooress) (State) (ZIp) Telephone No Signed by a:L. :ii:' .. Printed Name: John A Brown 425-485-7908 Title Operations Manager Notes: (1) If the bidder is a partnership, so state, giving firm name under which business is transacted. (2) If the bidder is a corporation, this bid must be executed by its duly authorized officials. . 1-9 Provided to BUilders Exchange of WA, Inc For usage Conditions Agreement see www.bxwa.com 810 F_ORM ___ ~_ __. _ ___ _ ELW~_A RE~U!~P-'~T~GE_21 PROJECT 02-118 " -, ! -----. - -..-.t.--.--. -, .----- -------. -------- -----.---.-....-.- -------- --- ._~-- ___ __-"'_ _ _nO' _ __~!.D....!!.~~,_ __" __.. _ w______LJ:I~!!~ __ __El_I~ _ !-_~~O~_~ E_a.~I~~.~li": .__. _.II~M~<2.~I _ _ __ " ii, OlY COST PER UNIT - 'n' .-.----j--- I __on. .------. -,---.--..--i---- ..- ----.- -------------- ~---.--.-.-------. INST ALLS ii, Trenching and Backfill Conduit 5" PVC CondUit 4" PVC U 3 04 (SectlOnal1zlng Cabinet and Vault) Install Vault Cable U 3 02 (Termination Three Phase Underground) Backfill Man Hole Street Asphalt Repair 1 2 3 4 5 6 7 8 9 Feet Feet Feet Each Each CircUit ft Each Each Sqft 2900 5800 2900 3 7 3100 2 2 100 :10..00 1 t)t) t:;t; : 1 Q(\(\ (\(\ '1 ")f'\ f'\f'\ ':l ") '1 -~" f'\f'\ ~'J"r.' in :?o fl :?Q t)t)t) t)t) t:; Q(\(\ f'\(\ 1 AAt; 00 t:; Af'\f'\ f'\f'\ n ;1 ;:; ';;' " ") -, \i '. \; OPTIONAL ITEMS 10 Conduit 2" PVC (PUD) 11 Coordinate cable Installation by Owesl Feet Feet 1200 :t> .aU 2400 'l:1?t; $ Il.U.UO 'l: "'It)t)t) t)t) I 1 I I I I I , , ; I I I : I : I I , I , I REMOVALS 1 Man Hoie and Vault lid Each 2 Rt)t) t)t) )t) 2 UG Riser and Terminations Each 2 -I UUU.UU ; . .)0 3 R/W Clearing LS 1 17 Inn.nn ,"'l' 10 , I i I : I i I I : __ __"_____~____.; _____ ---1-------;- ______.__--,_________.__.__ __ 1______ ~~_ .__ __________.____ _.___. _._______! , ,', I I , I ~~rT1P2..niNa~T~~__;i~;;F.i-;;;:;t--r1 r -l\i~:;:.t-ih;;.;est ~Tnr..~~- ~-:_ '__ __: :=~=_===_-~_~29}~"C~gs~!! -Trag ~-i:j'RO ~ -6-0----; ,___L___~ Q...~ ' -;-7~-1,- ;-/: --;,t-------- _~ALg~ TA.~8.3~o $ 9 128 34 : ,_~.uth!'!,1zed-~~Q..~~~ur _.' , * t&h.: · ----- _!?ate~~._Q_-:r_~__.__~__ --"!:9!~~_~9~_T., $119: 1 08: 34 'Tltle ;-'Qperatlons -Mana~er--.---'_----- ---.._- ---- --: _ '_:_:-:---~~.~-':-:~=~_-~.=:--:===-~=~~-.~~:==~~:~~~=-~=-=-~_ I WA StatElC~onir~tior~:~'iis-Ed.Jo; STrPryF.NOf~MI< _ __:-_-~-- ~~ -- ----- --- '--- _n~~_~:_::_:__:- _--- .------- - ELx~l;at~,;_ p~ie:;::: --5.7?ofos i-- - -- ----y-----. -__ -_::~~----_~: _: ...:~~-:_ '!- _u ---------- ---- n' - - -=--:~_.:_ :_-=--=-- - __ _ _n__.. .._ ____.I.u ._ ______L _ . _ ____'- _______ ---I 1-10 ProVided to BUilders Exchange of WA, Inc. For usage Conditions Agreement see VNJW.bxwa com , .' (iA I.... d ~ BID BOND FORM Herewith find deposit In the form of a cashiers check, postal money or sr or bid bond In the amount of $ which amount Is not les than five (5%) percent of the total bid. SIGN HERE BID BONO KNOW ALL MEN BY THESE PR.ESENTS: Superior Electric ' , Continental That we, 1\1"rt~T.T"'d I Tn,.. as Principal and Casualty Company as Surety, are held and firmly bound unto the CITY OF PORT ANGELES as Obligee, in the pe al sum of _ 5% Dollars, for the payment of which the Principal and the Surety ind themselves, their heirs, executors, administrators, successors and assigns, Jointly an' 'severally. by these presents. ' The condition of this obligation is such that if the Obligee shall make any award to th Principal for: Electric Underground Rebuild - Elwna line Stage 2 Project 02.11 B according to the terms of the bid made by the Principal, and the Principal shall duly enter into a contract with the Obligee in accordance with the terms of said bid and a ard and shall give bond for the faithful performance thereof, with Surety or Sureties approved by the Obllgee; or if the Principal shall, In case of failure so to dOj pay and forfeit to the Obli ee the penal amount of the deposit specified in the advertIsement for bids, then this obllgati n shall be null and void; otherwise It shall be and remain in full force a'nd effect and the Surety hall forthwith pay and forfeit to the Obligee, as penalty and liquidated damages, the smo nt of this bond. Superior Electric Northwest, Inc. PMnol 1 .~ Attorney-in- Fact CNA Pl za. Chicago, IL 60685 Surety Address 2004. SIGNED, SEALED AND DATED THIS 25th day of BY: David A. NeJson, Pr sident Weible & Cahill, LLC Agent -......, 2300 Cabot Dr., Ste 100, L sle, IL 60532 Agent Address Patrick Holland, 630-719-3013 Surety Contact & Telephone Number Laurie Fish 630-245-4600 Agent Contact & Telephone Nu ber Dated: Received return of deposit in the sum 01 $ 1-11 Provided to Builders Exchange of WA, Inc, For usage Conditions Agreement see WWW.bxwa.com ACKNOWLEDGMENT BY SURETY STATE OF ILLINOIS COUNTY OF DuPage On this 25th day of June, 2004, before me personally appeared Laura E. Fish_known to, me to be the Attorney-In-Fact of Continental Casualty Company, the Corporation that executed the within instrument, and acknowledged to me that such corporation executed the same. IN WITNESS WHEREOF, I have hereunto set my hand and affixed my official seal, at my office in the aforesaid County, the day and year in this certificate first above written. (Seal) "OFFICIAL SEAL" ESTHER C. JIMENEZ Notary Public, Stale of IllInois My Commission ExPires MAR. 26, 2007 Notary Public In the Sta County of DuPage POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men By These Presents, That Continental Casualty Company, an IllInois corporation, NatIonal FIre Insurance Company of Hartford, a ConnectIcut corporatIOn, and Amencan Casualty Company ofReadmg, PennsylvanIa, a PennsylvanIa corporatIOn (herem called "the CNA CompanIes"), are duly orgamzed and eXlstmg corporatIOns haVIng their pnnclpal offices m the City of ChIcago, and State of IllInOIs, and that they do by vIrtue of the sIgnatures and seals herem affixed hereby make, constItute and appoint William P Weible, Molly M Moran, William Cahill, Kimberly Sawicki, Deborah Buss, Patricia J Kenis, Phyllis Boyd, Kimberly K Libers, Melissa Newman, Laura E Fish, Karen A Ryan, Individually of LIsle, IL, theIr true and lawful Attomey(s)-m-Fact WIth full power and authonty hereby conferred to SIgn, seal and execute for and on theIr behalf bonds, undertakmgs and other oblIgatory mstruments of snmlar nature - In Unlimited Amounts - and to bmd them thereby as fully and to the same extent as If such mstruments were signed by a duly authonzed officer of theIr corporatIOns and all the acts of saId Attorney, pursuant to the authonty hereby glVen IS hereby ratified and confirmed. ThIs Power of Attorney IS made and executed pursuant to and by authonty ofthe By-Law and ResolutIOns, pnnted on the reverse hereof, duly adopted, as mdlcated, by the Boards of Directors of the corporations. In Witness Whereof, the CNA CompanIes have caused these presents to be SIgned by theIr Senior VIce President and their corporate seals to be hereto affixed on thIS 1st day of October, 2003. Continental Casualty Company National Fire Insurance Company of Hartford Amencan Casualty Company ofReadmg, Pennsylvania State of IllInOIS, County of Cook, ss: On thIS 1st day of October, 2003, before me personally came MIchael Gengler to me known, who, bemg by me duly sworn, dId depose and say that he reSIdes m the CIty of ChIcago, State of IllInOIs; that he is a Semor VIce PresIdent of Continental Casualty Company, an IllInOIS corporatIon, NatIOnal FIre Insurance Company of Hartford, a Connecticut corporatIon, and Amencan Casualty Company ofReadmg, PennsylvanIa, a PennsylvanIa corporatIOn descnbed m and whIch executed the above mstrument; that he knows the seals of saId corporatIOns; that the seals affixed to the saId mstrument are such corporate seals, that they were so affixed pursuant to authonty gIVen by the Boards of DIrectors of saId corporatIOns and that he SIgned hIS name thereto pursuant to lIke authonty, and acknowledges same to be the act and deed of saId corporatIons <f::~ cY~ OFFICIAL SEAL ELIZA PRICE NOTARY PUBUC, STATE OF UINOIS MY COMMISSION EXPIRES 0Dl17IDB My Commission Expires September 17, 2006 CERTIFICATE I, Mary A. RIbIkawskis, ASSIStant Secretary ofContmental Casualty Company, an IllmOls corporatIOn, National FIre Insurance Company of Hartford, a Connecticut corporation, and Amencan Casualty Company ofReadmg, Pennsylvania, a PennsylvanIa corporatIOn do hereby certIfy that the Power of Attorney herem above set forth IS still m force, and further certIfy that the By-Law and ResolutIOn of the Board ofDuectors ofthe corporatIOns pnnted on the reverse hereof is stilI in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the saId corporations thIS 25th day of June 2004 Form F6853-11/2001 Continental Casualty Company NatiOnal FIre Insurance Company of Hartford American Casualty Company of Reading, Pennsylvania a~ Assi~tant Secretary kis Authorizing By-Laws and Resolutions ADOPTED BY THE BOARD OF DIRECTORS OF CONTINENTAL CASUALTY COMPANY: Tlus Power of Attorney IS made and executed pursuant to and by authority of the following By-Law duly adopted by the Board of Directors of the Company. "Article IX--Jtxecution of Documents SectIon 3. Appointment of Attorney-m-fact. The ChaIrman of the Board of Directors, the PresIdent or any ExecutIve, Senior or Group Vice PreSIdent may, from tJme to tJme, appoint by wntten certIficates attorneys-m-fact to act in behalf of the Company in the executJon of pohcles of msurance, bonds, undertakmgs and other obhgatory instruments of hke natJlre. Such attorneys-m-fact, subject to the liIDltatJons set forth m theIr respectJve certificates of authority, shall have full power to bmd the Company by theIr signatJlre and executJon of any such instruments and to attach the seal of the Company thererto. The ChaIrman of the Board of DIrectors, the PreSIdent or any ExecutJve, Seruor or Group VIce PreSIdent or the Board of DIrectors, may, at any tIme, revoke all power and authonty preVIously gIVen to anyattorney-m-fact." Thts Power of Attorney IS SIgned and sealed by facsnnile under and by the authonty of the followmg ResolutJon adopted by the Board of DIrectors of the Company at a meeting duly called and held on the 17th day of February, 1993. "Resolved, that the slgnatJlre of the President or any ExecutJve, Senior or Group VIce President and the seal of the Company may be affixed by facsIIDlle on any power of attorney granted pursuant to Section 3 of ArtJcle IX of the By-Laws, and the sIgnature of the Secretary or an AssIstant Secretary and the seal of the Company may be affixed by facsimile to any certIficate of any such power and any power or certIficate beanng such facSImile sIgnature and seal shall be vahd and bmding on the Company. Any such power so executed and sealed and certified by certIficate so executed and sealed shall, with respect to any bond or undertaking to which it is attached, continue to be valid and bmdmg on the Company." ADOPTED BY THE BOARD OF DIRECTORS OF AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA Thts Power of Attorney is made and executed pursuant to and by authority of the followmg By-Law duly adopted by the Board of DIrectors of the Company. "Article VI--Execution of Obligations and Appointment of Attorney-In-Fact SectJon 2. Appomtment of Attorney-m-fact. The Chairman of the Board of DIrectors, the President or any ExecutJve, Semor or Group VIce PreSIdent may, from tIme to time, appoint by wntten certificates attorneys-m-fact to act m behalf of the Company m the executJon of pohcles of Insurance, bonds, undertakmgs and other obhgatory Instruments of like natJlre. Such attorneys-m-fact, subject to the hIDltatJOns set forth in theu respectJve certIficates of authonty, shall have full power to bmd the Company by theIr signature and execution of any such Instruments and to attach the seal of the Company thereto The PresIdent or any ExecutJve, Senior or Group Vice PresIdent may at any tJme revoke all power and authonty preVIously gIven to anyattorney-m-fact." Thts Power of Attorney is SIgned and sealed by facsimile under and by the authority of the following ResolutJon adopted by the Board of DIrectors of the Company at a meetmg duly called and held on the 17th day of February, 1993. "Resolved, that the signature of the PresIdent or any ExecutIve, Senior or Group VIce President and the seal of the Company may be affixed by faCSImIle on any power of attorney granted pursuant to SectIon 2 of ArtIcle VI of the By-Laws, and the sIgnature of the Secretary or an ASSIstant Secretary and the seal of the Company may be affixed by faCSImile to any certIficate of any such power and any power or certIficate beanng such facsllrule sIgnature and seal shall be valid and binding on the Company. Any such power so executed and sealed and certIfied by certIficate so executed and sealed shall, WIth respect to any bond or undertakmg to which It is attached, continue to be valid and bindmg on the Company." . ADOPTED BY THE BOARD OF DIRECTORS OF NATIONAL FIRE INSURANCE COMPANY OF HARTFORD ThIs Power of Attorney is made and executed pursuant to and by authonty of the followmg ResolutJon duly adopted on February 17, 1993 by the Board of Duectors of the Company. "RESOLVED: That the President, an ExecutJve VIce PresIdent, or any Seruor or Group VIce PresIdent of the Corporation may, from tJme to tJme, appomt, by wntten certIficates, Attorneys-m-Fact to act m behalf of the CorporatJon in the executJon of poliCIes of Insurance, bonds, undertakmgs and other obhgatory Instruments of hke nature. Such Attorney-m-Fact, subject to the hmitatJons set forth in theIr respectJve certIficates of authonty, shall have full power to bmd the CorporatIon by theIr signature and executJon of any such Instrument and to attach the seal of the Corporation thereto. The PreSIdent, an Executive VIce PreSIdent, any Senior or Group VIce PreSIdent or the Board of Duectors may at any time revoke all power and authority preVIously given to any Attorney-m-Fact " ThIs Power of Attorney is SIgned and sealed by faCSImile under and by the authority of the following ResolutJon adopted by the Board of DIrectors of the Company at a meetmg duly called and held on the 17th day of February, 1993. "RESOLVED: That the sIgnature of the PreSIdent, an Executive VIce President or any Semor or Group VIce PreSIdent and the seal of the CorporatJon may be affixed by facsIIDlle on any power of attorney granted pursuant to the Resolution adopted by tlus Board of DIrectors on February 17, 1993 and the signature of a Secretary or an Assistant Secretary and the seal of the CorporatJon may be affixed by faCSIIDlle to any certIficate of any such power, and any power or cernficate beanng such facsiIDlle sIgnature and seal shall be valid and bmdmg on the CorporatJon Any such power so executed and sealed and certified by certIficate so executed and sealed, shall WIth respect to any bond or undertaking to whIch It IS attached, contmue to be vahd and bmdmg on the CorporatJon " ... . " . .. NOTICE In accordance with the Terrorism Risk Insurance Act of 2002, we are providing this disclosure notice for bonds and certain insurance policies on which one or more of the Writing Companies identified below is the surety or insurer. To principals on bonds and insureds on certain insurance policies written by anyone or more of the following companies (collectively the "Writing Companies") as surety or insurer: Western Surety Company, Universal Surety of America, Surety Bonding Company of America, Continental Casualty Company, National Fire Insurance Company of Hartford, American Casualty Company of Reading, P A, The Firemen1s Insurance Company of Newark, NJ, and The Continental Insurance Company. DISCLOSURE OF PREMIUM The premium attributable to coverage for terrorist acts certified under the Act was Zero Dollars ($0.00). DISCLOSURE OF FEDERAL PARTICIPATION IN PAYMENT OF TERRORISM LOSSES The United States will pay ninety percent (90%) of covered terrorism losses exceeding the applicable surety/insurer deductible. Form F7310 City of Port Angeles Elwha Rebuild Stage 2 Project 02-11B Contracts on hand City of Blaine Underground and Overhead Distribution Feeder Contract Amount: $2,900,000.00 Completion Date: Summer 2004 Contact: Sandy Peterson 360-332-8820 Clark County PUD Distribution Line Rebuild Contract Amount: $169,000.00 Completion Date: July 2004 Contact: Don LiDrazzah 360-992-8877 Snohomish County PUD 12kV Vault Room Contract Amount: $165,000.00 Completion Date: July 2004 Contact: Nick Fadich 425-783-5585 Clallam County PUD 40,000 Feet of Underground Cable Contract Amount: $320,000.00 Completion Date: August 2004 Contact: Jim Hoare 360-565-3220 Customer Mason County PUD NO.1 N21971 Hwy101 Shelton, WA 98584 Willie Pierce 360-877-5249 Puget Sound Energy 411108th Ave. NE Bellevue, WA 98009 Brenda Wagner 425-462-3931 Snohomlsh County PUD PO Box 1107 Everett, W A 98206 John Wnght 425-783-4367 Snohomlsh County PUD PO Box 1107 Everett, W A 98206 Nick Fadlch 425-783-4489 SUPERIOR ELECTRIC NORTHWEST, INC. Project Title & Location Hwy 101 Distribution Line Rebuild 228th Street Rebuild Sammamlsh, WA Stanley Street Relocation Granite Falls, WA Lakes Stevens 12-125 Reconductor Lake Stevens, W A Dollar Value $554,000 Construction Period 2/10/2003 4/10/2003 $470,000 2-Jun 2-Aug $342,000 9/1/2003 12/1/2003 $520,000 4/21/2003 9/11/2003 Project Descnptlon Overhead and underground 12 kV dlstnbutlon rebUild with 1 5 miles of overhead and 3.2 miles of underground. Pad mounted transformers and sWitches RebUild 1.3 miles overhad and undergound conversion. Main feeder 12 kV. Pad mounted transformer and switch gear. 2.8 miles overhead and underground rebUild. Main feeder reroute Overhead and underground sWitches, regulators and reclosers. 3.5 miles overhead and underground rebUild Main feeder reroute. Overhead and underground sWitches, regulators and reclosers. . ~flRIIJ ~rA~ ELECTRIC SUPERIOR ELECTRIC L--_~___~_-==~_ -------I 11711 North Creek Pkwy. South Suite 0103 . Bothell, WA 98011 Phone: 425.485.7908. Fax: 425.485.3418 SUPEREN016MK This list is comprised of equipment owned by Michels Corporation and available for any project. Description Dump Trucks Pick-up Trucks Truck Tractors with Fifth Wheel Equipments, Pole, Pipe and Tool Trailers Trucks with Mounted Cranes, Ladders or Buckets Flatbed Utility Trucks Trucks with Mounted Winches Trenching and Ditching Machine some with Mounted Plows Graders Trailer Type Cable Plows and Crushing and Related Equipment Self-Propelled Rollers and Trailer Rollers Portable Power Compactors Hydraulic Backhoes, Cable Backhoes and Cable Cranes Crawler Tractors, Front End Loaders, Wheel Cable Plows and Crawler Tractors with Mounted Plows Wheel Type Tractors with Mounted Front End Loaders and Backhoes Self-propelled Power Hammers/Concrete Breakers Wheel Tractors with Mounted Sweepers or Various Little Cable Tools Wheel and Crawler Tractors with Side Booms Auger Backfilling Machines Air Compressors Horizontal Earth Boring Equipment TOTAL VALUE OF OWNED EQUIPMENT All equipment purchased between 1990 and 2003 Quantity 121 72 43 283 109 64 6 67 5 138 15 62 30 137 103 16 31 15 11 97 55 Appraised Market Value $2,700,000.00 $601,500.00 $1,800,000.00 $1,050,000.00 $3,815,000.00 $498,500.00 $90,000.00 $1,474,000.00 $280,000.00 $8,400,000.00 $39,000.00 $11,300.00 $2,100,000.00 $7,535,000.00 $2,369,000.00 $161,000.00 $236,000.00 $350,000.00 $16,500.00 $550,000.00 $8,250,000.00 $42,326,800.00 ,-- PART II CONTRACT FORMS SUBMITTED FOllOWING AWARD OF CONTRACT PUBLIC WORKS CONTRACT This Contract is made and entered into in duplicate this O~ day o~ and between the City of Port Angeles, a non-charter code city of the State of Washington, hereinafter referred to as "the City", and Superior Electric Northwest, Inc., an electrical construction contractor, hereinafter referred to as "the Contractor". WITNESSETH: Whereas, the City desires to have certain public work performed as hereinafter set forth, requiring specialized skills and other supportive capabilities; and Whereas, the Contractor represents that it is qualified and possesses sufficient skills and the necessary capabilities to perform the services set forth in this Contract. NOW, THEREFORE, in consideration of the terms, conditions, and agreements contained herein, the parties hereto agree as follows: 1. Scope of Work. The Contractor shall do all work and furnish all tools, materials, and equipment in order to accomplish the following project: Electric Underground Rebuild - Elwha Line Stage 2 Project 02-11 B in accordance with and as described in A. this Contract and B. the Project Manual, which include the attached plans, Specifications, Special Provisions, submittal requirements, attachments, addenda (if any), Bid Form, Performance and Payment Bond, and C. the Standard Specifications for Road, Bridge, and Municipal Construction prepared by the Washington State Department of Transportation, as may be specifically modified in the attached Specifications and/or Special Provisions, hereinafter referred to as "the standard specifications", and shall perform any alterations in or additions to the work provided under this Contract and every part thereof. The Contractor shall provide and bear the expense of all equipment, work, and labor of any sort whatsoever that may be required for the transfer of materials and for constructing and completing the work provided for in this Contract, except as may otherwise be provided in the Project Manual. 