Loading...
HomeMy WebLinkAbout1608 W 16th St Technical - BuildingTECHNICAL Permit# U 5 Address I (0 8 (0+h S+ Project description CA0.1\am Cocrh Fairq rounds lovt€ Ar Bu■ Idi of Date the permit was finaled l- 15 07 Number of technical pages -7(0 March 2006 FOR THE Set Number: Date: BID AND CONSTRUCTION SPECIFICATION FOR THE FAIRGROUNDS HOME ARTS BUILDING RE -ROOF fZ Project No. 620610FG G BOARD OF CLALLAM COUNTY COMMISSIONERS: HOWARD V. DOHERTY, JR., CHAIR STEPHEN P. THARINGER MICHAEL C. CHAPMAN LINDBER( MITH A R C H I T? .E C TS 319 South Peabody Street, Suite B Port Angeles, WA 98362 (360) 452 -6116 (fax) 452 7064 TABLE OF CONTENTS Title COVER SHEET BIDDING REQUIREMENTS END OF TABLE OF CONTENTS Clallam County Parks, Fair Facilities No. of Pages 1 TABLE OF CONTENTS 1 DIVISION ZERO Section 00100 Notice of Call For Bids 1 Section 00200 Instructions To Bidders 5 Section 00300 Bid Proposal Form 2 Section 00400 Supplemental Bid Forms 7 Section 00500 Form of Agreement Between Owner Contractor 2 Section 00600 General Conditions of the Contract 16 DIVISION ONE Section 01001 General Requirements 5 DIVISION SIX Section 06100 Rough Carpentry 2 DIVISION SEVEN Section 07210 Building Insulation 3 Section 07311 Asphalt Shingles 6 Section 07400 Metal Roofing 4 Section 07600 Flashing and Sheet Metal 3 Section 07900 Sealant 4 DIVISION NINE Section 09900 Exterior Painting 3 PREVAILING WAGES Clallam County State 9 Table of Contents Fairgrounds Home Arts Building Re Roof March 2006 Table of Contents DIVISION ZERO Notice of Cat for Bids Section 00100 SEALED BIDS will be received by the Board of Clallam County Commissioners at 223 East Fourth Street, Room 150 Port Angeles, Washington until, 1000 A.M June 27 2006 at which time they will be publicly opened and read aloud for Complete drawings and specifications may be obtained from Clallam County Parks, Fair Facilities Division of Public Works in the Old Courthouse, Room 180 Monday through Friday from 8.30 a.m to 4 30 p m. All bidding and related questions should be directed to Lindberg Smith Architects at 360 -452 6116 The sealed bids must be clearly marked on the outside of the envelope "Bid Proposal Fairgrounds Home Arts Building Re- Roof Address bid proposal to Board of Clallam County Commissioners 223 East 4 Street, Suite 4 Port Angeles Washington 98362 or hand deliver to 223 East 4 Street, Room 150 Port Angeles, Washington Bid documents delivered to other offices and received late by the Commissioner's Office will not be considered nor will bids received by facsimile or e-mail. Clallam County will determine the lowest responsible bidder in accordance with the terms of Clallam County Code Section 3 12.060 and further reserves the right to reject any or all bids received, or to accept the bid which in its estimation best serves the interests of Clallam County or to waive informalities in the bidding. END OF SECTION 00100 CLALLAM COUNTY PARKS, FAIR FACILITIES DIVISION NOTICE OF CALL FOR BIDS Fairgrounds Home Arts Building Re -Roof Construction Timeframe: August 28. 2006 September 15. 2006 Access to the site is possible weekdays through the north main gate Prospective bidders are encouraged to visit the site in order to familiarize themselves with the B ing and Contract requirements Date. Q (o SOO BO 'OF ATTEST Please publish (Peninsula Daily News Trish Perrott, Clerk of the Board CMC Fairgrounds Home Arts Building Re -Roof March 2006 Division 00- General Conditions Clallam County Parks, Fair Facilities "Iftbward V Lt rty Jaai� COUNTY COMMISSIONERS June 11 18, 2006) DIVISION ZERO Instructions to Bidders Section 00200 INSTRUCTIONS TO BIDDERS ARTICLE 1 DEFINITIONS 1 1 Bidding Documents include the Bidding Requirements and the proposed Contract Documents Bidding Requirements include Advertisement and Notice of Call for Bids Instructions to Bidders Bid Forms, Sample Contract Forms and Supplementary Instructions Contract documents consist of Agreement or Contract Form between Owner and Contractor Conditions of the Contract including General, Supplementary Drawings Plans Specifications and all Addenda issued prior to execution of the Contract. 1.2 Addenda are written or graphic instructions issued by the Owner or Owner's representative Architect, which modify or interpret the Bidding Documents by additions deletions, clarifications or corrections 1 3 A Bid is a properly completed and signed proposal to do the work for sums stipulated and submitted in accordance with the Bidding Documents 1 4 The Base Bid is the sum stated in the Bid for which Bidder offers to perform work described as the base to which work may be added or deleted for sums stated in Alternate Bids 1 5 An Alternate Bid is an amount stated in the Bid to be added or deducted from the Base Bid if Alternate work is accepted 1 6 A Unit Price is an amount stated in Bid as a price per unit for materials equipment, or service as described in Bidding Documents 1 7 A Bidder is person or entity who submits a Bid 1 8 A Sub bidder is a person or entity who submits a bid to a Bidder for materials equipment or labor for a portion of work. ARTICLE 2 BIDDER'S REPRESENTATION 2.1 By making a Bid the