2. Time for Performance and Liquidated Damages. A. Time is of the essence in the performance of this Contract and in adhering to the time frames specified herein. The Contractor shall commence work within ten (10) calendar days after notice 2-1 to proceed from the City, and said work shall be physically completed within 60 working d'ays after said notice to proceed, unless a different time frame is expressly provided in wx;iting by the City. B. If said work is not completed within the time for physical completion, the Contractor may be required at the City's sole discretion to pay to the City liquidated damages as set forth in the Project Manual, for each and every day said work remains uncompleted after the expiration of the specified time. 3. Compensation and Method of Payment. A. The City shall pay the Contractor for work performed under this Contract as detailed in the bid, as incorporated in the Project Manual. B. Payments for work provided hereunder shall be made following the performance of such work, unless otherwise permitted by law and approved in writing by the City. No payment shall be made for any work rendered by the Contractor except as identified and set forth in this Contract. C. Progress payments shall be based on the timely submittal by the Contractor of the City's standard payment request form. D. Payments for any alterations in or additions to the work provided under this Contract shall be in accordance with the Request For Information (RFI) and/or Construction Change Order (CCO) process as set forth in the Project Manual. Following approval of the RFI and/or CCO, the Contractor shall submit the standard payment request formes). E. The Contractor shall submit payment requests with a completed Application for Payment form, an example of which is included in the Attachments to this Contract. This form includes a lien waiver certification and shall be notarized before submission. Applications for payment not signed or notarized shall be considered incomplete and ineligible for payment consideration. The City shall initiate authorization for payment after receipt of a satisfactorily completed payment request form and shall make payment to the Contractor within approximately thirty (30) days thereafter. 4. Independent Contractor Relationship. The relationship created by this Contract is that of independent contracting entities. No agent, employee, servant, or representative of the Contractor shall be deemed to be an employee, agent, servant, or representative of the City, and the employees of the Contractor are not entitled to any of the benefits the City provides for its employees. The Contractor shall be solely and entirely responsible for its acts and the acts of its agents, employees, servants, subcontractors) or representatives during the performance of this Contract. The Contractor shall assume full responsibility for payment of all wages and salaries and all federal, state, and local taxes or contributions imposed or required, including, but not limited to, unemployment insurance, workers compensation insurance, social security, and income tax withholding. 5. Prevailing Wage Requirements. The Contractor shall comply with applicable prevailing wage requirements of the Washington State 2-2 Department of Labor & Industries, as set forth in Chapter 39.12 RCW and Chapter 296-127 WAC. The Contractor shall document compliance with said requirements and shall file with the City appropriate affidavits, certificates, and/or statements of compliance with the State prevailing wage requirements. The Washington State Prevailing Wage Rates For Public Works Contracts, Clallam County, incorporated in this Contract have been established by the Department of Labor & Industries and are included as an Attachment to this Contract. The Contractor shall also ensure that any subcontractors or agents of the Contractor shall comply with the prevailing wage and documentation requirements as set forth herein. 6. Indemnification and Hold Harmless. A. The Contractor shall defend, indemnify, and hold harmless the City, its officers, officials, employees, and volunteers against and from any and all claims, injuries, damages, losses, or lawsuits, including attorney fees, arising out of or in connection with the performance of this Contract, except for injuries and damages caused by the sole negligence of the City. It is further provided that no liability shall attach to the City by reason of entering into this Contract, except as expressly provided herein. B. Should a court of competent jurisdiction determine that this Contract is subject to RCW 4.24.115, then, in the event of liability for damages arising out of bodily injury to persons or damages to property caused by or resulting from the concurrent negligence of the Contractor and the City, its officers, officials, employees, and volunteers, the Contractor's liability hereunder shall be only to the extent of the Contractor's negligence. It is further specifically and expressly understood that the indemnification provided herein constitutes the Contractor's waiver of immunity under Industrial Insurance, Title 51 RCW, solely for the purposes of this indemnification. This waiver has been mutually negotiated by the parties. The provisions of this section shall survive the expiration or termination of this Contract. 7. Insurance. The Contractor shall procure, and maintain for the duration of the Contract, insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, their agents, representatives, employees or subcontractors. Failure by the Contractor to maintain the insurance as required shall constitute a material breach of contract upon which the City may, after giving five working days notice to the Contractor to correct the breach, immediately terminate the Contract or at its discretion, procure or renew such insurance and pay any and all premiums in connection therewith, with any sums so expended to be repaid to the City on demand, or at the sole discretion ofthe City, off set against funds due the Contractor from the City. A. Minimum Scope of Insurance The Contractor shall obtain insurance of the types described below: 1. Automobile Liability insurance covering all owned, non-owned, hired and leased vehicles. Coverage shall be written on Insurance Services Office (ISO) form CA 00 01 or a substitute form providing equivalent liability coverage. If necessary, the policy shall be endorsed to provide contractual liability coverage. 2-3 11. Commercial General Liability insurance shall be written on ISO occurrence form CG 00 01 and shall cover liability arising from premises, operations, stop gap liaqility, independent contractors, products-completed operations, personal injury and advertising injury, and liability assumed under an insured Contract. The Commercial General Liability insurance shall be endorsed to provide the Aggregate Per Project Endorsement ISO form CG 2503 11 85. There shall be no endorsement or modification of the Commercial General Liability insurance for liability arising from explosion, collapse or underground property damage. The City shall be named as an insured under the Contractor's Commercial General Liability insurance policy with respect to the work performed for the City using ISO Additional Insured endorsement CG 20 10 1001 and Additional Insured- Completed Operations endorsement CG 2037 10 01 or substitute endorsements providing equivalent coverage. 111. Workers' Compensation coverage as required by the Industrial Insurance laws of the State of Washington. B. Minimum Amounts of Insurance The Contractor shall maintain the following insurance limits: 1. Automobile Liability insurance with a minimum combined single limit for bodily injury and property damage of $1 ,000,000 per accident. 11. Commercial General Liabilitv insurance shall be written with limits no less than $1,000,000 each occurrence, $2,000,000 general aggregate and a $2,000,000 products-completed operations aggregate limit. C. Other Insurance Provisions The insurance policies are to contain, or be endorsed to contain, the following provisions for Automobile Liability and Commercial General Liability insurance. i. The Contractor's insurance coverage shall be primary insurance with respect to the City. Any insurance, self-insurance, or insurance pool coverage maintained by the City shall be in excess of the Contractor's insurance and shall not contribute with it. 11. The Contractor's insurance shall not be cancelled or reduced as to coverage by either party, except after forty-five (45) days prior written notice by certified mail, return receipt requested, has been given to the City. D. Acceptability of Insurers Insurance is to be placed with insurers with a current A.M. Best rating of not less than A: VII. E. Verification of Coverage 2-4 The Contractor shall furnish the City with original certificates and a copy of the amendatory endorsements, including but not necessarily limited to the additional insured endorsement, evidencing the insurance requirements of the Contractor before commencement of the work. F. Subcontractors The Contractor shall include all subcontractors as insureds under its policies or shall furnish separate certificates and endorsements for each subcontractor. All coverages for subcontractors shall be subject to all of the same insurance requirements as stated herein for the Contractor. 8. Compliance with Laws. A. The Contractor shall comply with all applicable federal, state, and local laws, including regulations for licensing, certification, and operation of facilities and programs, and accreditatIOn and licensing of individuals, and any other standards or criteria as set forth in the Project Manual. B. The Contractor shall pay any applicable business and permit fees and taxes which may be required for the performance of the work. C. The Contractor shall comply with all legal and permitting requirements as set forth in the Project Manual. 9. Non-discrimination. The parties shall conduct their business in a manner which assures fair, equal and nondiscriminatory treatment of all persons, without respect to race, creed, color, sex, Vietriam era veteran status, disabled veteran condition, physical or mental handicap, or national origin, and, in barticular: A. The parties will maintain open hiring and employment practices and will welcome applications for employment in all positions from qualified individuals who are members of the above-stated minorities. B. The parties will comply strictly with all requirements of applicable federal, state or local laws or regulations issued pursuant thereto, relating to the establishment of non discriminatory requirements in hiring and employment practices and assuring the service of all patrons and customers without discrimination with respect to the above-stated minority status. 10. Assignment. A. The Contractor shall not assign this Contract or any interest herein, nor any money due to or to become due hereunder, without first obtaining the written consent of the City, nor shall the Contractor subcontract any part of the services to be performed hereunder without first obtaining the consent of the City. B. The Contractor hereby assigns to the City any and all claims for overcharges resulting from antitrust violations as to goods and materials purchased in connection with this Contract, except as to overcharges resulting from antitrust violations commencing after the date of the bid or other event 2-5 establishing the price of this Contract. In addition, the Contractor warrants and represents that each of its suppliers and subcontractors shall assign any and all such claims for overcharges to the City in accordance with the terms of this provision. The Contractor further agrees to give the City immediate notice of the existence of any such claim. 11. Contract Administration. This Contract shall be administered by John Brown on behalf of the Contractor and by James L. Harper, Electrical Engineering Manager on behalf ofthe City. Any written notices required by the terms of this Contract shall be served or mailed to the following addresses: Contractor: Superior Electric Northwest, Inc P.O. Box 808 Bothell, W A 98041-0808 City: City of Port Angeles P.O. Box 1150 321 East Fifth Street Port Angeles, W A 98362-0217 12. Interpretation and Venue. This Contract shall be interpreted and construed in accordance with the laws of the State of Washington. The venue of any litigation between the parties regarding this Contract shall be Clallam County, Washington. IN WITNESS WHEREOF, the parties hereto have caused this Contract to be executed the day and year first set forth above. CONTRACTOR: CITY OF PORT ANGELES: Superior Electric Northwest Inc. ~actor ~ By: 1 ~ Randy Burrus ~MJ(]W Mayor Approved as to Form: 0~i: City Attorney Title: Vice President of Finance Attest: 6fl~. Vpto^- CIty k 2-6 , ' .~ .J>> PERFORMANCE and PAYMENT BOND Bond to the City of Port Angeles KNOW ALL MEN BY THESE PRESENTS; That we, the undersigned. Superior Electric Northwe~ ~~cF.rincipaL and Continental Casual ty Company a cor!=loratlon, organized and existing under the laws of the State of ~ as a sU~ety corporation, and qualified under the laws of the State of Washington to become1j&tty upon bonds of contractors with municipal corporations as surety, are jointly and severally held and firmly bound to the City of Port Angeles in the penal sum of $ 111,810 .00 for the !=Iayment of which sum on demand we bind ourselves and our successors, heirs1 administrators or personal representatives, as the case may be. Bond # 929339428 This obligation Is entered Into pursuant to the statutes of the State of Washington and the ordinances of the City of Port Angeles. . Dated at Bothell , Washington, this ~ tday of July ,20~. The conditions of the above obligation are such that: WHEREAS, the City of Port Angeles haslet.or Is about to let to the said. Superior Electric Northwest, Inc. the above bounded Principal, a certain contract, the said contract being numbered 02.11~, and providing for Electric Underground Rebuild. Elwha Line (which contract is referred to herein and is made a part hereof as though attached hereto), and WHEREAS, the said Principal has accepted, or is about to accept, the said contract, and undertake to perform the work therein provided for in the manner and withIn the time set forth; now, therefore, If the said Principal, Superior Electric Ndrthwest. Inc. ~, shall faithfully perform all of the provisions of said contract in the manner and within the time therein set forth, or within such extensions of time as may be granted under said contract, and shall pay alllsborers, mechanicEI, subcontractors and materialmen, and all persons who shall supply said Prlnolpal or subcontractors with provisions and supplies for the oarrying on of said work, and shall indemnify and hold the City of Port Angeles harmless from any damage or expense by reason of failure of performance as speolfled In said contract or from defects appearing or developing In the material or workmanship !=Irovided or performed under said contract within a periOd of one year after Its acceptance thereof by the City of Port Angeles, then and In that event, this obligation Shall be,void; but otherwise, It shall be and remain In full force and effect. Signed this ~ day of July ,2004. Superior Electric Northwest, Inc. r-t~nclp.1 (2.., By' 1 L-~) ~ LL~ Randy Burru~ '\7i~~ "Ornc; rJonr nf Pi nrlnc~ Title CNA Plaza, Chicago. IL 60685 Surely Address P. Holland, 312-822-5000 Surety Contllct &lnd Phone Number Weible & Cahill, LLC, 2300 Cabot Dr., Ste 100, A;ent Address Lisle, IL 60532 L. F~sh, 630-245-4600 Agent Contact and Phone Number 2-7 "" l J ACKNOWLEDGMENT BY SURETY STATE OF ILLINOIS COUNTY OF DuPage On this 21st day of July, 2004, before me personally appeared Laura E. Fish_known to, me to be the Attorney-In-Fact of Continental Casualty Company, the Corporation that executed the within instrument, and acknowledged to me that such corporation executed the same. IN WITNESS WHEREOF, I have hereunto set my hand and affixed my official seal, at my office in the aforesaid County, the day and year in this certificate first above written. (Seal) "OFFICIAL SEAL" KAREN ^ RYAN NOTARY PUBL.IC STATE OF ILLINOIS cr. I f; ires 05/15/2008 Notary Public In the State of lIIino s County of DuPage Authorizing By-Laws and Resolutions ADOPTED BY THE BOARD OF DIRECTORS OF CONTINENTAL CASUALTY COMPANY: This Power of Attorney IS made and executed pursuant to and by authority of the followmg By-Law duly adopted by the Board of Directors of the Company. "Article IX-Execution of Documents Section 3. Appomtment of Attorney-in-fact. The Chairman of the Board of Directors, the President or any Executive, Senior or Group Vice President may, from time to time, appoint by written certificates attorneys-m-fact to act in behalf of the Company in the execution of policies of insurance, bonds, undertakings and other obligatory Instruments of like nature. Such attorneys-m-fact, subject to the limitations set forth in their respective certificates of authority, shall have full power to bind the Company by their signature and execution of any such instruments and to attach the seal of the Company thererto. The Chairman of the Board of Directors, the PreSident or any Executlve, Sernor or Group Vice President or the Board of Directors, may, at any time, revoke all power and authority previously given to any attorney-in-fact." This Power of Attorney is Signed and sealed by faCSimile under and by the authority of the following Resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 17th day of February, 1993. "Resolved, that the signature of the President or any Executive, Senior or Group Vice PreSident and the seal of the Company may be affixed by facsimile on any power of attorney granted pursuant to Sectlon 3 of Article IX of the By-Laws, and the signature of the Secretary or an Assistant Secretary and the seal of the Company may be affixed by faCSimIle to any certIficate of any such power and any power or certificate beanng such faCSimile signature and seal shall be valid and bmclmg on the Company. Any such power so executed and sealed and'certified by certIficate so executed and sealed shall, With respect to any bond or undertalong to wInch it IS attached, continue to be valid and binding on the Company." ADOPTED BY THE BOARD OF DIRECTORS OF AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA: This Power of Attorney IS made and executed pursuant to and by authonty of the following By-Law duly adopted by the Board of Directors of the Company. "Article VI-Execution of Obligations and Appointment of Attorney-In-Fact Section 2. Appomtment of Attorney-m-fact The Chairman of the Board of Directors, the President or any Executive, Senior or Group Vice President may, from time to time, appoint by written certIficates attorneys-in-fact to act in behalf of the Company in the executlon of poliCies of insurance, bonds, undertakings and other oblIgatory Instruments of like nature. Such attorneys-in-fact, subject to the limItatlons set forth m theIr respectlve certificates of authonty, shall have full power to bind the Company by their signature and execution of any such instruments and to attach the seal of the Company thereto. The President or any Executlve, Senior or Group Vice President may at any time revoke all power and authority previously given to any attorney-in-fact." Thts Power of Attorney is signed and sealed by faCSimile under and by the authority of the follOWing Resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 17th day of February, 1993. "Resolved, that the signature of the PreSident or any Executive, Sernor or Group Vice President and the seal of the Company may be affixed by facsimile on any power of attorney granted pursuant to Section 2 of Article VI of the By-Laws, and the signature of the Secretary or an Assistant Secretary and the seal of the Company may be affixed by facsimile to any certificate of any such power and any power or certIficate beanng such facsimIle signature and seal shall be valId and bmding on the Company. Any such power so executed and sealed and certified by certIficate so executed and sealed shall, With respect to any bond or undertaking to whIch It is attached, continue to be valid and bmdmg on the Company." ADOPTED BY THE BOARD OF DIRECTORS OF NATIONAL FIRE INSURANCE COMPANY OF HARTFORD' This Power of Attorney is made and executed pursuant to and by authonty of the following Resolution duly adopted on February 17, 1993 by the Board of Directors of the Company. "RESOLVED: That the PreSident, an Executive Vice President, or any Senior or Group Vice PreSident of the Corporation may, from tlme to tlme, appoint, by wntten certificates, Attorneys-m-Fact to act in behalf of the Corporation m the execution of poliCies of msurance, bonds, undertakmgs and other oblIgatory Instruments of lIke nature Such Attorney-in-Fact, subject to the limItatiOns set forth m their respectlve certificates of authonty, shall have full power to bmd the Corporatlon by theIr signature and execution of any such Instrument and to attach the seal of the Corporation thereto. The President, an Executive Vice President, any Sernor or Group Vice PreSident or the Board of Directors may at any time revoke all power and authonty previously given to any Attorney-in-Fact." This Power of Attorney IS signed and sealed by facsimIle under and by the authonty of the follOWing Resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 17th day of February, 1993. "RESOLVED: That the signature of the PreSident, an Executlve Vice PreSident or any Sernor or Group Vice President and the seal of the CorporatIon may be affixed by facsimIle on any power of attorney granted pursuant to the Resolution adopted by this Board of Directors on February 17, 1993 and the signature of a Secretary or an ASSistant Secretary and the seal of the Corporatlon may be affixed by facsimile to any certificate of any such power, and any power or certificate bearing such facsimIle signature and seal shall be valId and binding on the Corporatlon. Any such power so executed and sealed and certified by certificate so executed and sealed, shall with respect to any bond or undertaking to whIch it IS attached, continue to be valid and bindmg on the Corporation." POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men By These Presents, That Contmental Casualty Company, an IllInois corporation, National Fire Insurance Company of Hartford, a ConnectIcut corporatIOn, and American Casualty Company of Reading, Pennsylvania, a Pennsylvania corporatIOn (herein called "the CNA Companies"), are duly organized and existing corporatIOns having their pnncipal offices m the City of Chicago, and State of Illinois, and that they do by virtue of the signatures and seals herein affixed hereby make, constitute and appomt William P Weible, Molly M Moran, William Cahill, Kimberly Sawicki, Deborah Buss, Patricia J Kenis, Kimberly K Libers, Melissa Newman, LauraE Fish, Karen A Ryan, Esther C Jimenez, Individually of Lisle, IL, their true and lawful Attorney(s)-in-Fact with full power and authority hereby conferred to sign, seal and execute for and on their behalf - bonds, undertakings and other obligatory mstruments of sirrnlar nature - In Unlimited Amounts - and to bind them thereby as fully and to the same extent as if such mstruments were signed by a duly authorized officer of their corporations and all the acts of said Attorney, pursuant to the authority hereby given is hereby ratified and confirmed. This Power of Attorney is made and executed pursua.'1t to and by authority of the By-Law and ResolutIons, printed on the reverse hereof, duly adopted, as mdlcated, by the Boards of Directors of the corporations. In Witness Whereof, the CNA Companies have caused these presents to be Signed by their Semor Vice PreSident and their corporate seals to be hereto affixed on this 23rd day of June, 2004. OFFICIAL SEAL ELIZA PRICE NOTARY PUBUC, STATE OF UlNOIS 11ft CO....ISSION EXPIRES' 011I17/01 My Commission Expires September 17, 2006 Continental Casualty Company National Fire Insurance Company of Hartford American Casualty Company of Reading, Pennsylvania Vice President CERTIFICATE I, Mary A. Riblkawskls, Assistant Secretary of Contmental Casualty Company, an Illinois corporation, National Fire Insurance Company of Hartford, a Connecticut corporation, and American Casualty Company of Reading, PennsylvanIa, a Pennsylvania corporation do hereby certify that the Power of Attorney herem above set forth is still m force, and further certify that the By-Law and ResolutIOn of the Board of Directors ofthe corporations pnnted on the reverse hereof IS still in force. In testimony whereof! have hereunto subscribed my name and affixed the seal ofthe said corporatIOns this 21st . day of July 2004 Form F6853-1 1/2001 Continental Casualty Company National Fire Insurance Company of Hartford American Casualty Company of Reading, Pennsylvania ~a~ NOTICE In accordance with the Terrorism Risk Insurance Act of 2002, we are providing this disclosure notice for bonds and certain insurance policies on which one or more of the Writing Companies identified below is the surety or insurer. To principals on bonds and insureds on certain insurance policies written by anyone or more of the following companies (collectively the "Writing Companies") as surety or insurer: Western Surety Company, Universal Surety of America, Surety Bonding Company of America, Continental Casualty Company, National Fire Insurance Company of Hartford, American Casualty Company of Reading, P A, The Firemen's Insurance Company of Newark, NJ, and The Continental Insurance Company. DISCLOSURE OF PREMIUM The premium attributable to coverage for terrorist acts certified under the Act was Zero Dollars ($0.00). DISCLOSURE OF FEDERAL PARTICIPATION IN PAYMENT OF TERRORISM LOSSES The United States will pay ninety percent (90%) of covered terrorism losses exceeding the applicable surety/insurer deductible. Form F7310 I ACORQM CERTIFICATE OF LIABILITY INSURANCE I DATE (MM/DDIYY) 08/02/04 PRODUCER 1-312-704-0100 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION Arthur J. Gallagher & Co. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR 125 S. Wacker Drive ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. Suite 500 Chicago, IL 60606 INSURERS AFFORDING COVERAGE Stephanie Sims 630-694-5167 INSURED INSURER A National Union Insurance Company Superior Electric Northwest, Inc. INSURER B Zurich American Insurance Company 11711 Northcreek Parkway South, Suite D 103 INSURER C Bothell, WA 98011 INSURER D I INSURER E THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS I~.;;: TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE P~~!fJ EXPIRATION B ~NERAL LIABILITY GL0350396003 02/01/04 02/01/05 ~ ~MMERCIAL GENERAL LIABILITY _ ~ CLAIMS MADE 0 OCCUR COVERAGES EACH OCCURRENCE FIRE DAMAGE (Anyone fire) MED EXP (Anyone person) n'L AGGRE~E LIMIT APnS PER POLICY X P,bW.,: LOC B ~OMOBILE LIABILITY BAP350396103 X ANY AUTO f-- f-- ALL OWNED AUTOS f-- SCHEDULED AUTOS f-- HIRED AUTOS r-- NON-OWNED AUTOS X PD Comp Ded $1,000 X PD Coll Ded $1,000 RRAGE LIABILITY ANY AUTO A EXCESS LIABILITY 5683545 m -OCCUR D CLAIMS MADE R DEDUCTIBLE RETENTION $ B WORKERS COMPENSATION AND WC350395903 EMPLOYERS' LIABILITY PERSONAL & ADV INJURY GENERAL AGGREGATE PRODUCTS - COMP/OP AGG 02/01/04 02/01/05 COMBINED SINGLE LIMIT (Ea accident) BODILY INJURY (Per person) BODILY INJURY (Per aCCIdent) PROPERTY DAMAGE (Per accident) AUTO ONLY - EA ACCIDENT OTHER THAN AUTO ONLY, 02/01/04 02/01/05 EACH OCCURRENCE AGGREGATE 02/01/04 02/01/05 X I 'y'xg~mI,~" I I OJ,tl- E L EACH ACCIDENT E L DISEASE - EA EMPLOYEE E L DISEASE - POLICY LIMIT OTHER LIMITS $1,000,000 $ 300,000 $ 5,000 $ 1,000,000 $ 2,000,000 $ 2,000,000 $1,000,000 $ EA ACC AGG $ $ $ $ 10,000,000 $10,000,000 $ $ $ $1,000,000 $1,000,000 $1,000,000 DESCRIPTION OF OPERATIONSlLOCATIONSNEHICLESJEXCLUSIONS ADDED BY ENDORSEMENT/SPECIAL PROVISIONS City of Port Angeles is shown as an additional insured solely with respect to general liabilty coverage as evidenced herein as required by written contract with respect to work performed by the named insured. PROJECT NAME:Elwha Underground Rebuild - Elwha Line Stage 2, Project No. 02-11B. REVISED CANCELLATON CLAUSE: The Contractor's insurance shall not be cancelled or reduced as to coverage by either party, except after forty-five (45) days prior written notice by certified mail, return receipt requested, has been given to the City. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ~X~'lflJMAIL ~ DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, ~1!I:J[i!IWlSO SHALL XIl41&~U1Q~~~UJlK.mi~ilfI1QlS~~i1tg~Xmc~R ~~~~gXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXX AUTHORIZED REPRESENTATIVE 0tk{~ @ ACORD CORPORATION 1988 CERTIFICATE HOLDER I I ADDITIONAL INSURED,INSURER LETTER CANCELLATION City of Port Angeles 321 E. Fifth P.O. Box 1150 Port Angeles, WA 98362 I ACORD 25-S (7/97) brianchi 2014696 USA Powered By CertiflcatesNow TM .-J I IMPORTANT If the certificate holder IS an ADDITIONAL INSURED, the pollcY(les) must be endorsed. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract between the Issuing Insurer(s), authorized representative or producer, and the certificate holder, nor does It affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ACORD 25-5 (7/97) ~ POLICY NUMBER: GL0350396003 COMMERCIAL GENERAL LIABILITY CG 20 26 11 85 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - DESIGNATED PERSON OR ORGANIZATION TI$ endorseent odifies insrance proided cder te fobwg COMMERCIAL GENERAL LIABILITY COVERAGE PART. SCHEDULE Name of Person or Organization: City of Port Angeles 321 E. Fifth P.O. Box 1150 Port Angeles, WA 98362 USA (If no entry appears abe, inforBtion re~ed to cOpBte tl$ endorseent iM3 sbw in te Decerations as applcae to tl$ endorseent.) WHO IS AN INSURED (Section II) is aended to inclje as an insred te person or or€lniation sbw in te Scede as an Insred bony iitrespect to lallty ar ising:ltJof yoooperations or preises ot'l.ed 9 or rented to you CG 20 26 11 85 Copyrig Insrance Sene es Office, Inc., 9 PART III SPECIAL PROVISIONS SPECIAL PROVISIONS I CHANGES IN WORK The City may, during the progress ofthis project, make changes in, additions to, or subtractions from the construction drawings and specifications as conditions warrant; provided, however, that if the cost to the Contractor shall be materially increased by any such change, the City shall pay the Contractor for the reasonable cost thereof. No claim for additional compensation for any such change will be considered unless the Contractor shall have made a written request therefor to the City prior to the commencement of work in connection with such change. If the cost to the Contractor shall be materially decreased by any such change or subtraction, the City shall deduct an appropriate amount in accordance with an agreement signed by the City and the Contractor. II GUARANTEES The Contractor shall guarantee all materials and equipment furnished and work performed for a period of one (1) year from the date of substantial completion. The Contractor shall warrant and guarantee for a period of one (1) year from the date of substantial completion of the system that the completed system is free from all defects due to faulty materials or workmanship, and Contractor shall promptly make such corrections as may be necessary by reason of such defects including the repairs of any damage to other parts of the system resulting from such defects. The City will give notice of observed defects with reasonable promptness. In the event that the Contractor should fail to make such repairs, adjustments, or other work that may be made necessary by such defects, the City may do so and charge the Contractor the cost thereby incurred. The Performance Bond shall remain in full force and effect through the guarantee period. III PERFORMANCE BOND The Contractor shall provide an executed performance bond for the full contract amount. This performance bond shall: A Be on a City-furnished form; B Be signed by an approved surety (or sureties) that; 1. Is registered with the Washington State Insurance Commissioner, and 2. Appears on the current Authorized Insurance List in the State of Washington published by the Office of the Insurance Commissioner, C Be conditioned upon the faithful performance of the contract by the Contractor within the prescribed time; and D Guarantee that the surety shall indemnify, defend, and protect the City against any claim of direct or indirect loss resulting from the failure: 1. Of the Contractor (or any of the employees, subcontractors, or lower tier subcontractors of the Contractor) to faithfully perform the contract, and 2. Of the Contractor (or the subcontractors or lower tier subcontractors of the Contractor) to pay all laborers, mechanics, subcontractors, lower tier subcontractors, 3-1 material person, or any other person who provides supplies or provisions for carrying out the work. The City may require sureties or surety companies on the contract bond to appear and qualify themselves. Whenever the City deems the surety or sureties to be inadequate, it may, upon written demand, require the Contractor to furnish additional surety to cover any remaining work. Until the added surety is furnished, payments on the contract will stop. IV LIQUIDATED DAMAGES: The City finds it impractical to calculate the actual cost of delays. Therefore, it has adopted the following formula to calculate liquidated damages for failure to complete the physical work of a contract on time. Accordingly, the Contractor agrees: A. To pay (according to the following formula) liquidated damages for each working day beyond the number of working days established for physical completion, and B. To authorize the City to deduct these liquidated damages from any money due or coming to the Contractor. LIQUIDATED DAMAGES FORMULA LD = O.15C/T Where: LD = liquidated damages per working day (rounded to the nearest dollar) C = original contract amount T = original time for physical completion. When the contract work has progressed to the extent that the City has full and unrestricted use and benefit of the transformer, both from the operational and safety standpoint, and only minor incidental work, replacement of temporary substitute facilities, or correction or repair remains to physically complete the total contract, the City may determine the contract work is substantially complete. The City will notify the Contractor in writing of the substantial completion date. For overruns in contract time occurring after the date so established, the formula for liquidated damages shown above will not apply. For overruns in contract time occurring after the substantial completion date, liquidated damages shall be assessed on the basis of direct engineering and related costs assignable to the project until the actual physical completion date of all the contract work. The Contractor shall complete the remaining work as promptly as possible. Upon request by City Representative, the Contractor shall furnish a written schedule for completing the physical work on the contract. Liquidated damages will not be assessed for any days for which an extension of time is granted. No deduction or payment of liquidated damages will, in any degree, release the Contractor from further obligations and liabilities to complete the entire contract. 3-2 V CONTRACTOR DEFAULT If default should be made by the Contractor in the performance of any of the terms of this Contract, the City, without in any manner limiting its legal and equitable remedies in the circumstances, may serve upon the Contractor and the Surety, if any, a written notice requiring the Contractor to cause such default to be corrected forthwith. Unless within twenty (20) days after the service of such notice upon the Contractor and the Surety, if any, such default shall be corrected or arrangements for the correction thereof satisfactory to the City shall be made, the City may take over the Project and prosecute the Contractor, at the expense of the Contractor, for the completion of the Project, and the Contractor and the Surety shall be liable to the City for any cost or expense occasioned thereby. VI TERMINATION OF CONTRACT In the event that the Contractor or any of the subcontractors persistently or repeatedly refuse or fail to supply competent supervision, enough properly skilled workmen, proper materials, or disregard laws, ordinances, or the instructions of the City, or fail to perform the work diligently and in an orderly and workmanlike manner in accordance with the Contract, or violate any provision of the Contract, the City may consider the Contractor in default and serve written notice of intention to terminate the contract upon the Contractor, which notice shall specify the reasons therefor. Unless within five (5) days after serving such notice upon the Contractor such violation shall cease, or an arrangement for the correction thereof satisfactory to the City be made, the Contract shall, upon the expiration of the said five (5) days, terminate and the Surety will become responsible for the performance of the work unless otherwise agreed in writing by the City. The rights and remedies of the City under this Termination Of Contract provision shall be in addition to any other rights and remedies provided by law or under this Contract. ,., ,., j-j ATTACHMENT A WASHINGTON STATE PREVAILING WAGE RATES FOR CLALLAM COUNTY CLALLAM County - Effective: 3/3/2004 -- Page 1 of 8 ~b~~~dtl~~~t~tri~~ , , ' (.0' Get or Renew a License (: G, Electrical (0 Apprenticeship (0 Factory-Built Structures @ Elevators Co Contractors r \0 Plumbers (0 Prevailing Wage 8 About Prevailing Wage EI Prevailing Wage Rates 8 Rates by Trade & County 8 Scopes of Work 8 Rate Surveys I!I Intents and Affidavits 8 Debarred Contractors 8 Advisory Committee 8 Forms & Publications \. FO Boilers \..""'" ... (e Trades & Licensing Rules . .. , , ~ ~ ., "~ - ~- > Topic Index Contact Info I S!!ll.!11,i! Home Safety Claims 8: Insurance Workplace Rights Trades 8: Licensing I ------ ----- -- ___u - - - ---- -- - --- r L Fln~ !_~~9~ ~~e 1 : _~t ,a _Form or p~QJ!c;~~j~!l__i CLALLAM County - Effective: 3/3/2004 J Washington State Prevailing Wage Rates for Public Works Contracts The PREVAILING WAGES listed here include both the hourly wage rate and the hourly rate of fringe benefits. On public works projects, workers' wage and benefit rates must add to not less than this total. A brief description of overtime calculation requirements is provided by clicking on the benefit code. CLALLAM County -- Effective 3/312004 -- Benefit Code Key PrevailingOvertirn eHoliday Note Classification Wage Code Code Code ASBESTOS ABATEMENT WORKERS JOURNEY LEVEL $31.86 IN 5D BOILERMAKERS JOURNEY LEVEL $43.47 1B 5N BRICK AND MARBLE MASONS JOURNEY LEVEL $38.37 1M SA CABINET MAKERS (IN SHOP) JOURNEY LEVEL $14.67 CARPENTERS ACOUSTICAL WORKER $38.06 1M SD BRIDGE, DOCK AND W ARF CARPENTERS $37.90 1M SD CARPENTER $37.90 1M SD ! CREOSOTED MATERIAL $38.00 1M SD DRYWALL APPLICATOR $38.74 1M SD FLOOR FINISHER $38.03 1M SD FLOOR LAYER $38.03 1M SD FLOOR SANDER $38.03 ]M SD MILL WRIGHT AND MACHINE ERECTORS $38.90 1M 5D PILEDRIVERS, DRIVING, PULLING, PLACING $38.10 1M SD COLLARS AND WELOING SA WFlLER $38.03 1M SO SHINGLER $38.03 1M SO STATIONARY POWER SAW OPERATOR $38.03 1M SO STATIONARY WOODWORKING TOOLS $38.03 1M 50 CEMENT MASONS JOURNEY LEVEL $31.86 IN SD DIVERS & TENDERS OIVER $79.57 1M 50 8A DIVER TENDER $40.67 1M 50 DREDGE WORKERS ASSISTANT ENGINEER $38.37 1B SO 8L ASSISTANT MATE (DECKHAND) $37.91 1B SO 8L BOATMEN $38.37 1B 50 8L ENGINEER WELDER $38.42 ]B 50 8L LEVERMAN, HYDRAULIC $39.85 1B SD 8L MAINTENANCE $37.91 IB 5D 8L MATES $38.37 IB SD 8L OlLER $38.02 1B 5D 8L DRYWALL TAPERS JOURNEY LEVEL $38.59 11 SB ELECTRICAL FIXTURE MAINTENANCE WORKERS JOURNEY LEVEL $9.37 ELECTRICIANS - INSIDE CABLE SPLICER $48.51 1D 6H CABLE SPLICER (TUNNEL) $52.31 1D 6H http://www.1ni. wa.gov !Prevailing W age/jwages/20041 /coOS . asp 2/10/04 CLALLAM County - Effective: 3/3/2004 -- Page 2 of8 CERTIFIED WELDER $46.79 10 6H CERTIFIED WELDER (TUNNEL) $50.41 10 6H CONSTRUCTION STOCK PERSON $24.33 10 6H JOURNEY LEVEL $45.06 10 6H JOURNEY LEVEL (TUNNEL) $48.51 10 6H -- ----- - - -- ---------E+.E-C---'f-RI€IANS~_Me'f_eR_sHeP--- ----- ----_.----- CRAFfSMAN $15.37 2A 6C JOURNEY LEVEL $14.69 2A 6C ELECTRICIANS - POWERLINE CONSTRUCTION CABLE SPLICER $48.96 4A 5A CERTIFIED LINE WELDER $44.65 4A 5A GROUNDPERSON $32.13 4A 5A HEAD GROUNDPERSON $33.93 4A 5A HEAVY LINE EQUIPMENT OPERATOR $44.65 4A 5A JACKHAMMER OPERATOR $33.93 4A 5A JOURNEY LEVEL LINEPERSON $44.65 4A 5A LINEEQUIPNrnNTOPERATOR $37.87 4A 5A POLE SPRAYER $44.65 4A 5A POWDERPERSON $33.93 4A 5A ELECTRONIC & TELECOMMUNICATION TECHNICIANS JOURNEY LEVEL $12.07 I ELEVATOR CONSTRUCTORS MECHANIC $49.28 4A 6Q MECHANIC IN CHARGE $54.18 4A 6Q FABRICATED PRECAST CONCRETE PRODUCTS ALL CLASSIFICATIONS $13.50 FENCE ERECTORS FENCE ERECTOR $13.80 FENCE LABORER $11.60 FLAGGERS JOURNEY LEVEL $27.18 IN 5D GLAZIERS JOURNEY LEVEL $38.96 2E 5G HEAT & FROST INSULA TORS AND ASBESTOS WORKERS MECHANIC $39.93 IF 5E HEATING EQUIPMENT MECHANICS MECHANIC $16.00 HOD CARRIERS & MASON TENDERS JOURNEY LEVEL $32.34 IN 5D INDUSTRIAL ENGINE AND MACHINE MECHANICS MECHANIC $15.65 INDUSTRIAL POWER VACUUM CLEANER JOURNEY LEVEL $9.07 INLAND BOATMEN CAPTAIN $33.50 IK 5B COOK $28.96 IK 5B DECKHAND $28.16 IK 5B ENGINEER/DECKHAND $30.61 IK 5B MATE, LAUNCH OPERATOR $32.05 lK 5B INSPECTION/CLEANING/SEALING OF SEWER & WATER SYSTEMS BY REMOTE CONTROL CLEANER OPERATOR, FOAMER OPERATOR $9.73 1 GROUT TRUCK OPERATOR $11.48 1 HEAD OPERATOR $12.78 I TECHNICIAN $7.16 1 TV TRUCK OPERATOR $10.53 1 INSULATION APPLICATORS JOURNEY LEVEL $20.50 IRONWORKERS JOURNEY LEVEL $41.02 IB 5A LABORERS ASPHALT RAKER $32.34 IN 5D BALLAST REGULA TOR MACHINE $31.86 IN 5D BATCH WEIGHMAN $27.18 IN 5D BRUSH CUTTER $31.86 IN 5D BRUSH HOG FEEDER $31.86 IN 5D BURNERS $31.86 IN 5D CARPENTER TENDER $31.86 IN 5D http://www.1ni.wa.gov/PrevailingWage/jwages/20041/co05.asp 2/10/04 CLALLAM County - Effective: 3/3/2004 -- CASSION WORKER CEMENT DUMPERlPA VING CEMENT FINISHER TENDER CHANGE-HOUSE MAN OR DRY SHACKMAN CHIPPING GUN (OVER 30 LBS) -CHIPPING-GUN (UNDER3tltBS} - CHOKER SEITER CHUCK TENDER CLEAN-UP LABORER CONCRETE DUMPER/CHUTE OPERATOR CONCRETE FORM STRIPPER CONCRETE SAW OPERATOR CRUSHER FEEDER CURING LABORER DEMOLITION, WRECKING & MOVING (INCLUDING CHARRED MATERIALS) DITCH DIGGER DIVER DRILL OPERATOR (HYDRAULIC, DIAMOND) DRILL OPERATOR, AIRTRAC DUMPMAN EPOXY TECHNICIAN EROSION CONTROL WORKER F ALLER/BUCKER, CHAIN SAW FINAL DETAIL CLEANUP (i.e., dusting, vacuuming, window cleaning; NOT construction debris cleanup) FINE GRADERS FIRE WATCH FORM SETTER GABION BASKET BUILDER GENERAL LABORER GRADE CHECKER & TRANSIT PERSON GRINDERS GROUT MACHINE TENDER GUARDRAIL ERECTOR HAZARDOUS WASTE WORKER LEVEL A HAZARDOUS WASTE WORKER LEVEL B HAZARDOUS WASTE WORKER LEVEL C HIGH SCALER HOD CARRIER/MORT ARMAN JACKHAMMER LASER BEAM OPERATOR MANHOLE BUILDER-MUDMAN MATERIAL YARDMAN MINER NOZZLEMAN, CONCRETE PUMP, GREEN CUTrER WHEN USING HIGH PRESSURE AIR & WATER ON CONCRETE & ROCK, SANDBLAST, GUNITE, SHOTCRETE, WATER BLASTER PAVEMENT BREAKER PILOT CAR PIPE POT TENDER PIPE RELINER (NOT INSERT TYPE) PIPELA YER & CAULKER PIPELA YER & CAULKER (LE AD) PIPEWRAPPER POT TENDER POWDERMAN POWDERMAN HELPER POWERJACKS RAILROAD SPIKE PULLER (POWER) RE-TIMBERMAN RlPRAP MAN RODDER SCAFFOLD ERECTOR SCALE PERSON http://www.lni. wa.gov !Prevailing W age/jwages/20041 I coOS .asp Page 3 of8 $32.70 IN 5D $32.34 IN 5D $31.86 IN 5D $31.86 IN 5D $32.34 IN 5D - --sn-:86 -- 1N ---SD------ - . $31.86 IN 5D $31.86 IN 5D $31.86 IN 5D $32.34 IN 5D $31.86 IN 5D $32.34 IN 5D $27.18 IN 5D $31.86 IN 5D $31.86 IN 5D $31.86 IN 5D $32.70 IN 5D $32.34 IN 5D $32.70 IN 5D $31.86 IN 5D $31.86 IN 5D $31.86 IN 5D $32.34 IN 5D $24.86 IN 5D $31.86 IN 5D $27.18 IN 5D $31.86 IN 5D $31.86 IN 5D $31.86 IN 5D $32.34 IN 5D $31.86 IN 5D I $31.86 IN 5D ! $31.86 IN 5D I $32.70 IN 5D $32.34 IN 5D $31.86 IN 5D $32.70 IN 5D $32.34 IN 5D $32.34 IN 5D $32.34 IN 5D $32.34 IN 5D $31.86 IN 5D $32.70 IN 5D $32.34 IN 5D $32.34 IN 5D $27.18 IN 5D $32.34 IN 5D $32.34 IN 5D $32.34 IN 5D $32.70 IN 5D $32.34 IN 5D $31.86 IN 5D $32.70 IN 5D $31.86 IN 5D $32.34 IN 5D $32.34 IN 5D $32.70 IN 5D $31.86 IN 5D $32.34 IN 5D $31.86 IN 5D $31.86 IN 5D 2/10/04 CLALLAM County - Effective: 3/3/2004 -- Page 4 of8 SIGNALMAN $31.86 IN 50 SLOPER (OVER 20") $32.34 IN 5D SLOPER SPRA YMAN $31.86 IN 50 SPREADER (CLARY POWER OR SIMILAR $32.34 IN 50 TYPES) -SPREADER (CONCRETE) --- ---sn~4 iN --------51) ST AK.E HOPPER $31.86 IN 50 STOCKPILER $31.86 IN 50 TAMPER & SIMILAR ELECTRIC, AIR & GAS $32.34 IN 50 TAMPER (MULTIPLE & SELF PROPELLED) $32.34 IN 50 TOOLROOM MAN (AT JOB SITE) $31.86 IN 50 TOPPER-TAILER $31.86 IN 50 TRACK LABORER $31.86 IN 50 TRACK LINER (POWER) $32.34 IN 50 TRUCK SPOTTER $31.86 IN 50 TUGGER OPERATOR $32.34 IN 50 VIBRATING SCREED (AIR, GAS, OR $31.86 IN 50 ELECTRIC) VIBRATOR $32.34 IN 50 VINYLSEAMER $31.86 IN 50 WELOER $31.86 IN 50 WELL-POINT LABORER $32.34 IN 50 LABORERS - UNDERGROUND SEWER & WATER GENERAL LABORER $31.86 IN 50 PIPE LAYER $32.34 IN 50 LANDSCAPE CONSTRUCTION IRRIGATION OR LAWN SPRINKLER $11.42 INSTALLERS LANOSCAPE EQUIPMENT OPERATORS OR $7.81 TRUCK ORIVERS LANOSCAPING OR PLANTING LABORERS $7.93 LATHERS JOURNEY LEVEL $38.74 1M 50 MACHINISTS (HYDROELECTRIC SITE WORK) MACHINIST $16.84 METAL FABRICATION (IN SHOP) FITTERlWELDER $15.16 LABORER $11.13 MACHINE OPERATOR $10.66 PAINTER $11.41 PAINTERS JOURNEY LEVEL $30.77 2B SA PLASTERERS JOURNEY LEVEL $25.83 PLA YGROUND & PARK EQUIPMENT INSTALLERS JOURNEY LEVEL $7.93 PLUMBERS & PIPEFITTERS JOURNEY LEVEL $48.71 IG SA POWER EQUIPMENT OPERA TORS ASSIST ANT ENGINEERS $36.41 IT 5D 8L BACKHOE, EXCA V A TOR, SHOVEL (3 YO & $39.03 IT 50 8L UNDER) BACKHOE, EXCAVATOR, SHOVEL (OVER 3 $39.49 IT 5D 8L YO & UNDER 6 YO) BACKHOE, EXCAVATOR, SHOVEL (6 YO $40.01 IT 50 8L AND OVER WITH A IT ACHMENTS) BACKHOES, (75 HP & UNOER) $38.64 IT 5D 8L BACKHOES, (OVER 75 HP) $39.03 IT 5D 8L BARRIER MACHINE (ZIPPER) $39.03 IT 50 8L BATCH PLANT OPERATOR, CONCRETE $39.03 IT 50 8L BELT LOADERS (ELEVATING TYPE) $38.64 IT 50 8L BOBCAT $36.41 IT 50 8L BROOMS $36.41 IT 5D 8L BUMP CUTTER $39.03 IT 50 8L CABLEW A YS $39.49 IT 50 8L CHIPPER $39.03 IT 50 8L COMPRESSORS $36.41 IT 50 8L CONCRETE FINISH MACHINE - LASER $36.41 IT 50 8L http://www.1ni.wa.gov/PrevailingWage/jwages/20041/co05.asp 2/10/04 CLALLAM County - Effective: 3/3/2004 -- Page 5 of8 SCREED CONCRETE PUMPS $38.64 IT 5D 8L CONCRETE PUMP-TRUCK MOUNT WITH $39.03 IT 5D 8L BOOM ATTACHMENT CONVEYORS $38.64 IT 5D 8L ---------eR1\NES, THRU 19 TONS;WIm-- ---- ----S38~64 -H- -jf}----8t---- ATTACHMENTS CRANES, 20 - 44 TONS, WITH $39.03 IT 5D 8L ATTACHMENTS CRANES, 45 TONS - 99 TONS, UNDER 150 Ff $39.49 IT 5D 8L OF BOOM (INCLUDING Jm WITH ATACHMENTS) CRANES, 100 TONS - 199 TONS, OR 150 Ff OF $40.01 IT 5D 8L BOOM (INCLUDING JIB WITH ATTACHMENTS) CRANES, 200 TONS TO 300 TONS, OR 250 Ff $40.55 IT 5D 8L OF BOOM (INCLUDING JIB WITH ATTACHMENTS) CRANES, A-FRAME, 10 TON AND UNDER $36.41 IT 5D 8L CRANES, A-FRAME, OVER 10 TON $38.64 IT 5D 8L CRANES, OVER 300 TONS, OR 300' OF BOOM $41.07 IT 5D 8L INCLUDING JIB WITH ATTACHMENTS CRANES, OVERHEAD, BRIDGE TYPE ( 20 - 44 $39.03 IT 5D 8L TONS) CRANES, OVERHEAD, BRIDGE TYPE ( 45 - 99 $39.49 IT 5D 8L TONS) CRANES, OVERHEAD, BRIDGE TYPE (100 $40.01 IT 5D 8L TONS & OVER) CRANES, TOWER CRANE UP TO 175'IN $40.01 IT 5D 8L HEIGHT, BASE TO BOOM CRANES, TOWER CRANE OVER 175' IN $40.55 IT 5D 8L HEIGHT, BASE TO BOOM CRUSHERS $39.03 IT 5D 8L DECK ENGINEERlDECK WINCHES (POWER) $39.03 IT 5D I 8L DERRICK, BUILDING $39.49 IT 5D ! 8L DOZERS, D-9 & UNDER $38.64 IT 5D 8L DRILL OILERS - AUGER TYPE, TRUCK OR $38.64 IT 5D 8L CRANE MOUNT DRILLING MACHINE $39.03 IT 5D 8L ELEVATOR AND MANLIFT, PERMANENT $36.41 IT 5D 8L AND SHAFf-TYPE EQUIPMENT SERVICE ENGINEER (OILER) $38.64 IT 5D 8L FINISHING MACHINE/BIDWELL GAMACO $39.03 IT 5D 8L AND SIMILAR EQUIP FORK LIFTS, (3000 LBS AND OVER) $38.64 IT 5D 8L FORK LIFTS, (UNDER 3000 LBS) $36.41 IT 5D 8L GRADE ENGINEER $38.64 IT 5D 8L GRADECHECKER AND ST AKEMAN $36.41 IT 5D 8L GUARDRAIL PUNCH $39.03 IT 5D 8L HOISTS, OUTSIDE (ELEVATORS AND $38.64 IT 5D 8L MANLlFTS), AIR TUGGERS HORlZONTALIDIRECTIONAL DRILL $38.64 IT 5D 8L LOCATOR HORlZONTALIDIRECTIONAL DRILL $39.03 IT 5D 8L OPERATOR HYDRALIFTS/BOOM TRUCKS (10 TON & $36.41 IT 5D 8L UNDER) HYDRALIFTS/BOOM TRUCKS (OVER 10 $38.64 IT 5D 8L TON) LOADERS, OVERHEAD (6 YD UP TO 8 YD) $39.49 IT 5D 8L LOADERS, OVERHEAD (8 YD & OVER) $40.01 IT 5D 8L LOADERS, OVERHEAD (UNDER 6 YD), $39.03 IT 5D 8L PLANT FEED LOCOMOTIVES, ALL $39.03 IT 5D 8L MECHANICS, ALL $39.49 IT 5D 8L MIXERS, ASPHALT PLANT $39.03 IT 5D 8L MOTOR PATROL GRADER (FINISHING) $39.03 IT 5D 8L MOTOR PATROL GRADER (NON-FINISHING) $38.64 IT 5D 8L http://www.lni. wa.gov/Prevailing W age/jwages/20041/co05.asp 2/10/04 MUCKING MACHINE, MOLE, TUNNEL DRILL $39.49 IT AND/OR SHIELD OIL DISTRIBUTORS, BLOWER DISTRIBUTION AND MULCH SEEDING OPERATOR -----PAV-EMENf BREAKER --- --- ---------$36.41 PILEDRIVER (OTHER THAN CRANE MOUND . $39.03 PLANT OILER (ASPHALT, CRUSHER) $38.64 POSTHOLE DIGGER, MECHANICAL $36.41 POWER PLANT $36.41 PUMPS, WATER $36.41 QUAD 9, D-IO, AND HD-41 $39.49 REMOTE CONTROL OPERATOR ON RUBBER $39.49 TIRED EARTH MOVING EQUIP RIGGER AND BELLMAN ROLLAGON ROLLER, OTHER THAN PLANT ROAD MIX ROLLERS, PLANTMIX OR MUL TILIFT MATERIALS ROTO-MILL, ROTO-GRINDER SAWS, CONCRETE SCRAPERS - SELF PROPELLED, HARD TAIL END DUMP, ARTICULATING OFF-ROAD EQUIPMENT ( UNDER 45 YD) SCRAPERS - SELF PROPELLED, HARD TAIL END DUMP, ARTICULATING OFF-ROAD EQUIPMENT (45 YD AND OVER) SCRAPERS, CONCRETE AND CARRY ALL SCREED MAN SHOTCRETE GUNITE SLlPFORM PAVERS SPREADER, TOPSIDE OPERATOR - BLA W KNOX SUBGRADE TRIMMER TOWER BUCKET ELEVATORS TRACTORS, (75 HP & UNDER) TRACTORS, (OVER 75 HP) TRANSFER MATERIAL SERVICE MACHINE TRANSPORTERS, ALL TRACK OR TRUCK TYPE TRENCHING MACHINES TRUCK CRANE OILERlDRlVER (UNDER 100 TON) TRUCK CRANE OILERlDRlVER (100 TON & OVER) TRUCK MOUNT PORTABLE CONVEYER $39.03 IT 5D 8L WHEEL TRACTORS, FARMALL TYPE $36.41 IT 5D 8L YO YO PAY DOZER $39.03 IT 5D 8L POWER EQUIPMENT OPERA TORS- UNDERGROUND SEWER & WATER (SEE POWER EQUIPMENT OPERATORS) $0.00 POWER LINE CLEARANCE TREE TRIMMERS JOURNEY LEVEL IN CHARGE $32.01 4A SPRAY PERSON $30.29 4A TREE EQUIPMENT OPERATOR $30.71 4A TREE TRIMMER $28.43 4A TREE TRIMMER GROUNDPERSON $20.89 4A REFRIGERATION & AIR CONDITIONING MECHANICS MECHANIC $27.68 RESIDENTIAL BRICK & MARBLE MASONS JOURNEY LEVEL RESIDENTIAL CARPENTERS JOURNEY LEVEL RESIDENTIAL CEMENT MASONS JOURNEY LEVEL RESIDENTIAL DRYWALL TAPERS JOURNEY LEVEL RESIDENTIAL ELECTRICIANS JOURNEY LEVEL CLALLAM County - Effective: 3/3/2004 -- httn~ / fwww.lni.wa.QovlPrevailineWaee/iwaees/20041/co05.asp $36.41 $36.41 $39.49 $36.41 $38.64 $39.03 $38.64 $39.03 $39.49 $38.64 $39.03 $36.41 $39.49 $39.03 $39.03 $38.64 $38.64 $39.03 $39.03 $39.49 $38.64 $38.64 $39.03 $38.37 $17.85 $25.63 $18.00 $27.78 IT Page 6 of8 5D 8L 5D 8L - iT ----5fl---8I::.- -- - - -- IT 5D 8L IT 5D 8L IT 5D 8L IT 5D 8L IT 5D 8L IT 5D 8L IT 5D 8L IT IT IT IT IT IT IT IT IT IT IT IT IT IT IT IT IT IT IT IT IT IT 1M 5D 5D 5D 5D 8L 8L 8L 8L 5D 5D 5D 8L 8L 8L 5D 8L 5D 5D 5D 5D 5D 8L 8L 8L 8L 8L 5D 5D 5D 5D 5D 5D 8L 8L 8L 8L 8L 8L 5D 5D 8L 8L 5D 8L 5A 5A 5A 5A 5A 5A 2/1 0/04 RESIDENTIAL GLAZIERS JOURNEY LEVEL RESIDENTIAL INSULATION APPLICATORS JOURNEY LEVEL RESIDENTIAL LABORERS - -- - -----JOURNEY LEVEL RESIDENTIAL PAINTERS JOURNEY LEVEL RESIDENTIAL PLUMBERS & PIPEFITTERS JOURNEY LEVEL $14.60 1 RESIDENTIAL REFRIGERATION & AIR CONDITIONING MECHANICS JOURNEY LEVEL $46.46 1 G 5A RESIDENTIAL SHEET METAL WORKERS JOURNEY LEVEL (FIELD OR SHOP) RESIDENTIAL SOFf FLOOR LAYERS JOURNEY LEVEL $10.88 1 RESIDENTIAL SPRINKLER FITTERS (FIRE PROTECTION) JOURNEY LEVEL $19.67 1 ROOFERS JOURNEY LEVEL USING IRRlT ABLE BITUMINOUS MATERIALS SHEET METAL WORKERS JOURNEY LEVEL (FIELD OR SHOP) $45.43 IJ SIGN MAKERS & INSTALLERS (ELECTRICAL) JOURNEY LEVEL $19.29 SIGN MAKERS & INSTALLERS (NON-ELECTRICAL) JOURNEY LEVEL $12.15 SOFf FLOOR LAYERS JOURNEY LEVEL SOLAR CONTROLS FOR WINDOWS JOURNEY LEVEL SPRINKLER FITTERS (FIRE PROTECTION) JOURNEY LEVEL $19.67 STAGE RIGGING MECHANICS (NON STRUCTURAL) JOURNEY LEVEL $13.23 SURVEYORS CHAIN PERSON $9.35 1 INSTRUMENT PERSON $11.40 1 PARTY CHIEF $13.40 1 TELEPHONE LINE CONSTRUCTION - OUTSIDE CABLE SPLICER $27.84 HOLE DIGGERlGROUND PERSON $15.69 INSTALLER (REPAIRER) $26.70 JOURNEY LEVEL TELEPHONE LINEPERSON $25.91 SPECIAL APPARATUS INSTALLER I $27.84 SPECIAL APPARATUS INSTALLER II $27.28 TELEPHONE EQUIPMENT OPERATOR $27.84 (HEAVY) TELEPHONE EQUIPMENT OPERATOR (LIGHT) TELEVISION GROUND PERSON TELEVISION LINEPERSON/INST ALLER TELEVISION SYSTEM TECHNICIAN TELEVISION TECHNICIAN TREE TRIMMER TERRAZZO WORKERS & TILE SETTERS JOURNEY LEVEL TILE, MARBLE & TERRAZZO FINISHERS FINISHER TRAFFIC CONTROL STRIPERS JOURNEY LEVEL TRUCK DRIVERS ASPHALT MIX (TO 16 YARDS) ASPHALT MIX (OVER 16 YARDS) DUMP TRUCK DUMP TRUCK & TRAILER OTHER TRUCKS CLALLAM County - Effective: 3/3/2004 -- http://www .lni. wa.gov/Prevailing W age/jwages/20041 1 coOS . asp $16.84 $9.86 - $lS;OS--t- $15.97 $30.75 IJ $34.53 $37.53 lR lR $31.52 1B $10.31 IB 2B 2B 2B 2B 2B 2B 2B $25.91 $14.89 $19.81 $23.43 $21.11 $25.91 $35.63 $29.46 $30.40 $35.91 $36.49 $20.23 $20.23 $36.49 6L 5A 5A 6L 5A 50 5A 5A 5A 5A 5A 5A 5A 2B 2B 2B 2B 2B 2B IH 1H lK IT IT 1 1 IT Page 7 of8 5A SA 5A SA 5A SA 5A SA SA 5D 5D 8L 8L 5D 8L 2/1 0104 CLALLAM County - Effective: 3/3/2004 -- Page 8 of 8 ~Tii~""lJ t" '~t.jr. '~I~. mNim'II~'l TRANSIT MIXER $23.73 WELL DRILLERS & IRRIGATION PUMP INSTALLERS IRRIGATION PUMP INSTALLER $11.60 1 OILER $9.45 1 WELL DRILLER $11.60 1 About L&I I Find a job at L&I I Informacion en espanol I Site Feedback I 1-800-547-8367 Q Washington ~tate Dept of Labor and Industnes. Use of this SIte Is subject to the laws of the state of Washington. Access Agreement I Pnvacy and 5eCurlty statement I Intended use lextemal content polley I Staff only link httn:llwww .lni. wa.gOv/Prevailing W age/jwages/20041 1 co05 . asp ..... Visit access.wa.!lOV 2/1 0104 CLALLAM County - Effective: 3/3/2004 -- Page 1 of6 ~b~~~dtl~d;;tri~~ --'-' (0 Get or Renew a License (' +), Electrical (0 Apprenticeship (O~ Factory-Built Structures CO: Elevators (0 < Contractors C!. Plumbers (0 Prevailing Wage I::] About Prevailing Wage B Prevailing Wage Rates I::] Rates by Trade & County I::] Scopes of Work I::] Rate Surveys I!I Intents and Affidavits I::] Debarred Contractors I::] Advisory Committee I::] Forms & Publications 1... (0) Boilers (0 Trades & Licensing Rules . ~ ~ ,,~, ~~ Topic Index Contact Info I ( -J , ~!!ar~ Home Safety Claims & Insurance Workplace RlsMs Trades a LicensinS ( LEt~~L~ ~W.~! Rl1~~ j : ~t ~ F~J:m ~r 1'11PJt~~tiqI}J CLALLAM County - Effective: 3/312004 J Washington State Prevailing Wage Rates for Public Works Contracts The PREVAILING WAGES listed here include both the hourly wage rate and the hourly rate of fringe benefits. On public works projects, workers' wage and benefit rates must add to not less than this total. A brief description of overtime calculation requirements is provided by clicking on the benefit code. Any apprentice not registered with the Washington State Apprenticeship and Training Council must be paid prevailing journey level wages. To verify apprentice registration, call (360) 902- 5324. CLALLAM County -- Apprentices -- Effective 3/312004 -- Benefit Code Key Prevailing Overtime Holiday Note Stage of Progression & Hour Range Wage Code Code Code ASBESTOS ABA TEMENT WORKERS ENVIRONMENTAL CONTROL PAINTERS 1: 0 - 1000 Hours - 50.00010 $17.11 IN 5D 2: 1001 - 2000 Hours - 60.00010 $19.58 IN 5D 3: 2001 - 3000 Hours - 75.00% $25.08 IN 5D 4: 3001 - 4000 Hours - 90.00010 $29.15 IN 5D LABORERS 1: 0 - 1000 Hours - 60.00% $21.98 IN 5D , 2: 1001 - 2000 Hours -70.00% $24.45 IN 5D 3: 2001 - 3000 Hours - 80.00% $26.92 IN 5D 4: 3001 - 4000 Hours - 90.00% $29.39 IN 5D BOILERMAKERS 1: 0 - 1000 Hours - 70.00% $35.04 IB 5N 2: 1001 - 2000 Hours -75.00% $36.45 1B 5N 3: 2001 - 3000 Hours - 80.00010 $37.85 IB 5N 4: 3001 - 4000 Hours - 85.00% $39.26 IB 5N 5: 4001 - 5000 Hours - 90.00% $40.66 IB 5N 6: 5001 - 6000 Hours - 95.00% $42.07 IB 5N BRICK AND MARBLE MASONS 1: 0 - 750 Hours - 50.00% $22.40 1M 5A 2: 751 - 2250 Hours - 55.00% $23.90 1M 5A 3: 2251 - 3000 Hours - 60.00010 $25.36 1M 5A 4: 3001 - 3750 Hours - 70.00% $28.27 1M 5A 5: 3751 - 4500 Hours - 80.00% $31.19 1M 5A 6: 4501 - 5250 Hours - 90.00% $34.10 1M 5A 7: 5251 - 6000 Hours - 95.00% $35.56 1M 5A CARPENTERS ACOUSTICAL WORKER I: 0 - 1000 Hours - 50.00% $19.91 1M 5D 2: 1001 - 2000 Hours - 60.00% $26.64 1M 5D 3: 2001 - 3000 Hours - 68.00% $28.92 1M 5D 4: 3001 - 4000 Hours - 76.00% $31.21 1M 5D 5: 4001 - 5000 Hours - 84.00% $33.49 1M 5D 6: 5001 - 6000 Hours - 92.00% $35.78 1M 5D BRIDGE, DOCK AND W ARF CARPENTERS 1: 1st Period - 60.00% $22.67 1M 5D 2: 2nd Period - 65.00% $27.96 1M 5D 3: 3rd Period - 70.00% $29.38 1M 5D 4: 4th Period - 75.00% $30.80 1M 5D 5: 5th Period - 80.00% $32.22 1M 5D 6: 6th Period - 85.00% $33.64 1M 5D ht+n./lurUTUT In; Wll O"ovIPrevHilinQWaQe/AnnwaQes/20041/co05.asp 2/10/04 CLALLAM County - Effective: 3/3/2004 -- Page 2 of6 7: ']tit Period - 90.00010 $3S.06 1M SD 8: 8th Period - 9S.0oolo $36.48 1M SD CARPENTER 1: I st Period - 60.00010 $22.67 1M SD 2: 2nd Period - 6S.0oolo $27.96 1M SD --<---- - 3:- jra-Period ~ 70.00% ---$2"938 - 1M ----so-..---. _______u_ . . ~- - - - -- 4: 4th Period - 7S.00% $30.80 1M SD S: Sth Period - 80.00010 $32.22 1M SD 6: 6th Period - 8S.00% $33.64 1M SD 7: 7th Period - 90.00% $3S.06 1M SD 8: 8th Period - 9S.00% $36.48 1M 5D DRYWALL APPLICATOR DRYWALL. METAL STUD. AND CEILING APPLICATORS 1: 0 - 700 Hours - SO.OO% $20.33 1M SD 2: 701 - 1400 Hours - 60.00% $27. II 1M SD 3: 1401 - 2100 Hours - 68.00% $29.43 1M SD 4: 2101 - 2800 Hours - 76.00010 $31. 76 1M SD S: 2801 - 3S00 Hours - 84.00% $34.09 1M SD 6: 3S01 - 4200 Hours - 92.00% $36.41 1M SD MILLWRIGHT AND MACHINE ERECTORS I: 1st Period - 60.00% $23.27 1M SD 2: 2nd Period - 6S.00% $28.61 1M SD 3: 3rd Period - 70.00% $30.08 1M SD 4: 4th Period - 7S.00% $3I.SS 1M SD S: Sth Period - 80.00% $33.02 1M SD 6: 6th Period - 8S.00% $34.49 1M SD 7: ']tit Period - 90.00% $3S.96 1M SD 8: 8th Period - 9S.00% $37.43 1M SD PILEDRIVERS, DRIVING, PULLING, PLACING COLLARS AND WELDING I: 1st Period - 60.00% $22.79 1M SD 2: 2nd Period - 6S.00% $28.09 1M SD I 3: 3rd Period - 70.00% $29.52 1M SD ! 4: 4th Period - 7S.00% $30.9S 1M SD S: Sth Period - 80.00% $32.38 1M SD 6: 6th Period - 8S.00% $33.81 1M SD 7: ']tit Period - 90.00% $3S.24 1M SD 8: 8th Period - 9S.00% $36.67 1M SD CEMENT MASONS I: 0 - 1000 Hours - SO.OO% $12.36 IN SD 2: 1001 - 2000 Hours - 60.00% $14.83 IN SD 3: 2001 - 3000 Hours - 70.00% $17.30 IN SD 4: 3001 - 4000 Hours - 80.00010 $19.77 IN SD S: 4001 - SOOO Hours - 90.00% $22.24 IN SD 6: SOOI - 6000 Hours - 9S.000/0 $23.47 IN SD DRYWALL TAPERS 1: 0 - 1000 Hours - SO.OO% $24.98 lJ SB 2: 1001 - 2000 Hours - SS.Oo% $26.34 1J SB 3: 2001 - 3000 Hours - 6S.00% $29.06 lJ SB 4: 3001 - 4000 Hours - 7S.00% $31. 79 lJ SB S: 4001 - SOOO Hours - 85.000/0 $34.51 lJ SB 6: SOOI - 6000 Hours - 90.00% $3S.87 1J SB ELECTRICIANS - INSIDE 1: 0 - 1000 Hours - 40.00% $18.SS 10 6H 2: 1001 - 2000 Hours - SO.OO% $22.00 10 6H 3: 2001 - 3S00 Hours - S5.00% $26.92 10 6H 4: 3501 - 5000 Hours - 65.00% $30.95 10 6H S: SOOI - 6S00 Hours - 75.00% $34.98 10 6H 6: 6501 - 8000 Hours - 85.00% $39.01 10 6H ELECTRICIANS - POWERLINE CONSTRUCTION JOURNEY LEVEL LINEPERSON I: 0.1000 Hours - 60.00% $28.54 4A SA 2: 1001 - 2000 Hours - 65.00% $30.33 4A SA 3: 2001 - 3000 Hours -71.00% $32.49 4A 5A 4: 3001 - 4000 Hours - 81.00% $36.07 4A SA S: 4001 - SOOO Hours - 85.00% $37.S2 4A SA http://www.lni.wa.govlPrevailing W agel Appwages/200411co05 . asp 2/10/04 6: 5001 - 6000 Hours - 89.00% 7: 6001 - 7000 Hours - 93.00% POLE SPRAYER 1: 0 -1000 Hours - 85.70010 $37.78 4A 2: 1001 - 2000 Hours - 89.80% $39.23 4A 3: 2001 - 3000-Hours - 92.80%-- --- ----$40.3.1--- - AA ELECTRONIC & TELECOMMUNICATION TECHNICIANS 1: 0 - 1000 Hours - 55.00% $7.16 1 2: 1001 - 2000 Hours - 60.00% $7.24 1 3: 2001 - 3000 Hours - 65.00% $7.85 1 4: 3001 - 4000 Hours - 70.00% $8.45 1 5: 4001 - 5000 Hours - 75.00% $9.05 1 6: 5001 - 6000 Hours - 80.00% $9.66 1 7: 6001 - 7000 Hours - 85.00% $10.26 1 8: 7001 - 8000 Hours - 95.00% $11.47 1 ELEVATOR CONSTRUCTORS MECHANIC 1: 1 st Period - 50.00010 2: 2nd Period - 55.00% 3: 3rd Period - 65.00% 4: 4th Period - 70.00% 5: 5th Period - 80.00010 FLAGGERS 1: 0 - 1000 Hours - 60.00% 2: 1001 - 2000 Hours - 70.00% 3: 2001 - 3000 Hours - 80.00% 4: 3001 - 4000 Hours - 90.00% GLAZIERS 1: 0 -1000 Hours - 45.00% $21.09 2E 2: 1001 - 2000 Hours - 50.00% $22.71 2E 3: 2001 - 3000 Hours - 55.00% $24.34 2E 4: 3001 - 4000 Hours - 60.00% $25.96 2E 5: 4001 - 5000 Hours - 65.00010 $27.59 2E 6: 5001 - 6000 Hours -70.00% $29.21 2E 7: 6001 - 7000 Hours - 80.00% $32.46 2E 8: 7001 - 8000 Hours - 90.00% $35.71 2E HEAT & FROST INSULA TORS AND ASBESTOS WORKERS MECHANIC 1: 0 -1000 Hours - 50.00% 2: 1001 - 2000 Hours - 55.00% 3: 2001 - 4000 Hours - 65.00% 4: 4001 - 6000 Hours - 75.00% 5: 6001 - 8000 Hours - 85.00% HOD CARRIERS & MASON TENDERS 1: 0 - 1000 Hours - 60.000/0 2: 1001 - 2000 Hours - 70.00% 3: 2001 - 3000 Hours - 80.00% 4: 3001 - 4000 Hours - 90.00% INSULATION APPLICATORS 1: 0 - 1000 Hours - 50.00% 2: 1001 - 2000 Hours - 60.00% 3: 2001 - 3000 Hours - 75.00% 4: 3001 - 4000 Hours - 90.00% IRONWORKERS 1: IstPeriod-65.00% 2: 2nd Period - 70.00% 3: 3rd Period - 75.00% 4: 4th Period - 80.00% 5: 5th Period - 90.00% 6: 6th Period - 90.00% 7: ?tit Period - 95.00010 8: 8th Period - 95.00% LABORERS 1: 0 - 1000 Hours - 60.00% 2: 1001 - 2000 Hours -70.00% 3: 2001 - 3000 Hours - 80.000/0 CLALLAM County - Effective: 3/3/2004 -- http://www.lni.wa.gov/PrevailingWage/Appwages/20041/co05.asp $38.95 $40.38 $17.67 $32.66 $36.20 $37.96 $41.50 $21.98 $24.45 $26.92 $27.18 $24.85 $26.36 $29.37 $32.39 $35.41 $21.98 $24.45 $26.92 $29.39 $10.25 $12.30 $15.38 $18.45 $24.02 $25.45 $33.88 $35.31 $38.16 $38.16 $39.59 $39.59 $21. 98 $24.45 $26.92 4A 4A 4A 4A 4A 4A 4A IN IN IN IN IF IF IF IF IF IN IN IN IN 1B IB 1B 1B IB 1B IB 1B IN IN IN 5A 5A' 5A 5A -_-5A..----___ -- 6Q 6Q 6Q 6Q 6Q 5D 5D 5D 5D 5G 5G 5G 5G 5G 5G 5G 5G 5E 5E 5E 5E 5E 5D 5D 5D SD 1 1 1 1 5A 5A 5A 5A 5A 5A 5A SA 5D 5D 5D Page 3 of6 2/10/04 4: 3001 - 4000 Hours - 90.00% $29.39 IN LABORERS - UNDERGROUND SEWER & WATER 1: 0 - 1000 Hours - 60.0oolo $21.98 2: 1001 - 2000 Hours - 70.0oolo $24.45 3: 2001 - 3000 Hours - 80.00% $26.92 _________--4; 3001--~AOOOHours - 90.00"A------- _ --- - __.---$29.39- LATHERS 1: 0 - 700 Hours - 50.00% 2: 701 - 1400 Hours - 60.00% 3: 1401 - 2100 Hours - 68.0oolo 4: 2101 - 2800 Hours - 76.00% 5: 2801 - 3500 Hours - 84.00% 6: 3501 - 4200 Hours - 92.00% PAINTERS 1: 0 -750 Hours - 55.00% 2: 751 - 1500 Hours - 65.00% 3: 1501 - 2250 Hours - 75.00% 4: 2251 - 3000 Hours - 80.0oolo 5: 3001 - 3750 Hours - 85.0oolo 6: 3751 - 4500 Hours - 95.00% PLASTERERS 1: 0 - 500 Hours. 40.00% 2: 501 - 1000 Hours - 45.00% 3: 1001 - 1500 Hours - 45.00% 4: 1501 - 2000 Hours - 50.00% 5: 2001 - 2500 Hours - 55.0oolo 6: 2501 - 3000 Hours - 60.0oolo 7: 3001 - 3500 Hours - 65.0oo/o 8: 3501 - 4000 Hours - 70.00% 9: 4001 - 4500 Hours - 75.00% 10: 4501 - 5000 Hours - 80.00% 11: 5001- 5500 Hours - 85.00% 12: 5501 - 6000 Hours - 90.00% 13: 6001 - 6500 Hours - 95.0oolo 14: 6501 -7000 Hours - 95.00% PLUMBERS & PIPEFITTERS 1: 0 - 2000 Hours - 50.00% 2: 2001 - 4000 Hours - 62.50% 3: 4001 - 6000 Hours - 70.0oolo 4: 6001 - 8000 Hours - 75.00% 5: 8001 - 10000 Hours - 85.00% POWER EQUIPMENT OPERA TORS ALL EQUIPMENT 1: 0 . 1000 Hours - 65.00% $28.41 IT 5D 8L 2: 1001 - 2000 Hours -70.0oolo $29.87 IT 5D 8L 3: 2001 - 3000 Hours - 75.0oolo $31.33 IT 5D 8L 4: 3001 - 4000 Hours - 80.0oo/o $32.79 IT 5D 8L 5: 4001 - 5000 Hours - 90.0oo/o $35.72 IT 5D 8L 6: 5001 - 6000 Hours - 95.00% $37.18 IT 5D 8L POWER EQUIPMENT OPERATORS- UNDERGROUND SEWER & WATER (SEE POWER EQUIPMENT OPERA TORS) 1: 0 - 1000 Hours - 65.00% $28.22 2: 1001 - 2000 Hours -70.00% $29.67 3: 2001 - 3000 Hours -75.00% $31.12 4: 3001 - 4000 Hours - 80.0()% $32.57 5: 4001 - 5000 Hours - 90.00% $35.46 6: 5001 - 6000 Hours - 95.00% $36.91 POWER LINE CLEARANCE TREE TRIMMERS TREE TRIMMER 1: 0 -1000 Hours - 65.0oo/o $19.74 4A 2: 1001 - 2000 Hours -75.00% $21.99 4A 3: 2001 - 3000 Hours - 80.00% $23.10 4A 4: 3001 - 4000 Hours - 90.00% $25.36 4A REFRIGERA TlON & AIR CONDITIONING MECHANICS MECHANIC 1: 0 - 2000 Hours - 50.00% 2: 2001 - 4000 Hours - 55.00% 3: 4001 - 6000 Hours - 60.00% CLALLAM County - Effective: 3/3/2004 -- Page 4 of6 5D, IN 5D IN 5D IN 5D __..1N-------51L---- _ _ _ _ __ -- - n - $20.33 $27.11 $29.43 $31.76 $34.09 $36.41 $15.97 $17.02 $18.90 $20.61 $21.60 $23.57 $10.33 $11.62 $11.62 $12.92 $14.21 $15.50 $16.79 $18.08 $19.37 $20.66 $21. 96 $23.25 $24.54 $24.54 $25.85 $35.81 $38.39 $40.10 $43.55 $13.84 $15.22 $16.61 httn. / /www 1n1_ wa.Qov/Prevailine W aee/ Appwages/20041/co05 . asp 1M 1M 1M 1M 1M 1M 2B 2B 2B 2B 2B 2B 5D 5D 5D 5D 5D SD SA 5A 5A 5A SA SA 1 1 I 1 1 1 1 1 1 1 1 1 1 1 IG 1G 1G 1G 1G SA SA SA SA 5A SA 5A SA SA 2/1 0/04 CLALLAM County - Effective: 3/3/2004 -- Page 5 of6 4: 6001 - 8000 Hours - 70.00010 $19.38 1 5: 8001 -10000 Hours - 85.00010 $23.53 1 RESIDENTIAL CARPENTERS I: Istperiod-60.00% $10.71 2: 2nd Period _ 65.00% $11.60 I -.----J":-3rdperiod-: 70:00% - - --.- --- -- - '-$12.50--' ----j-------- ------ --- --- --- - - -.-- 4: 4th Period _ 75.00010 $13.39 1 5: 5th Period _ 80.00% $14.28 1 6: 6th Period _ 85.00% $15.17 I 7: 7th Period _ 90.00% $16.07 1 8: 8th Period _ 95.00% $16.96 I RESIDENTIAL ELECTRICIANS I: 0 - 900 Hours. 50.00010 $13.89 I 2:901-1800Hours-55.00% $15.28 I 3: 1801 - 2700 Hours - 75.00% $20.84 1 4: 2701 - 4000 Hours - 85.00% $23.61 1 RESIDENTIAL PLUMBERS & PIPEFITTERS 1: 0 -1000 Hours - 55.00% $8.03 2: 1001 - 2000 Hours - 65.00% $9.49 3: 2001 - 4000 Hours -75.00% $10.95 4: 4001 - 6000 Hours - 85.00% $12.41 RESIDENTIAL SHEET METAL WORKERS JOURNEY LEVEL (FIELD OR SHOP) 1: 1 - 1000 Hours - 50.00% $15.66 1J 6L 2: 1001 - 2000 Hours - 60.00% $17.84 1J 6L 3: 2001 - 3000 Hours - 65.00% $22.10 1J 6L 4: 3001 - 4000 Hours - 70.00% $23.20 1J 6L 5: 4001 - 5000 Hours - 80.00% $25.39 1J 6L 6: 5001 - 6000 Hours - 85.00% $26.48 1J 6L ROOFERS 1: 0 - 820 Hours - 60.00% $21.93 lR 5A 2: 821 - 1630 Hours - 67.00% $23.78 lR 5A 3: 1631 - 2450 Hours -74.00% $25.58 lR 5A 4: 2451 - 3270 Hours - 81.00% $29.66 lR 5A I 5: 3271 - 4080 Hours - 88.00% $31.46 lR 5A 6: 4081 - 4899 Hours - 95.00% $33.25 lR 5A SHEET METAL WORKERS JOURNEY LEVEL (FIELD OR SHOP) 1: 0 - 2000 Hours - 45.00% $19.17 1J 6L 2: 2001 - 3000 Hours - 50.00010 $26.89 11 6L 3: 3001 - 4000 Hours - 55.00% $28.63 1J 6L 4: 4001 - 5000 Hours - 60.00% $30.38 1J 6L 5: 5001 - 6000 Hours - 65.00% $32.14 1J 6L 6: 6001 - 7000 Hours - 70.00010 $33.89 1J 6L 7: 7001 - 8000 Hours - 75.00% $35.64 1J 6L 8: 8001 - 9000 Hours - 80.00% $37.39 1J 6L 9: 9001 - 10000 Hours - 85.00% $39.15 1J 6L SOFT FLOOR LAYERS APPRENTICES INDENTURED ON OR AFTER JUNE I. 2003 1: 0 -750 Hours - 45.00% $15.19 IB 5A 2: 751 - 1500 Hours - 50.00% $17.31 1B 5A 3: 1501 - 2250 Hours - 60.00% $20.95 IB 5A 4: 2251 - 3000 Hours -70.00% $23.59 1B 5A 5: 3001 - 3750 Hours - 80.00% $26.24 IB 5A 6: 3751 - 4500 Hours - 90.00% $28.88 IB 5A APPRENTICES INDENTURED PRIOR TO JUNE I. 2003 1: 0 -750 Hours. 45.00010 $16.99 IB 5A 2: 751 -1500 Hours - 50.00% $18.31 1B 5A 3: 1501 - 2250 Hours - 60.00% $20.95 1B 5A 4: 2251 - 3000 Hours -70.00% $23.59 IB 5A 5: 3001 - 3750 Hours - 80.00% $26.24 1B 5A 6: 3751 - 4500 Hours - 90.00% $28.88 IB 5A SPRINKLER FITTERS (FIRE PROTECTION) GRADE J (INDENTURED AFTER APRIL J. 2000) 1: 0 - 1000 Hours - 45.00% $8.85 1 2: 1001 - 2000 Hours - 50.00% $9.84 1 3: 2001 - 3000 Hours - 55.00% $10.82 1 htto:/Iwww.1ni.wa.govlPrevailingWagelAppwages/20041/co05.asp 2/10/04 CLALLAM County - Effective: 3/3/2004 -- tJJ'Ti~">'UIi po \!1.1rw '~l"~ ';r : Hn~tJJ}-J ..n~1 " "" 4: 3001 - 4000 Hours - 60.00% $11.80 GRADE I (INDENTURED BEFORE APRIL I. 2000) 1: 0 -1000 Hours. 40.00010 $7.87 1 2: 1001 - 2000 Hours - 45.00010 $8.85 1 3: 2001 - 3000 Hours - 50.00% $9.84 1 __ ---4;-300l---4000Hours-S,)<00%-- --- ---$W.87r------L-- ------- ---- GRADE 2 (]NDENTURED AFTER APRIL I. 2000) 1: 0 - 1000 Hours - 65.00010 $12.79 2: 1001 - 2000 Hours -70.00% $13.77 3: 2001 - 3000 Hours - 75.00% $14.75 4: 3001 - 4000 Hours - 80.00% $15.74 5: 4001 - 5000 Hours - 85.00% $16.72 6: 5001 - 6000 Hours - 90.00% $17.70 GRADE 2 (]NDENTURED BEFORE APRIL I. 2000) 1: 0 - 1000 Hours - 60.00010 $11.80 2: 1001 - 2000 Hours - 65.00% $12.79 3: 2001 - 3000 Hours -70.00% $13.77 4: 3001 - 4000 Hours -75.00010 $14.75 5: 4001 - 5000 Hours - 80.00010 $15.74 6: 5001 - 6000 Hours - 85.00% $16.72 TERRAZZO WORKERS & TILE SETTERS 1: 0 - 1000 Hours - 50.00% 2: 1001 - 2500 Hours - 55.00010 3: 2501 - 3500 Hours - 60.00% 4: 3501 - 4500 Hours - 70.00% 5: 4501 - 5500 Hours - 80.00% 6: 5501 - 6250 Hours - 90.00% 7: 6251 -7000 Hours - 95.00% TILE, MARBLE & TERRAZZO FINISHERS FINISHER 1: 0 - 1000 Hours - 50.00% 2: 1001 - 2500 Hours - 55.00010 3: 2501 - 3500 Hours - 60.00% 4: 3501 - 4500 Hours - 70.00% TRAFFIC CONTROL STRIPERS 1: 0 - 500 Hours - 60.00% 2: 501 - 1000 Hours - 60.00% 3: 1001 - 2333 Hours - 60.00% 4: 2334 - 4666 Hours - 73.00% 5: 4667 - 7000 Hours - 88.00% TRUCK DRIVERS ALL TRUCKS 1: 0 - 700 Hours - 70.00010 2: 701 - 1400 Hours - 80.00% 3: 1401 - 2100 Hours - 90.00% $20.69 $22.02 $23.35 $26.01 $28.66 $31.32 $32.65 $20.07 $21.35 $22.61 $25.15 $12.96 $17.82 $20.22 $23.53 $27.35 $14.16 $16.18 $18.21 1 1 1 1 1 1 1 1 I 1 1 1 1 IH 1H 1H IH 1H IH 1H 1H IH IH 1H lK lK lK lK lK About L&\ I Find a job at L&I Ilnformadon en espanol I Site Feedback I 1-800-547-8367 Cl Washmgton State Dept of Labor and Industries. Use of thIS site is subject to the laws of the state of Washington. ACcess Agreement I Privac:y and secunty statement I Intended use/external content polley I Staff onlv link hftn.//WUTW lnl WH ~mv/Prevailim.!WaQe/ADDWaJ!es/2004l/co05.asp Page 6of6 5A 5A 5A 5A 5A 5A 5A 5A 5A 5A 5A 5A 5A 5A 5A 5A ~.. Visit access.wa.gov 2/10/04 ATTACHMENT B CONSTRUCTION CHANGE ORDER PROCEDURES PUBLIC WORKS DEPARTMENT - POLICY AND PROCEDURES CHANGE ORDERS ON CONSTRUCTION CONTRACTS PW-404 1.0 PURPOSE: 1.1 To provide Instructions to field Inspectors and office personnel on procedures for contract change orders 1.2 To Improve record keeping on construction projects. 1 3 To provide a Uniform method for contract change orders 2.0 ORGANIZATIONS AFFECTED: 2.1 Public Works Engineering staff 2.2 Engineers and Architects on City managed construction projects 3.0 POLICY: 3.1 All revIsions, clarifications, field requests and field authorizations for construction contracts shall be documented using the "REQUEST FOR INFORMATION" form. 3 2 All change orders to contracts shall be approved in accordance with City Council Resolution No 7-0. 3 3 Change Order authorization by the Director of Public Works & Utilities and the City Manager shall not exceed their statutory limits of $5,000 and $15,000 respectively. When it is anticipated their authority will be exceeded, approval shall be obtained from the next higher authority. 4.0 DEFINITIONS: 41 RFI: Request for Information. 4.2 CCO: Construction Change Order 5.0 PROCEDURES: 5.1 A construction contract change order may be initiated by the Contractor, City Inspector, or ArchitecUEngineer by uSing the RFI form, PW-404_02. 5.2 The person completing the form shall fill in all areas of the form and sign the request. 5.3 The paperwork flow on the change order shall proceed as shown on the attached diagram, PW-404_03 6.0 5 4 The change order form IS PW-404_04. APPENDIX: 6 1 The "RFI" Form 6 2 Procedure flow for Change Orders ........... ... .. 6.3 Change Order Form . 6 4 RFI Request Log . .... . . . . . . . 65 Resolution 7-01 authorizing approval of Change Orders . . PW-404_02 [12/01] PW-404_03 [12/01] . . . . . PW-404_04 [12/01] . . PW-404_05 [12/01] B-1 CITY OF PORT ANGELES PUBLIC WORKS & UTILITIES DEPARTMENT DESIGN CLARIFICATION /VARIATION REQUEST (DCVR) FORM PROJECT NAME: PROJECT/CONTRACT NUMBER: ORIGINATOR: ITEM: REFERENCE DRAWING OR SPECIFICATION: DESCRIPTION OF CLARIFICATION/REQUEST: o Contractor 0 Inspector DA TE REPLY REQUESTED: CRITICAL TO SCHEDULE: 0 YES 0 NO ORIGINATOR SIGNATURE: DATE: COMMENTS: N \PWK't\l J(jH I\FN0R\PRO Ire. I MEh\ hll UV\Ph.J~l 2\LL W J\MAN2 \\ pd DCVR NO._ B-2 CONTRACT CHANGE ORDER (CCO) NO. Project Name Date: Contractor Project No. DESCRIPTION OF WORK You are ordered to perform the following described work upon receipt of an approved copy of this Change Order: Such work will be compensated by: check one or more of the following as applicable [ ] Increase or [ ] Decrease in bid items; [ ] Force Account; [ ] Negotiated Price: The described work affects the existing contract items and/or adds and/or deletes bid items as follows: em o DescnptIon RFI# Qty Umt *$ Cost Per Umt *$ Cost Ong Rev 2 Orig_ Rev * ORIGINAL * CURRENT * EST NET CHANGE TOTAL CHANGE ORDERS, *EST CONTRACT AFTER CONTRACT THIS CHANGE ORDER INCLUDING THIS ONE THIS CHANGE ORDER CONTRACT I DAYS, I DAYS I DAYS: I DAYS, I DAYS, I * Sales Tax not included All work, matenals and measurements to be m accordance wIth the provIsIons of the ongmal contract and/or the standard specIficatIOns and specIal provIsIOns for the type of constructIon mvolved The payments and/or addItIonal tIme specIfied and agreed to m thIS order mclude every claIm by the Contractor for any extra payment or extensIOn of tIme WIth respect to the work descnbed herem, mcludmg delays to the overall project I APPROVED BY I SIGNATURE I DATE I PROJECT ENGINEER CITY ENGINEER CONTRACTOR PUBLIC WORKS & UTILITIES DIRECTOR CITY MANAGER CITY COUNCIL APPROY AL DATE B-3 ATTACHMENT C CONTRACTORS APPLICATION FOR PAYMENT FORM CONTRACTOR'S APPLICATION FOR PAYMENT TO: City of Port Angeles FROM: Public Works & Utilities Department P.O. Box 1150 Port Angeles, W A 98362 DATE: PROJECT NAME: PAYMENT REQUEST NO. PROJECT NUMBER: PERIOD From: to [end of period]: STATEMENT OF CONTRACT ACCOUNT 1 Contract Amount Thru Approved Change Order No,_ [Excluding Sales Tax] $ 2 Work Completed to Date [per attached continuation sheets] $ 3 Sales Tax (Port Angeles is 8.3% of [2]) $ , 4 Amount Retained (5% of [2])** t $ I t 5 Subtotal ([2]+[3]-[4]) $ 6 Total Previously Paid [Deduction] $ 7 AMOUNT DUE THIS REQUEST ([5]-[6]) $ *correspond to column letters shown on the continuation sheet. **Enter zero if a retainage bond has been approved WAIVER OF CLAIMS FOR EXTRA COST OR TIME: The undersigned Applicant waives and releases, up through the date hereof, any and all claims for costs or item extensions arising out of or relating to extra or changed work or delays or acceleration not specifically identified and reserved in the amounts identified below or previously acknowledged in writing by the City of Port Angeles. CERTIFICA TE OF ~HE CONTRACTOR: I hereby certify that the work performed and the materials supplied through the ending period date noted above represents the actual value of accomplishment under the terms of the contract (and all authorized changes) between the Applicant and the City of Port Angeles, relating to the above referenced project, and that the remaining contract balance is sufficient to cover all costs of completing the work in accordance with the contract documents. C-l CONTRACTOR'S APPLICATION FOR PAYMENT I also certify that all lower-tier payments, less applicable retention, have been made by the Applicant for the periods covered by previous payment received by the Applicant to (1) all lower-tire subcontractors/suppliers, and (2) for all materials, equipment and labor used or in connection with the performance of this contract. I further certify that I have complied with all Federal, State and local tax laws, including Social Security laws and Unemployment Compensation laws and Workmen's Compensation laws, insofar as applicable to the performance of this work, and have paid all such taxes, premiums and/or assessments arising out of the performance of the work. I further certify that, to the best, of my knowledge, information and belief, all work for which previous payment(s) have been received shall be free and clear of liens, claims, security interests and encumbrances in favor of the Contractor, subcontractors, material suppliers, or other persons or entities making a claim by reason of having provided labor, materials and equipment relating to the work. Within seven (7) days of receipt of the payment requested herein, all payments, less applicable retention, will be made through the period covered by this pay request to all my lower-tier 3ubcontractors/suppliers and for all materials, equipment, labor, taxes and assessments arising out of the performance of all said lower-tire work. , DATED: CONTRACTOR: SIGNATURE: PRINTED NAME AND TITLE: SUBSCRIBED AND SWORN to before me this day of Notary Public in and for the State of residing at My appointment expires APPROVAL: Project Manager Date City Engineer Date Director Date PW-402 13 [rev 1/01] C-2 PAY REQUEST FORM ELWHA REBUILD (STAGE 2) PROJECT 02-11 B No BID ITEM UNITS CONTRACT BID ~ONTRAC OUANITY QUANITY QUANITY COST COST COST COST COST/UNIT QTY OUANITY COMPLETE PREVIOUS THIS CONTRACTED UNITS PREVIOUS THIS APPLICATIONS APPLICATION ITEM COMPLETE APPLICATION APPLICATION INSTALLS 1 Trenching and Backfill Feet 2900 2 CondUit 5" PVC Feet 5800 3 Conduit 4" PVC Feet 2900 4 U 3 04 (Sectlonalizlng Cabinet and Vault) Each 3 5 Install Vault Each 7 6 Cable CirCUit ft 3100 7 U 302 (Termination Three Phase Underground) Each 2 8 Backfill Man Hole Each 2 9 Street Asfault Repair Soft 100 Optional Items 10 CondUit 2" PVC (PUm Feet 1200 11 Coordinate cable Installation by Owest. Feet 2400 I REMOVALS 1 Man Hole and Vault Lid Each 2 2 UG Riser and Terminations Each 2 3 R!W ClearinQ LS 1 '. Company Name: AuthOrized Signature: Date PayRequestForm(ElwhaStage3 ) R.W. Beck, Inc. ATTACHMENTD CONSTRUCTION SPECIFICATIONS CONSTRUCTION SPECIFICATIONS GENERAL REQUIREMENTS I PROJECT DESCRIPTION A. GENERAL , The following information is provided to assist the Contractor in evaluation of and preparation for the work required to construct the Electric Underground Rebuild - Elwha Line Phase 2. B. DESCRIPTION The following project is to be constructed. The project is for the excavating and installing approximately 2900 feet of underground primary (l2.47kV) power cables in conduit and related appurtenances west of Dry Creek along City right of way in the County ofClallam, Washington. The project also includes removal of existing facilities. II WORKFORCE REQUIREMENTS Construction work on poles or equipment containing lines energized in excess of 600 volts will be done by crews containing a minimum oftwo journeyman linemen and one groundman/equipment operator. Construction work on poles or equipment containing deenergized lines or lines energized at 600 volts or less will be done by crews containing a minimum of one journeyman lineman and one groundman/equipment operator. III SWITCHING AND CLEARANCES The Contractor's Qualified Worker (Foreman) will be required to take all line clearances from designated City Representative who has jurisdiction over the line. All switching of the electrical system will be done by City personnel. A notice of 72 hours is required to schedule any switching other than in an emergency. IV AS-BUILT DRAWINGS As-built drawings are required. The City will supply a set of drawings to be used by the Contractor to prepare the as-built drawings for the project. The as-built drawings shall be a record of the construction as installed and completed by the Contractor. They shall include all the information shown on the contract set of drawings and a record of all construction deviations or changes from those drawings which were incorporated in the work; all additional work not appearing on the contract drawings; all design submittals, including electrical schematics; and all D-l changes which are made after final inspection of the contract work. The Contractor shall mark up a set of full size plans using red ink to show the as-built conditions. These as-built marked prints shall be kept current and available on the job site at all times and be made available to the City Representative upon request. The changes from the contract plans which are made in the work or additional information which might be uncovered in the course of construction shall be accurately and neatly recorded as they occur by means of details and notes. No construction work shall be concealed until it has been inspected, approved, and recorded by the City Representative. The drawings shall show at least the following: A. The project number, contract number, community name, and other relevant general information. B. The location and description of any utilities or other installation known to exist and or to be encountered within the construction area. The location of these utilities shall include accurate description, dimensions, and at least 2 ties to permanent features for all utilities encountered. C. The location and description of all facilities and appurtenances installed by the Contractor. The location of facilities and appurtenances shall include accurate dimensions and at least 2 ties to permanent features for all major components. The City of Port Angeles has the right to deny progress payments for completed work if as-built records, as required by this section, are not available on the job site for the work that has been completed by the date of the payment request. Final as-built drawings shall be delivered to the City Representative at the time of final inspection for the Project Engineer's review and approval. As-built drawings must be approved by the Project Engineer before final payment will be made. V SEQUENCE OF OPERATIONS A. The Contractor shall cooperate in the coordination of their activities with any other contractors working in the area. B. The Contractor will be required to work on or around energized circuits, and hot-line work is anticipated. C. If any difficulty or dispute should arise in the accomplishment of the above, the problem shall be brought immediately to the attention of the City Representative for resolution. VI SITE CONDITIONS A. CONTRACTOR'S RESPONSIBILITY FOR UTILITY PROPERTIES AND SERVICE D-2 1. Utility Location Request Center a. The Contractor shall call the Utility Location Request Center (One Call Center)[1-800-424-5555], for field location not less than two nor more than ten business days before the scheduled date for commencement of excavation which may affect underground utility facilities, unless otherwise agreed upon by the parties involved. A business day is defined as any day other than Saturday, Sunday, or a local, state or federal legal holiday. The telephone number for the One Call Center for this project may be obtained from the City Representative. If no one-number locator service is available, notice shall be provided individually to those owners known to or suspected of having underground facilities within the area of proposed excavation. b. The Contractor is alerted to Chapter 19.22 RCW, relating to underground utilities. Any cost to the Contractor incurred as a result of this law shall be at the Contractor's expense. c. No excavation shall begin until all known facilities in the vicinity ofthe excavation area have been located and marked. d. The following addresses and telephone numbers of utility companies known or suspected of having underground facilities within the project limits are supplied for the Contractor's convenience: i 1 City of Port Angeles - Department of Public Works & Utilities (water, sewer, power) 321 East Fifth Street Port Angeles, W A 98362 Telephone: 417-4702 11 Qwest 635 Oakridge Drive Port Angeles, W A 98362 Telephone: 452-2184 111 Northland Cable Television 725 East First Street Port Angeles, W A 98362 Telephone: 452-8466 2. The Contractor shall in all cases be held responsible to notify the City Representative at least 48 hours not including Saturday, Sunday, or holidays in advance of any construction. The Contractor shall under no circumstances expose any underground utility without first obtaining permission from the appropriate agency. The Contractor shall, once permission has been granted, D-3 locate, expose, and provide temporary support for all existing underground utilities. 3. Where the Contractor's operations could cause damage or inconvenience to telegraph, telephone, television, power, oil, gas, water, sewer, storm drains, or other systems, the operations shall be suspended until all arrangements necessary for the protection of these utilities and services have been made by the Contractor. 4. The Contractor shall be solely and directly responsible to the City and operators of properties referenced in #2 above for any damage, injury, expense, loss, inconvenience, delay, suits, actions, or claims of any character brought because of any injuries or damage which may result from the construction operations under this contract. 5. Neither the City nor its officers or agents shall be responsible to the Contractor for damages as a result of the location of underground utilities being other than that shown on the drawings, for the existence of underground utilities not shown on the drawings, or the Contractor's failure to protect utilities encountered in the work. 6. The Contractor shall in the event of interruption to domestic water, sewer, storm drain, or other utility services as a result of accidental breakage due to construction operations, promptly notify the proper authority. The Contractor shall cooperate with said authority in restoration of service as promptly as possible and bear all costs of repair. In no case shall interruption of any utility service be allowed to exist outside the Contractor's normal working hours unless prior approval is granted. 7. The Contractor shall replace, at its own expense, any and all existing utilities or structures removed or damaged during construction, unless otherwise provided for in these contract documents or ordered by the City Representative. 8. The Contractor shall excavate and expose all buried plant marked in the field by hand digging a minimum of eighteen (18") inches on either side of the staked location, plus one-half (1/2) the width ofthe facility. All other known buried plant must also be exposed by hand digging. 9. Damage to Buried Plant: The Contractor shall notify the City Representative of all damage to buried plant and shall not cover the damage until inspected and approved for cover by the City Representative. 10. The Contractor shall hold the City harmless against all claims for damage to buried plant arising out ofthe Contractor's performance here under, which may be filed against the City. 11. The Contractor shall be responsible to obtain all necessary permits and licensing to perform the work unless such work is to be performed by the City and stated so herein. D-4 , . B. CONTRACTORS RESPONSIBILITY FOR PROTECTION OF THE ENVIRONMENT This project is in an environmentally sensitive area and the contractor shall at all times keep construction activities controlled to limit the impact on the environment.. C. INTERFERING FACILITIES 1. The Contractor shall take necessary precautions to prevent damage to existing facilities or structures whether on the surface, aboveground, or underground. An attempt has been made to show major facilities and structures on the drawings. While the information has been compiled from the best available sources, its completeness and accuracy cannot be guaranteed, and it is presented simply as a guide to possible difficulties. 2. Where existing buildings, poles, or any other structure must be removed in order to properly carry out the construction, or are damaged during construction, the Contractor shall restore them to their original condition to the satisfaction of the City Representative at the Contractor's own expense. The Contractor shall notify the City Representative of any damaged facility or underground structure and make repairs or replacements before backfilling. 3. CONSTRUCTION IN RIGHT OF WAY a. All work within the public right of way shall be carried out in such a manner that where possible one lane of traffic in each direction will be available at all times on all streets affected by the work. A traffic control plan must be submitted and approved by the City prior to starting construction. The approved traffic control plan including signs, sign placement, lane routing, and flaggers will be enforced at all times. b. Disruption of traffic shall be kept to a minimum at all times. c. All signs required by the approved traffic control planes) as well as any other appropriate signs prescribed by the City Representative shall be furnished by the Contractor. The Contractor shall provide the posts or supports and erect and maintain the signs in a clean, neat, and presentable condition until the necessity for them has ceased. All nonapplicable signs shall be removed or completely covered with metal, plywood, or a City Representative approved product specifically manufactured for sign covering during periods when they are not needed. When the need for the signs has ceased, the Contractor, upon approval of the City Representative, shall remove all signs, posts, and supports from the project and they shall remain the property ofthe Contractor. Construction signs will be divided into two classes. Class A construction signs are those signs that remain in service throughout the construction or during a major phase of the work. They are mounted on posts, existing D-5 fixed structures, or substantial supports of a semi-permanent nature. The following Class A signs shall be installed by the Contractor at locations designated at the Pre-construction conference: "Construction Ahead" (2) "Project Sign" - Wording to be determined Class B construction signs are those signs that are placed and removed daily, or are used for short durations which may extend for one or more days. They are mounted on portable or temporary mountings. In the event of disputes, the City Representative will determine if a construction sign is considered as a Class A or B construction sign. d. There shall be no delay to medical, fire, police, or other emergency vehicles with flashing lights or sirens. The Contractor shall alert all flaggers and personnel of this requirement. e. All unattended material storage, trenches, excavations and spoil shall be guarded by barricades and warning tape. f. Materials, equipment, trench spoil or debris shall not be stored on the street surface and shall be cleared by the end of each work day. g. During the actual hours of work, only materials absolutely necessary to construction shall be within the construction area, and only construction vehicles absolutely necessary to construction shall be allowed within the construction area or allowed to stop or park on the local streets. h. The Contractor's nonessential vehicles and employees' private vehicles shall not be permitted to park within the construction area or on city streets. 1. Prior to trenching across driveways, the Contractor MUST NOTIFY ALL OWNERS 24 HOURS IN ADVANCE. VII TEMPORARY CONSTRUCTION UTILITIES AND FACILITIES A. LAYOUT OF TEMPORARY FACILITIES The Contractor shall make its own arrangements for storage of materials and equipment. D-6 B. STORAGE BUILDINGS 1. The Contractor shall provide temporary storage facilities required for the protection of mechanical and electrical equipment and materials as recommended by manufacturers of such equipment and materials. The facilities shall be provided with such environmental control systems that meet recommendations of manufacturers of all equipment and materials stored in the buildings. The facilities shall be of sufficient size and so arranged or partitioned to provide security for their contents and provide ready access for inspection and inventory. The temporary storage facilities shall remain the property of the Contractor. 2. Combustible materials (paints, solvents, fuels, etc.) shall be stored in a well- ventilated facility removed from other facilities. All storage shall comply with NFP A and applicable state and local requirements. ,C. STORAGE YARDS The Contractor shall arrange for and construct temporary storage yards for the storage of materials that are not subject to damage by weather conditions. Materials shall be stored on pallets or racks, off the ground, and in a manner to allow ready access for inspection. D. STORAGE OF MATERIALS Materials shall be stored to ensure the preservation of their quality and fitness for the work. All items, as a minimum, shall be placed on wooden platforms or other hard, clean surfaces, and not on the ground. Materials subject to vandalism shall be placed under locked cover. Stored materials shall be located so as to facilitate prompt inspection. Private property shall not be used for storage purposes without the written permission of the property owner or lessee. VIII MOVE IN AND SITE PREPARATION The Contractor shall set up construction facilities in a neat and orderly manner and shall confine operations to work areas described or as approved. IX PUBLIC SAFETY AND CONVENIENCE A. ACCESS BY FEDERAL, STATE, AND LOCAL GOVERNMENT OFFICIALS Authorized representatives ofthe United States Environmental Protection Agency, the State Department of Transportation, State Board of Health, and other government officials shall at all times have safe access to the work wherever it is in preparation or progress, and the Contractor shall provide proper facilities for such access and inspection. D-7 B. TRAFFIC MAINTENANCE AND SAFETY The Contractor shall comply with all applicable sections of the State Department of Transportation, Utility Accommodation Guide, latest edition, and the Department's Manual on Traffic Control and Safe Practices. The Contractor shall comply with all other applicable rules and regulations of the state, federal, and county authorities regarding closing or restricting the use of public streets or highways. No public or private road shall be closed, except by express permission of the owner. The Contractor shall conduct the work so as to assure the least possible obstruction to traffic and normal commercial pursuits. The Contractor shall protect all obstructions within traveled roadways by installing approved signs, barricades, and lights where necessary for the safety of the public. The convenience of the general public and residents adjacent to the project, and the protection of persons and property are of prime importance and shall be provided for in an adequate and satisfactory manner. During construction operations, the Contractor shall construct and maintain such facilities as may be required to provide access by all property owners to their property. No person shall be cut off from access to hislher residence or place of business unless the Contractor has made special arrangements with the City to inform affected persons. C. PROTECTION OF PROPERTY The Contractor shall protect stored materials, trees, and other items located adjacent to the proposed work. D. FIRE PREVENTION AND PROTECTION I The Contractor shall perform all work in a fire-safe manner and shall supply and maintain, on the site, adequate fire-fighting equipment capable of extinguishing incipient fires. The Contractor shall comply with applicable federal, local, and state fire prevention regulations. Where these regulations do not apply, applicable parts of the National Fire Prevention Standard for Safeguarding Building Construction Operations, (NFP A No. 241) shall be followed. E. PROTECTION OF THE ENVIRONMENT 1. The Contractor shall maintain all work areas within and outside the project boundaries free from environmental pollution which would violate any federal, state, or local regulations. 2. The Contractor shall prevent contamination of the project area and not dump any waste oil, rubbish, or other similar materials on the ground. Upon completion of the project, the Contractor shall remove the construction facilities and shall complete and clean up the construction area to the satisfaction of the City Representative. 3. The Contractor shall observe applicable State and Federal rules and regulations prohibiting the pollution of stream or river waters by the dumping of any refuse, rubbish, or debris therein. D-8 4. Protection of Air Quality: a. Air pollution due to construction operations shall be minimized by wetting down bare soils during windy periods, the use of properly operating combustion emission control devices on construction vehicles and equipment used by the Contractor, and by shutting down motorized equipment not actually in use. b. Trash burning will not be permitted on the construction site. c. If temporary heating devices are necessary for protection of the work, such devices shall be of an approved type that will not cause air pollution. 5. The Contractor shall conduct all work by using appropriate construction methods and equipment and by furnishing and installing acoustical barriers, all as necessary to keep noise emanating from the process or any related equipment at legal noise levels. 6. If the Contractor desires to perform any work between the hours of 8 p.m. and 7 a.m., it shall obtain all necessary permits from the appropriate agencies and make all necessary arrangements through the City Representative prior to commencing. X PRESERVATION, RESTORATION, AND CLEANUP A. SITE RESTORATION AND CLEANUP 1. The Contractor shall at all times during the work keep the premises clean and orderly and upon completion of the work repair all damage caused by equipment and leave the project free of rubbish or excess materials of any kind. 2. Excavated materials shall be stockpiled in a manner that will cause the least damage to adjacent lawns, grass areas, gardens, shrubbery, or fences, regardless of whether these are on private property or on city, state, or county rights-of-way. The Contractor shall remove all excavated materials from grass and planted areas and leave these surfaces in a condition equivalent to their original condition. 3. All existing drainage ditches and culverts shall be reopened and graded and natural drainage restored. Broken or damaged culverts shall be restored to their original condition and location. 4. Upon completion of construction, the Contractor shall leave all disturbed areas free from rocks, gravel, clay, or any other foreign material. The finished surface shall conform to the original surface and shall be free-draining and free from holes, ruts, rough spots, or other surface features detrimental to a seeded area, unless noted otherwise on the drawings. All excess excavation materials and debris shall be delivered to the Port Angeles Landfill or other approved disposal site. 5. The Contractor shall seed and provide erosion control in all devegetated areas in a manner suitable to the City Representative. All surface restoration shall be the D-9 responsibility of the Contractor. B. TREE REMOVAL Trees, stumps and shrubs shall be removed to a width of20 feet north of the south right-of- way line. All debris to be hauled the the City Landfill. No other trees to be removed without the express approval of the City Representative. C. DUST PREVENTION If required by the City Representative, the Contractor shall give all unpaved streets, roads, detours, or haul roads used in the construction area an approved dust preventive treatment or periodically water them to prevent dust. Applicable environmental regulations for dust prevention shall be strictly enforced. XI SUBMITTALS DURING CONSTRUCTION A. The following requirements are in addition to any specific requirements for submittals specified in other sections of the project manual. B. Submitted data shall be fully sufficient in detail for determination of compliance with the project manual. I C. Approval of substitutions, schedules, lists of materials, and procedures submitted or requested by the Contractor shall not add to the contract amount, and any additional costs which may result therefrom shall be solely the obligation ofthe Contractor. It shall not be the responsibility of the City to provide engineering or other services to protect the Contractor from additional costs accruing from such approvals. D. The City is not precluded, by virtue of review, acceptance, or approval, from obtaining a credit for construction savings resulting from allowed concessions in the work or materials therefor. XII MATERIAL AND EQUIPMENT A. MA TERIALS All materials with the exception of backfill and paving repair materials will be provided by the City. These materials may be picked up, after 48 hrs advance notice, at the City's warehouse at 206 South Valley Street, Port Angeles, W A. All unused and/or removed materials shall be returned to this warehouse. B. EQUIPMENT AND TOOLS The Contractor shall provide all construction equipment and tools required to complete the work as specified herein. D-IO C. INCIDENTAL MATERIALS Materials required for temporary work shall be provided by the Contractor. The Contractor shall also provide pentachlorophenol solution for treating bolt holes, cedar plugs, gains, etc., as required, and all tools, fire suppression implements and other equipment as required. The Contractor shall also supply ancillary items that may be needed for construction or maintenance. This shall include but not be limited to drainage culverts, water, gravel, fill dirt, concrete, seed and other erosion control devices. D. ENERGIZA TION Upon the completion of construction and cleanup, the Contractor shall energize each project task, or a portion thereof, after written notice to the City Representative, in accordance with applicable sections of the project manual, and as instructed by the City Representative. D-ll UNDERGROUND DISTRIBUTION SYSTEMS I General These specifications provide for the construction of underground distribution power facilities. All construction work shall be done in a thorough and workmanlike manner in accordance with the Contract, specifications, basic framing units and construction drawings, adhering to good construction practices at all times. The 1997 or latest edition of the National Electric Safety Code and the Washington Administrative Code (WAC) shall be followed, except where local regulations are more stringent, in which case local regulations shall govern. II Handling of Cable Cable shall be handled carefully at all times to avoid damage, and shall not be dragged across the ground, fences or sharp projections. Care shall be exercised to avoid excessive bending ofthe cable. The ends of the cable shall be sealed at all times against moisture with suitable end caps. Where it is necessary to cut the cable, the ends shall be terminated or sealed immediately after the cutting operation. III Minimum Bending Radius of Cable The minimum bending radius of primary cable is 12 times the overall diameter of the cable. The minimum bending radius of secondary and service cable is six times the overall diameter of the cable. In all cases, the minimum radius specified is measured to the surface of the cable on the inside of the bend. No cable bends shall be made within 6.0 inches ofa cable terminal base. IV Conduit All exposed ends of conduit shall be plugged during construction to prevent the entrance of foreign matter and moisture into the conduit. Burrs or sharp projections which might injure the cable shall be removed. All PVC conduit must be glued securely with PVC cement. All rigid steel conduit must be securely screwed at all couplings. Primary and secondary risers shall be sealed at the top with a suitable moisture resistant sealant to prevent water from accumulating in the riser. V Installation of Cable in Conduit Where cable must be pulled through conduit or duct, the operation shall be performed in such a way that the cable will not be damaged from strain or dragging. The cable shall be lubricated with a suitable lubricant prior to and during pulling into conduit or duct. In placing primary cables, the stress applied while pulling into ducts or during other pulling operations shall not exceed the least of the following: A. Where a pulling eye is attached to the conductor, the maximum pulling strain in pounds shall not exceed .006 times the circular mil area for aluminum or .008 times the circular mil area for copper. B. Where a basket grip is placed over the cable, the pulling strain shall not exceed the lesser of (1) that calculated in "a." above or (2) 1000 pounds. The cable under the cable grip and 1.0 foot preceding it shall be cut and discarded after the pulling operation. C. In no case shall the maximum pulling tension exceed that recommended by the specific cable manufacturer. D-12 D. At bends the maximum sidewall pressure recommended by the cable manufacturer shall not be exceeded. VI Tagging of Cables at Termination Points As the cables are pulled they shall be identified and tagged as indicated on the construction drawings. The identification shall be permanent type, corrosion resistant tags provided by the City. The tag shall be securely attached to the cable as required. Cable terminations at riser poles shall also be tagged properly. Tags inside enclosures shall be oriented so they can be read without having to touch them. VII Primary Cable Termination Prefabricated terminations shall be installed in accordance with the manufacturer's instructions at all primary cable terminals. They shall be suitable for the size and type of cable that they are used with and for the environment in which they will operate. Any indication of misfit, such as a loose or exceptionally tight fit, shall be called to the Light Department Representative's attention. The outer conductive surface of the termination shall be bonded to the system neutral. VIII Special Precautions for Cable Splices and Terminations A portable covering or shelter shall be available for use when splices or terminations are being prepared. The shelter shall be used as necessary to keep rain, snow and windblown dust off the insulating surfaces of these devices. Since cleanliness is essential in the preparation and installation of primary cable fittings, care shall be exercised to prevent the transfer of conducting particles from the hands to insulating surfaces. Mating surfaces shall be wiped with a solvent such as denatured alcohol to remove any possible accumulation of dirt, moisture or other conducting materials. A silicone grease should be applied afterwards, in accordance with the manufacturer's recommendations. Whenever prefabricated cable devices are opened, the unenetgized mating surfaces shall be lubricated with silicone grease before the fittings are reconnected. IX Secondary and Service Connections A suitable inhibiting compound shall be used with all secondary and service connections. All secondary cable connections located below grade or in secondary pedestals shall be made with preinsulated secondary connector blocks. Diving bells with open terminals, insulating boots or moisture barriers that depend solely on tape are not acceptable. A transformer secondary terminal connection shall be completely insulated. If the secondary terminals are threaded studs, the connection shall be made with a preinsulated secondary transformer connection block. If the transformer secondary terminals are insulated cable leads, connection shall be made with a preinsulated secondary connector block or with a secondary prefabricated splice when the transformer leads continue directly to the service. If a transformer is so large that it must have secondary spades, the spades shall be taped or otherwise insulated. Boots used for insulation shall be taped so that they cannot be readily slipped off. Secondary connections to terminals of pole-mounted transformers shall be made so that moisture cannot get inside the cable insulation. This may be accomplished by covering the terminals and bare conductor ends with an appropriate moisture sealant. The secondary connections and insulation shall have accommodations for all future and existing services as shown on the construction drawings and specifications. D-13 X Transformers Transformers shall be handled carefully to avoid damage to the finish and shall be positioned in accordance with the construction drawings and specifications. Only qualified and experienced personnel shall be allowed to make connections and cable terminations. Lock rings must be installed in addition to penta nut. XI Grounding All neutral conductors, ground electrodes, sacrificial anodes and groundable parts of equipment shall be interconnected. All interconnections shall be made as shown on the basic framing units. A complete ground loop shall be trained neatly around equipment opening and shall include the ground rod in the loop. XII Cable Acceptance Tests A. Continuity: After installation of the cable and prior to the high potential test specified below, the contractor and the Light Department Representative shall jointl);' perform a simple continuity test on the system. This can easily be accomplished by grounding the conductor at the source and checking for continuity from the end of each tap with a Meggar. B. High Potential: After successful continuity tests, the contractor and the Light Department Representative will jointly perform high potential tests on each length of cable in the system, with terminations in place but disconnected from the system. The installation shall withstand for a minimum of five minutes a dc test potential as follows: Primary URD Cable XLPE and HMW Poly Rated Voltage Insulation Thickness Inches Field dc Acceptance Voltage 15 kV .220 52.8kV The voltage may either be increased continuously or in steps to the maximum test value. (1) If increased continuously, the rate of increase of test voltage should be approximately uniform and increasing to maximum voltage in not less than 10 seconds and in not more than approximately 60 seconds. (2) If applied in steps, the rate of increase of test voltage from one step to the next should be approximately uniform. The duration at each step shall be long enough for the absorption current to attain reasonable stabilization (one minute minimum). Current and voltage readings should be taken at the end of each step duration. The number of steps should be from five to eight. WARNING: A hazardous voltage may still exist on the cable after the above testing has been completed. Therefore, before handling the cable, the conductor shall be grounded to permit any charge to drain to earth. D-14 CONTRACT CLOSEOUT I FINAL INSPECTION A. After final cleaning and upon written notice from the Contractor that the work is completed, the City Representative will make a preliminary inspection with the Contractor present. Upon completion of this preliminary inspection, the City Representitive will notifY the Contractor in writing of any particulars in which this inspection reveals that the work is defective or incomplete. B. Upon receiving written notice from the City Representative, the Contractor shall immediately undertake the work required to remedy all defects and complete the work to the satisfaction of the City Representative. C. When the Contractor has corrected or completed the items as listed in the City Representative's written notice, it shall inform the City Representative in writing that the required work has been completed. Upon receipt of this notice, the City Representitive, in the presence of the Contractor, shall make his final inspection ofthe project. D. Should the City Representative find all work satisfactory at the time of his inspection, the Contractor will be allowed to make application for final payment in accordance with the provisions of the project manual. Should the City still find deficiencies in the work, the City Representative will inform the Contractor of the deficiencies and will deny the Contractor's request for final payment until such time as the Contractor has satisfactorily completed the required work. II FINAL SUBMITTALS The City will not give its final acceptance of the project until all required record (as-built) drawings have been submitted and approved by the City. III GUARANTEES, BONDS, AND AFFIDAVITS The City will not give its final acceptance of the project until all guarantees, bonds, certificates, licenses, and affidavits required for work or equipment as specified are satisfactorily filed with the City. IV ACCESSORY ITEMS If equipment is furnished and/or installed on this project, the Contractor shall provide to the City, upon acceptance ofthe equipment, all special accessories required to place each item of equipment in full operation. These special accessory items include, but are not limited to, adequate oil and grease as required for the first lubrication of the equipment, fuses, and other expendable items as required for initial startup and operation of all equipment. V RELEASE OF LIENS OR CLAIMS The City will not give its final acceptance of the project until satisfactory evidence of release of liens has been submitted to the City as required by the Project Manual. D-15 ATTACHMENT E PERMITS The contractor must obtain a right of way use permit from Clallam County for the trench crossing of Lower Elwha Road. The fee for this permit will be $150.00 if the conduits are installed utilizing trenchless construction. The fee for the permit will be $1,760.00 if Lower Elwha road is open cut. The permit conditions are included in the following information from the Clallam County Public Works Department 06/01/04 13:50 FAX 360 417 2513 CLALLAM CO ROAD DEPT I4l 001 Clal1am County Public Works Department 223 E. Fourth St., P.O. Box 863 Port Angeles, W A 98362-0149 Phone: 360-417-2319 Fax: 360-417-2513 I Date: 1 June 1,2004 I Pages mcluding this page: I 2 1'0 From Company Name: City-of Port An~des Name: Rav Bradford Contact: Jim Harper Phone No. (360) 417-2530 Fax No. (360)417-4709 Fax No. (360) 417-2S13 Subiect: Lower Elwha Road right-of-way pennit Remarks: Txm Attached is a copy of the Public Works pennit conditions for an open cut at the intersection of Lower Elwha Road and Kaccc Way. The pemdt fee for the open cut in this location is $1.760.00. As an alternative, Ifa road bore is perfoIttled at this location, the permit fee is $150.00. We will. hold the Right-of-way permit until you or your conmetor has decided on" what type of crossing to pursue. If you have any questions you can call me at 417-2530. J:\users\rbradfor\lemp fax form\pwfolJdorm.doc 06/01/04 13:50 FAX 360 417 2513 CLALLAM CO ROAD DEPT 141 002 Clallam County Public Works Department 223 E. Fourth St, Suite 6 Port Angeles, WA 98362-3015 May 28, 2004 City of Port Angeles P.O. Box 1150 Port Angeles, W A 98362-4702 Attention; Jim Harper ~~~~\\ Re: Right of Way Permit (RDP2004-00219) Dear Jim: The Public Works Department has reviewed and approved right-oi-way permit #RDP2004-00219. This permit is for the Elwha Underground Rebuild- Stage 2 Project for the City of Port Angeles. This work is considered an appurtenance to the Port Angeles waterline that was franchised with Clallam County on June 27, 1977. Listed below are additional conditions of this permit: 1. The open cut trench across Lower Elwha Road will need to be backfilled with control density backfill to match the existing road surface. Within one week of bacldil1; the top 3 inches of trench shall be replaced with 3 inches of asphalt and crack sealed. . 2. Restore all disturbed areas in the right-of-way to their original cross section, along with grass seeding and mulch for erosion controL All rocks larger than one inch shall be removed or embedded into the ground for road maintenance pUIposes (roadside mowing). 3. There shall be no clear zone objects placed in the clear zone. If you have any questions regarding these conditions, please call me at 417-2530. ;;~ Ray Bradford Development Review Engineer ~~~~~ J:\Users\R.BRADFOR\R.W\ROP2004-00219.doc ATTACHMENT F CONSTRUCTION STANDARDS CITY OF PORT ANGELES UNIT CONSTRUCTION SPECIFICATIONS SUMMARY LIST ELWHA REBUILD STAGE 2 Project Number 02-11B IUNIT NUMBER U 3 02 U 3 04 UM 0 01 UM 0 07 UM 0 08 UM 0 11 DESCRIPTION Termination Three Phase Underground 4" Conduit Riser-Primary Three Phase Sectionalizing Cabinet, 200AMP Loadbreak Components have been changed to 600AMP Deadbreak (See Drawing E3 for Detail of Junction) Trenching: Primary, Secondary, TV, & TELCO Depth Parking Bushing Parking Bushing Protective Cap Signage Speclfications( Stage2) R.W. Beck Inc. ~ I I I 5' 0" 26 FT ON 40 FT POLE 8 ft. I 6" Min. Min~ 4611 ~ =i=:< TOP TERMINATOR LIGHTNING ARRESTOR TERMINATOR ~ I PROPERTY SIDEI Ground level * NOTE: First conduit Installed at maximum distance from pole. (iDate)M2- .. Appd Eng: :', '~~~-' Appd ops: ~ RevIsed. TERMINATION THREE PHASE UNDERGROUND 411 CONDUIT RISER - PRIMARY CITY OF PORT ANGELES ELECTRIC ENGINEERING SPECIFICATION Sheet-Lof 2 U 302 ITEM QUANTITY STOCK No. (" CD Clamp, hot line 3 3375 @ Wire, cu, bare, #2 Str. cu (#1/0 & #4/0 Str AL URD) as required @ Cut out, open type, 100A or 200A 3 5120/5121 G) Bracket, mounting, cut out 1 5180 @ Screw, lag 112" x 4" as required 1290 @ Terminator, 15 KY, outdoor 3 7317 (j) Arrestor, lightning, Distribution Class 3 5000/5001 @ Bracket, mounting, 3 phase outdoor terminator 7350 @ Bolt, machine, 5/8" x required length 3 124X @ Washer, 2 1/4" x 2 1/4", flat 3 1293 @ Wire, cu, #2 str. cu as required @ Connector (AL or cu) as required 3280/3330 @ Crimplt 2 or 3 3170 @ CondUit, 4" Ridged SCH 80 PVC, 10ft section 1 8008 C': @ Bracket, pole nser Standoff 15" min. 5 min. 8520 @ Strap, Conduit Bracket 5 min. 8335 @ Conduit, 4" PVC, Sch 40 20 ft min. 8032 @ Elbow, 4" 9cf fiberglass 1 8118 @ Ground rod 5/8" dia. x 8', Copperweld 1 1368 @ Copper ground clamp 1 1350 Date: J/"/"'. Appd Eng Appd Ops ReVIsed TERMINATION THREE PHASE UNDERGROUND 411 CONDUIT RISER - PRIMARY Sheet~of 2 CITY OF PORT ANGELES ELECTRICAL ENGINEERING SPECIFICATION U 3 02 3 @ 12' TO 18' BELOW GROUND LEVEL. @ Dale- llt/n. 'IIIii Appd. Eng. n_O} ~~:e~PS. THREE PHASE SECTIONALlZING CABINET Sheet--1- of 2 CITY OF PORT ANGELES ELECTRICAL ENGINEERING SPECIFICATION U 3 04 ./'\ 1, ITEM QUANTITY STOCK No. G) Vault 48"x72,)(42' 42')(66')(38' inside diameter @ Pad 66" x 84')(6" with 18" x 60' hole 7030 1 7031 @ Above ground pnmary sectionalizlng cabinet 24' x 74' x 30' high o Junction mounting panel @ Tank ground @ Conductor, #6 cu bare STA (j) Cnmplt @ Conductor, #2 cu bare STA., soft drawn @ Cadweld *@ Ground rod, 518" dia x 8', copperweld @ 4' PVC CondUit, Sch 40 @ Elbow loadbreak connector With cold shnnk 7040 3 ( Included wi cabinet) as required 6' 2512 as required 3170 38' approx. 2502 2 2 1368 as required 8032 as required 715x ; NOTES: 1. Grout around condUit at vault. 2. Backfill to be mechanically compacted In 6" lifts to 90% maximum Proctor density. 3. Ground to be sloped down and away from the top of the vault. * 4. Omit ground rods when grounded vault is used. Date lfthL Appd Eng' Appd Ops Revised' THREE PHASE SECTIONALlZING CABINET Sheet-2- of~ CITY OF PORT ANGELES ELECTRICAL ENGINEERING SPECIFICATION U 3 04 ~4'~ r-18' -1 / // / " / / ,/ /' ~ : /;: / ". "//",'[', 1/'/"'/ :, /' ~"...""" / ," .. , '" " [' ' " ,,.' .. / " ' 1/ .. /' " .,," , ' , L,','/'/'> ",/ ~/,..../ " ,/1/,-" ' ... . -{C'" .' /: '.:</, ,'", ~J ", ' '-I' " " ',' . " ". '/v /1//'''''/' ..../"//~/:///1,/ ... " ,,/, I' // (/,,':,,',_, ' 1/ " , "..... .... ... ' .. ...'" " '.... .. \.~......, .".. ......,.. '// :.)47'"-' ~'/ / ,/"... // v.. " '.' / .< // . '," ." " ES r-r Q . '~~" .',./ ,"/"", './~t.'-" ~ '0 ' ' 1/ " '. ' / 1. f--1-l ~ -" /1/>:', ' / ---: / 1/' 1 2" 2" " 1 /" ,/ , " '<1-..'" ,,',12_", ". >" ':/~', .. /<>1/, "'1:<:: ':'>l~ ' ~//"" " /y", ',' / / " ,'/, "/,,'.,' I I ',/ / /, I I" ' / / /, ,'.... / ,/,', 1-_________''. ,/ .. > ' //' ",,/' ~" ',/1' " ,,/',...., ,,/ " ,'/ /''./ ','/ /", , '/ /'" / ..... / ./ " // ,/ '" / ,I",,/ / / c , I 'I' / ' : 3Q.l, -' ,/ '''.' '''~ , . / -", /' / /~ ". '~, ", .., .' r -, /' /, I . ' ~ ... '> '-, /~>~.,. )<;.~><<~<~, .. "../"-, ,,, . ,/'........ .... <,'......." ',:../ ....... '...., '. '. TRENCH NOTES 1. ALL GRADES SHOWN ARE FINAL GRADES 2. ALL COVERAGE DEPTHS AND SPACING DIMENSIONS ARE MINIMUM. 3. THE BOTTOM OF THE TRENCH AND BACKFILL WITHIN 6 INCHES OF ELECTRICAL CONDUIT SHALL BE FREE OF ROCKS LARGER THAN 1.5 INCHES. DEBRIS. PAVING MATERIAL, SHARP ANGULAR OBJECTS OR CORROSIVE MATERiALS THAT MAY DAMAGE THE CONDUIT!CABLE OR PREVENT ADEQUATE COMPACTION OF BACKFILL. IF TRENCH BOTTOM CONTAINS ROCKS EXCEEDING THIS LIMIT THE TRENCH SHALL BE OVER EXCAVATED BY 6 INCHES AND THEN BEDDED WITH 6 INCHES OF ACCEPTABLE MATERIAL AND COMPACTED PRIOR TO iNSTALLING THE CONDUIT, 4 MINIMUM COVER AND TRENCH DEPTH REQUIREMENTS SHALL BE INCREASED BY 12 INCHES AT UNDEVELOPED LOCATIONS WITHOUT FINAL GRADE STAKES CUSTOMERlDEVELOPER RESPONSIBLE FOR COSTS ASSOCIATED WITH RELOCATION OF UNDERGROUND FACILmES DUE TO SUBSEQUENT GRADE CHANGE. 5. THE DEVELOPERlCUSTOMER is RESPONSIBLE FOR PROVIDING FINAL GRADE OF THE TRENCH AND WILL BE RESPONSIBLE FOR ANY SUBSEQUENT GRADE CHANGES AND THE ASSOCIATED COSTS TO RELOCATE UNDERGROUND FACILITIES. 6. TRENCHES 48 INCHES OR MORE IN DEPTH INTO WHICH A WORKER MUST ENTER SHALL HAVE ADEQUATE PROTECTION PROVIDED PER WAC 296-155. 7. ALL CONDUIT TO BE 1 INCH MINIMUM FROM SIDES OF THE TRENCH. THIS SEPARATION IS REQUIRED FOR ADEQUATE COMPACTION. 8. ALL ELECTRICAL TRENCHES MUST BE INSPECTED AND APPROVED PRIOR TO BACKFILLING. 9. CONTROLLED DENSITY BACKFILL REQUIRED UNDER ALL PAVED STREET SURFACES. LEGEND ES - ELECTRIC SERVICE T - COMMUNICATIONS EP - ELECTRIC PRIMARY TV - CABLE TV TRENCHING: PRIMARY, SECONDARY, TV, & TELCO DEPTH ENGINEERING SPECIFICATION CIIY OF PORT ANGELES LIGHT DEPARTMENT Sheet--Lof 1 UM 0 01 ~ Date: M Appd. Eng: ~ Appd.Ops: ~ Revised: PARKING BUSHING - STOCK NUMBER 7125 UM 0 07 PROTECTIVE CAP - STOCK NUMBER 7190 UM 0 08 PARKING BUSHING PROTECTIVE CAP Sheet 1 of 1 UM 0 07 UM 0 08 ENGINEERING SPECIFICATION CITY OF PORT ANGELES UGHT DEPARTMENT - ......L'l'=.:(Nf'.ll::. LlJl.A'l'.LUN : '-,:-l .LV :< / -....., "DP-.NGER, UNDERGROBND SACK FEElY' SIGN. REFERRED LOCATION FOR 10"x 7" "'JANGER, UNDER- GROUND SAC<FEED" SIGN. ;:''1' ) f-J ~.;: 1.~ STREET SIDE -' ,- /' ~~ ~ i ~;j , ~ ~ ~ t\t~~ \\ J ! ". I '~ H [ -' := ALTERNATE LOCATION FO 10"x7" "DAN UNDERGROUND BAC!<FEED" SIGN . .....g NO~E: 1. USE ALTERNATE LOCATION ONLY IF PREFERRED LOCATION NOT ACCEPTBLE & CLIMBING ABOVE NOT ALLOWED, 2. INSTALL USING GALVANIZED CO~~OGATED NAILS. Dale. ENGINEERING SPE.CIFICATION SHEET ~ of ~ ApDd. ENG: " fee iJ " :::, 1(,1 ,'-.j STANDARD SPEC. No. Appd.OPS: DAWG:::6'Z.. - U U D;:; c. ~ :'2..D [jJ-.):J ~\C..~ LJM 0 II Revl~ed : CITY of PORT ANGELES LIGHT DEPARTMENT u. T ~ ":NSTALL 10 "x7" ~'-', "DANGER, tJNDERGROUND 3ACKFEED" SIGN uSING 4 GALVANIZED, CO~qOGATED NAILS I STREET SIDE @ :\ -~ i:l PROPERTY SIDE R I II I I I i I I ; I I U I I I I , I I I I I W W , 3' I I I I r- I ~~ ..~.~ . - \\ o ---= ., 3' i _--INSTALL 10"x7" "DANGER, UNDERGROUN BAC!< FEED" SIGN uSING 4 GALVANIZED, CORRCGATED NAILS. ~II' I' Dole. A .ENG. ApOd.OPS: RevISed. ENGINEERING SPECIFICATION ~ r 1 ""1(:- f/ _ " ,.- !.:..- .. .C'-, I, 1 --. ;:?-" - 1 / r;:::-,. - I' .../ ;\r....\(...::.J_ ~ :.... '-.,I, _ _.::;,~ -' I'" _ _....~--- I, ___ V :.tilj-\ SHEET~Qf ~ . STANDARD SPEC. No ! JM D II CITY of PORT ANGELES lIG HT DE PARTMENT , I ~.1 1) 6 ft. x 9 inch diameter concrete bollard set min. 2 1/2 ft. in the ground and in gravel, compacted. 2) For customer installations: 6 ft. x 6 inch diameter concrete filled steel pipe set min. 2 1/2 ft. in the ground and in gravel, compacted. Date: \0/4/ <13 Appd.Eng: ~ Appd.Ops: ~ Revised: ENGINEERING SPECIFICATION BARR I CADE SHEET 1 of 1 STANDARD SPEC. CITY OF PORT ANGELES LIGHT DEPARTMENT UM 5 02 UM ATTACHMENT G CABLE TAGS J--ELWHAREBUILO-STAGE2--:'.CABLE NUMBERS , ~ ~ - -- --_._-~ ---- ----------" - - -- - -- -~-- --- .~-_.~-_. ------- ~~--_. ------ :PROJECT02-11B 2/11/04 , 1-- ,._,-- -- ,-,,-,------- ----- ---- - ------- J LOCATION CABLE NUMBER PHASE Riser pole to Vault 10 2182 A 2183 B 2184 C Riser pole to Vault 10A 2185 A 2186 B 2187 C Vault 10 to Vault 11 2188 A 2189 B 2190 C Vault 10 A to Vault 11 A 2191 A 2192 B 2193 C Vault 11A to Vault 12 2194 A 2195 B 2196 C Vault 11 to Vault 13 2197 A 2198 B 2199 C Vault 12 to Vault 14 2200 A 2201 B 2202 C Vault 13 to Vault 15 2203 A 2204 B 2205 C Vault 14 to Vault 16A 2206 A 2207 B 2208 C Vault 15 to Vault 16 2209 A 2210 B 2211 C Vault 16 to riser 2212 A 2213 B 2214 C Vault 16A to riser 2215 A 2216 B 2217 C PULL-PLANNER~ 2000 PULL 1.0.: elwha CONDUIT INNER DIAMETER: 4.75 INCHES CONDUIT FILL: 11 % TOTAL OF 3 CABLES OF 1 DIFFERENT TYPES BEING PULLED. CABLE # 1 3 CABLES 0.0. OF 0.945 INCHES WEIGHT OF 1.647 LBS/FT TOTAL CABLE WEIGHT: 4.941 LBS/FT CALCULATED WEIGHT CORRECTION FACTOR: 1.08 CONFIGURATION: CRADLED JAM/CLEARANCE ANALYSIS: JAMMING NOT PROBABLE COF= 0.2 INCOMING TENSION= 0 LBS STRA SECT ANGL UP STRA OR SECT DOWN LEN(ft) BEND TYPE UP OR BEND BEND DOWN RAD(ft) ANGLE TENSION(lbs) SW PRES (lbs/ft) SEG 1 o NA 1200 NONE NA o o 1281 o ATTACHMENT H PROJECT PLANS 5 START OF PROJECT VAULT 15 L POINT & 10 NO ~ LOCA TION 16B ,/W/SEGTIONALlZER CONTROL POINT '& 10 NO CONTROL LINE ' i /CONTROL LINE OUND POWER LINE -p- VAULT 16 & 16A r., , .'UNDERGROtJND POWNS LINE ~p~ WATERL~ w-....-, /GRAV~L"DRIVEWAY" /....': ,~_/""'" "'V'''''-WAT(~~~!!,S''''-'~w- OVERHEAD Ip~i~ ,." '.....J / r _ c-- \ \ UND~~ROUND I', r) '.,' I' \ .' / VARIOJ!? WA r. t1C~L VE5 I "" ....-..../ ....-..... ACROSS CRE i I ~ \ '!\O\?C \ ,.< \-- ; .. COMMUNICATlON.1INE '.', y:/ AND M ._____--> / l I I, I I clJ" 'C;.'" - " .. 3- "_.._'--'~'-" . - <- ,---, ---. --- -- -1-' --'3; c -...--.;-. . u --..- ..--- ..::::: 6'" ~~~T[,R L!HE ' , - --~.. .. '. --.---.::=---- .----__...........~ ........./ t 1-4" PUD ' . " .?-~v.. l MH5 ......./ 0 ~ t __"-_., ,_', ~~H __', ,', ','_ ~:" ,~.. ' , .. ,.' _-,.. ,,~_~ ~ ,.,~. '~, , ~ ,.._ __.-1. I~~~.~~ .w ~~ 0;': HP -- OH P ~ ..,",,-P -j- N' "?J '-.: '='1.4!- ~.~_~-:---.:- --"t j;i~~- ~'~:-=+-w-' -..04.-----=:ti-=--. ~ IF -=1- ~.,~:. .~B~=~.:,~-~ --.-=4::~=::-.=v.- .:~'---' - . j;',-" ~ :-=-fti=_~9-.::?t{~-...~--:::.. .- -- -e' 70 @ J . ~, ,.J ".-(~'aHP~aHP-DHP-aHP-aHP-aHP' 5'}:..O~ ~ . -- 7:OO~ 1 58+00 59+00 .60+00 61+00' . 2+00 63+00 64+00 .' . - --. -- 65+00 1-- ~ 70 "" ~~~~~~D'~'~GLE- PHASE ELE: -2VAULT & 6" WATER LiNE --.. I~ .. ~ ~ ~ . , ~ GR~ CE; , D;;E~A jr "'00_ ";:: "" __M'OO - 1: ' -- · ~RANSF9RMER FROM 4TH WATER VALVE GRAVEL_ QR/VEWAY ~, " ~I~ RISER TERMINATION " CONCRETE WATER VALVE POST , '_" . ~~ " WHILE TRENCH IS LOCATIONS 10-14. TRENCH AND INSTALL 2-'5" POWER POLE No. 3007'::"'027567> GUY _. .)r.----..__ Vl~ CENTER OF CREEK .OPEN BETWEEN VAULTS 13 AND 15 AND 1-4" CONDUIT. LOCATIONS 14-16 TRENCH' ANCHOR AND C6~MUNICATI?N'P'!.rJCsrAL /, ~13= .' COORDINATE WITH THE PUD AND INSTALL 2-5" AND 2-4" CONDUIT 4" COMMUNICATIONS ". - i "-- ~II~ TO INSTALL THEIR CONDUIT CONDUIT BY-PASSES ALL VAULTS. SECTIONAUZE THE ONE 5" ~: CONDUIT AT VAULTS 10A, 12, 14 (NO CABLE). " ,/ .~~' SECTIONAUZE THE OTHER 5" CONDUIT A T VAULTS 10, / _.: . 11, 13, 15 AND INSTALL 3-350 MCM CU UNDERGROUNIJ' CABLE SECTlONALlZED AT VAULTS. TERMINATE ANC}' CAP THE 4" CONDUIT AND SPARE 5" CONDUIT 12" ABOVE: GRADE AT LOCATIONS 10A AND 16A. ~5 ...... I i , --' " VAULT 14 '. , SERVfC'E /POLE \ ,/ , \ I/O,... ,/ ,,/ \ tffA VEL DRlVaWA , ' , -f/-" --..~ ,- ' ....- -.' ..~..- f ....-. -..... \ ., ......----......-..... \ " ........~..\...... :. \ ~- ....-. ........ ,- ...... .-..~ ~..., I! ~-, ....- /.-"'" ( ! I / ~'-_/" VAULT 13 W/SECTIONALlZER CONTROL POINT & 10 NO. CONTROL LINE UNDERGROUND POWER LINE WA TER LINE ~5 76 ~ 504-4:5.31 cP 5 ~ 544- 52.55 cP 7 :::::::::: 554- cP 6 ....,.... ~' ~ -.......-.---- \.\ -.----- ""'" '" _ ,\,:/ /......./....--- 1500 " ',\' Y ---- ...---- 07-01 ~~.?\: t, .: OAOWA.....----- NO. 30 ~ ... .' -0 '~\'~ f{JNfJ) ~ ,"E:R PO~NCHOR ~~1l ,//' oQ' i=, \K'; pOv' GUY <::) '5- / I- 'u \" NO ~// U \\4 \\ A <;l"~ w~ ...~ . IJ) " \ \ REMOVE ENTI~RE // \ ~~,. -'> , \ MANHOLE AN ,/ ~ :A/~ . \ .. ",' BACKFILL // .-::/:' '~ VAULT 11 /,/' //" ~~ ~~~/C:R6NALI,~7~~' ,." ~ {J// / ;:.?S.. . ..... # //"JrrP ~/.. &'J. .17.. ..- \ . ...... ....,.... , 1- " .-- II --- /. ---.., L . , / , SERV/G'[ ,POLE ~ D ;GRAV:L _DRIVEWAY~~/ EDGEOF ROAO ~ROW .. .. ~___~AU~T '~ I '1 EPCE 3.F::-- ~''':;4' ,i' ' , o ; f ., -l- -I-;::'-G~~~':--- 'I' '_'p"<-_ "p I'~'=-P -""p --. P F -'p P P P -p- '..-:-- 'p'. .. '0.." '---1:'':;' ~\-p-I~"~p . '=:7~:p.~~~" . E:80 0 l7= =! \;I ""I 1-=4 ~ ==F ="4' "=4 ...., 1 a'~~ ~\~. '-a'up"\~a.::,,~7~awH-P- -.' Ii' W~"'-'7'8+0-:-0-\..~-;';O +oo",^TE:R UN ':~_~H-~:~ll 'u~-~,~~_= ~~;"oo G\_ ",:c"',,:; c ";";---::::0-- ,J'; ':'00 \ II - ",00 " ,,," "'" _~PO~~~_6~6~2_:_ _':- U f10NS; , 'm ____ ____ u__.___ ___ .. __._. ~----- _. .__ ._____- -5B uNICA ~I POWER POLE NO. 3007-027500 .:tROW POWER POLE NO 3007-028503 UI..T AND :~ cONl~srAL _ <I~ ADJACENT TO CONTROL A .."fE~ 'rAr Vf.L'vf--. --2_..p~~ _/ -:....-~ f- <.:> v''''' IJ'JO : - .... Vl a:: 8\..0" ~~ N uNE: ~Iw 1 ,/::; cRHE:A c,,'no =:ilij ,.// (.;1-2 .....~oV[;. NlNIUNI ,... 5~ ~ / \ E-3 sE:C~:r CO ~w,./'/ \ NE:1/4 E:CT10N -P- -w- \ ....---- ....----. --.---.. 50 0 50 111111111.1 I 100 I DES CL 0.... ON ~ ~~ CITY of PORT 12.47KV UNOERCROuND Ol:STRlBUl1ON -"-----.i 1" = 50' ELWHA UNDERGROUND REBUILD fiLE NO P AKOl 003 WID 11-00803-10000 owe NO POINT & ID NO ROL CONTROL LINE _p UND POWER LINE. ___ OHP- , o UNDERGRO D POWER LINE ~w...,.:....- ~ O,,!RHEA WATER LINE POw/~'~ ~ ;:O'e NO~"Q -,~ ~" CUy 4NCk,~-...,_ 4NCHo~r' 0'>-'0, '500 '-... .. __ <c, ~II~ "ROW, --" I , ....Je:> ----..- _h_ IT 10 I, _'__ _ " .. VAU '., ~Iw j;2LOCATION 108 ,,_' '.:.:.'~~~ ~<I~ 0 P~'>, ,-,+-,_' ~,t1'" .', "/00 ~, ;- -\of __ OMP 86+00 / . , OHP '" M.OO , 9 & 9A . 83;00 / 84+00 - - \ / L VAUL\ \ +ROW '- POWeR Ie '- ./ ~ ~ \, \ CUy -" O'e wlr" CeNJ<R ~ _ _ _ _ ~ )\ '\ \ 10A o"CHOR" , 0". Db" ~ ',- VAULT "_"'" 'c, CReek ~ ~ ~~ IA- . WAlE/? Willi 8L.~~L.I(S) OFF k4L. VE ~"-" ----- ----.....-... ~ ......... --- "-...... ....- " 7 I---._~ I; " " " 50 0 111111111,1 100 I 50 I 1" - 50' , "\ "_...1' UG"~15KV CABLE TO..... XFMR. /~_........ \ ~, .-' -~I?<\ --I --,p P GH-POHP ~ / --' . I P-OH ,-_ ,- ", ,-~ '" '- L....': "" +-- ~ I __ , OHP~ OHP" ' - ._._.. _" h_ ___ _ ""'- ", , I -, -- , .. ..... -~~-=f;{'~'tg~~R~~B- cAEikFROM POLE 56+ 00 REMQ-V9>'VAUL'if TO \ EXIS"ftN& RISER POLE ,0 ! I TO RESIDENT ~ ........ / / '\'", '\ '>""" " '\ ", '\ '\ " "\ P P P P -It \of \of \of ~ ,-,j::., ' , /-...1 l ,:::. '., )' , -- ~'. 4" CONDUIT ,C CAP ONDUIT \;~'.\ -:phLACE C ' MARKER \ \ - L.... -" . 0.. . ~ f'-.f- R/W ... \ :~ ....... ~_.)"\ " t VAULT 1 ,'. --~ -- - -- , . 5"-+~~MqVE MAN LID AND BAC DETAil E', SCALE '"=15' ~ ~~ I"""" m.E NO PAK010l0 W/O 11-00803-10000 DWG NO CITY of PORT ......._~".,....- GROUND DiStRIBUTION 12.47KV UNDER UNDERG_R aU.ND REBUILD ElWHA EXTEND CABLE NEUTRAL ALLOW 6' SLACK fOR DISCONNECTING AND PARKING lERMINATIONS .1 I' 0" STRAIGHT BEfORE STARTING RADIUS 600A ELBOW TERMINATOR, 15KV CLASS DETAIL NO SCALE LOADBREAK REDUCING TAP PLUG ELASTIMOLD 6SDETP OR APPROVED EQUAL INSULA lED PROlECTING CAP PROVIDE WHEN A TAP CIRCUIT IS NOT INSTALlED, SEE DETAIL SEPARAlE GROUND WIRE AND ATTACH TO J-BOX GROUND LUG, TYP 2 PLACES GROUND LUG 60DA FEEO- THROUGH 4 WAY JUNCTION WlTH 200A TAP DETAIL NO SCAlE CD R/W r LOCATIONS 10 TO 11 LOCA TlONS 11 TO 14 0-1-4" o 0 - 2-S" ~ o (V SECTION NO SCALE +- 1- If II tr#ot\ II lie /lOtS J.,dl4lftC. C&.,.1I0~ ,( "Ad .' ELASTlMOLO ISKV CLASS CATALOG NO 168DRG OR APPROVED EQUAL NOlE , EACH UNUSED JUNCTION BUSHING SHALL HAVE ONE Of THESE CAPS 15KV CLASS INSULATING PROTECTIVE CAP ELASTlMOLO ISKV CLASS CATALOG NO K656DR OR APPROVED EQUAL DETAIL NO SCALE 2 15KV CLASS INSULATING PROTECTIVE CAP R/W R/W 600A, ISKV CLASS LOADBREAK JUNCTION ELASTlMOLD K6S0J4 OR APPROVED EQUAL ELBOW PARKING, ONE POSI1l0N ON EACH SlOE 2/0 CU \ \ DETAIL NO SCAlE CD o SECTION NO SCAlE LOCATIONS 14 TO 16 I-J-" + 1-4" _ 0 cf ~+UD I 2-S"- 00 (V R/W ~ -~ CONSTRUCTION NOTES 1. SEE SURVEY DRAWlNGS ELWHA UNDERGROUND DISTRIBUTION LINE REBUILD PROJECT 22-11", DATED 8/1/02 BY NTI SURVEYING. PORT ANGELES 2. SEE CONSTRUCTION DRAWlNG FOR UNDERGROUND POWER LINE Cll062-5 DATED 08/77 AND FOR WATER LINE C11062-2 DATED 08/77. CITY of PORT 1247KV OVERHEAD DISTRIBUltON ELWHA UNDERGROUND REBUILD STAGE 2 1-2J-2OO.l FiLE NO PAK01038 Wlo 11-00803-10001 OWG NO CITY OF PORT ANGELES, LIGHT DIVISION-STAKING SHEET DEPT I D ---~------ --- - ~ --- ------- - ---~- ---- --------~-- -- - - - - -- --- ----~-- ELWHA REBUILD STAGE 2 PROJECT NUMBER 02-11B ACTIVITY ------- -----~------------------~--------- - - - - --- --------- SHEET 1 OF 1 DESCRIPTION --- -------- --~-------- --- - - ---------~--------- ------------ ---- --------- --- -- - -- ----- PRIORITY ENGINEERED BY CHAD LARSON DATE - ---------- ___ - - ___n __ ------------------~-------- -- ------- SPECIAL INSTRUCTIONS CHECKED BY K C FAGEN DATE SYMBOLS ----- - --- --------- --------~- ------ LOCATION DATE ISSUED REVISED E-EXISTING ----- ~----- - ---- -- ------------~--- DESCRIPTION OF WORK FOREMAN FILE R-REMOVE - ------ SUBSTATION/FEEDER START DATE OTHER A-ADD ---- ----- -- --- --- LOCATE COMPLETION DATE COMPLETED OPS MGR ---- COPIES MAINT INSP CREW DPW TOTAL -- ----- LOC POLEN AUL T DISTANCE WIRE SIZE MISCELANEOUS CONSTRUCTION UNITS PORT ANGELES CONSTRUCTION SPECIFICATIONS MISC. & REMARKS NO. NUMBER FT. E 10B 10B R lOB 10B RC A 10B 10B 50 350kcmll CU BFV, UM 0 11 U 302 U 3 02 use 5" Conduit and Brackets. Distance IS the Riser E 10 10 R 10 10 A 10 10 50 VLT Distance is to Pole Location 10B E 10A 10A R 10A 10A A 10A 10A 50 VLT Distance IS to Pole Location 10B E 10C 10C R 10C 10C RC A 10C 10C BFV E 11 11 R 11 11 A 11 11 300 350kcmll CU U 304M, 6-600AE Distance is to Vault 10 E 11A 11A R 11A 11A A 11A 11A 300 VLT Distance is to Vault 10A E 11 B 11B R 11 B 11B RC I A 11 B 11B BFV I E 12 12 R 12 12 , A 12 12 550 VLT Distance IS to Vault 11A E 13 13 R 13 13 A 13 13 1000 350kcmll CU U 304M, 6-600AE Distance is to Vault 11 E 14 14 R 14 14 A 14 14 1000 VLT Distance is to Vault 12 E 15 15 R 15 15 , A 15 15 1000 350kcmll CU U 304M, 6-600AE Distance IS to Vault 13 E 16 16 R 16 16 A 16 16 450 VLT Distance IS to Vault 15 E 16A 16A R 16A 16A A 16A 16A 925 VLT Distance to Vault 14 E 16B 16B R 16B 16B A 16B 16B 150 UM 0 11 U 3 02 U 3 02 use 5" Conduit and Brackets Distance IS to Vaults 16 & 16A, & Riser E 16C 16C R 16C 16C RC A 16C 16C BFV I RC RS BFV VLT U 304M 600AE REMOVE COVER AND VAULT LID REMOVE SECT10NALlZER AND VAULT LID BACK FILL VAULT INSTALL STOCK ITEM 7030, 7031, AND SECURED COVER FOR 18" X 60" CUTOUT MODIFIED PORT ANGELES SPECIFICATION U 304, 200AMP LOADBREAK COMPONENTS HAVE BEEN CHANGED TO 600 AMP DEADBREAK (SEE DRAWING E3 DETAIL 3 FOR JUNCTION) ELBOW DETAILED ON SRAWING E3, DETAIL 1 Staklng(Stage2) Page 1 R.W. Beck Inc. CITY COUNCIL MEETING July 6, 2004 PUBLIC COMMENT FOR ITEMS NOT ON AGENDA (Cont'd) Break FINANCE: Elwha Underground Cable Replacement - Matenal Purchase ElectrIc Underground Rebuild Phase II, Project 02-11B, Elwha Lme Stage 2 Peabody Creek Water Mam, Project 02-02 Famnount Pump StatIOn, Project 02-26 </. <174./ neighborhood needed the sewer lme and time was runnmg out. CouncIlmember Mumo stated that the neighborhood, includmg Mrs. Schmuck, voted to be annexed and receIve sewer servIce. He stated that each resident knew how many lots they would be paymg for at the time it was decIded to annex, and this dId not change. Paul Lamoureux, 602 Whidby, wanted to inform the Council that he had a glowmg and positIve report from the southeast neighborhood. He stated that the PublIc Works Department listens to safety concerns ofthe citIzens. He wanted the Council to know that good thmgs are happemng around the CIty departments and gave hIS congratulatIOns to Finance DIrector ZiomkowskIfor domg a greatJob on budgetmg and wInnmg the Budget A ward agam. Mr. Lamoureux expressed hope that in August a report WIll be gIven by the PublIc Works Department regardmg the downspout dIsconnectIOn project and on the energy program. Mayor Headnck recessed the meetmg for a break at 8: 12 p.m. The meetmg reconvened at 8:29 p.m. J Elwha Underground Cable Replacement - Matenal Purchase Director Cutler summarized the proposed purchase of underground electrIcal cable from Consolidated Electncal Distributors (CED) through the State of Washmgton Procurement Contract #07400. Councilmember Rogers moved to authorize the purchase of underground distribution cable for Light Operations, and authorize the City Manager to sign the purchase order with CED in an amount not to exceed $69,000. The motion was seconded by Council member Braun and carried unanimously. 2 Electnc Underground RebUIld Phase II, Project 02-JJB, Elwha Lzne Stage 2 DIrector Cutler presented mformation regardmg bIds requested to rebUIld approxImately 2,700 feet of underground electrIc servIce. Brief discussIOn followed and DIrector Cutler responded to questIons and provIded clarificatIOn. Councilmember Rogers moved to award the contract for the Elwha Underground Rebuild Phase II, Project 02-11, to Superior Electric Northwest Inc., and authorize the Mayor to sign the contract in the amount of $119,108.34. Council member Williams seconded the motion, which carried unanimously. 3 Peabody Creek Water Main, Project 02-02. DIrector Cutler summanzed the mformatIon regardmg the request for bIds to mstall approxImately 6,400 linear feet of water mam within the OlympIc NatIOnal Park and north along Eunice Street to 9th Street. Followmg bnef dIscussIOn and clanficatIOn, Councilmember Williams moved to award the contract for Peabody Creek Water Main, Project No. 02-02, to Snelson Companies Inc., and authorize the Mayor to sign the contract in the amount of $1,271,101.94. Councilmember Braun seconded the motion, which carried unanimously. 4 Fazrmount Pump Station, Project 02-26 Director Cutler reviewed the mformation regarding the request for bIds to mstall a water pump statIOn and approxImately 2,200 lInear feet of water mam to the FaIrmount area along US 101. - 8 -