Bidder represents that the Bidder has visited the site and become familiar with local conditions under which the work is to be performed has read and understands all Bidding and Contract Documents and correlated personal observations with the requirements of the proposed contract documents. Site visits shall be as stated on Notice of Call for Bids 2.2 The Bid is based upon materials equipment, labor and systems required by the Bidding Documents without exception ARTICLE 3 BIDDING DOCUMENTS 3 1 1 Bidders may obtain complete sets of Bidding Documents from the office designated in the Advertisement or Notice of Call for Bids at no charge (Each set consists of (1) each drawings and specifications with a limit of two (2) sets per bidder) All bidders shall return documents within seven (7) days of bid opening A bidder receiving the Contract Award may retain Documents 3 1 2 Bidders shall use complete sets of Bidding documents in preparing Bids neither Owner nor Owner's representative Architect assumes responsibility or errors or misrepresentations resulting from use of incomplete Bidding Documents Fairgrounds Home Arts Building Re Roof March 2006 Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO Instructions to Bidders Section 00200 3.1 3 In making copies of the Bidding Documents available the Owner and /or Owner's representative Architect, do so for the purpose of obtaining Bids and do not confer a license or grant permission for any other use of the Bidding Documents 3.t4 Copies of bidding documents and specs are available for review in Parks Office Room 180 in the Old Courthouse 3.2 Interpretation or correction of Bidding Documents 3.2.1 The Bidder shall carefully examine the Bidding Documents examine the site and local conditions and compare them with other work being bid concurrently or presently under construction to the extent that it relates to work being Bid and shall at once report to the Owner and /or Owner's representative Architect errors inconsistencies or ambiguities discovered 3,2.2 The Bidder and sub bidders requiring clarification or interpretation of the Bidding Documents shall make a written request to Owner and /or Owner's representative Architect at lease seven days prior to date of receipt of Bids 3.2.3 Changes in the Bidding Documents will be made by Addendum and changes made in any other manner will not be binding and Bidders shall not rely upon them 3.3 Substitutions 3 3.1 The materials equipment, products described in the Bidding Documents establish a standard of function, dimension appearance and quality to be met by any substitution 3 3.2 No substitution will be considered prior to receipt of Bids unless written request for approval has been received by Owner or Owner's representative Architect at least ten days prior to the date for receipt of Bids Such requests shall include the name of the materials or equipment for which it is to be substituted and a complete description of the proposed substitution including drawings performance and test data, and other information necessary for an evaluation A statement setting forth changes in other materials, equipment or other portions of the Work including changes in the work of other contractors that incorporation of the proposed substitution would require shall be included The burden or proof of the merit of the proposed substitution is upon the proposer The Owner's decision of approval or disapproval of a proposed substitution shall be final 3 3 3 If the Owner approves a proposed substitution prior to receipt of Bids such approval will be set forth in an Addendum Bidders shall not rely upon approvals made in any other manner 3 3.4 No substitutions will be considered after the Contract award unless specifically provided in the Contract Documents 3 3.5 Should any proposed product substitution require any redesign work by the Owner and /or Architect or his consultations to accommodate the substitute product, costs for such redesign work shall be included in the Bid amount and shall be paid to the Architect or Owner at his usual rates for the time expended in the required redesign work. ARTICLE 4 BIDDING PROCEDURES 4 1 1 Bids shall be submitted on forms identified to ones included in the Bidding Documents shall have all blanks filled out in ink (typed or manually) with sums expressed in words and figures where indicated with words governing and all alternates and unit prices bid If alternates do not change Base Bid enter no change Fairgrounds Home Arts Building Re Roof March 2006 Division 00- General Conditions Clallam Count) Parks, Fair Facilities DIVISION ZERO Instructions to Bidders Section 00200 4 1 2 Interlineations alterations and erasures must be initialed by signer of the Bid 4 1 3 Bid shall include legal name of Bidder and a statement that the Bidder is a sole proprietor partnership corporation or other legal entity Each copy shall be signed by the person or persons legally authorized to bind the Bidder to a Contract. A Bid by a corporation shall give the state of incorporation or corporate seal affixed A Bid submitted by an agent shall have a current power of attorney attached certifying the agent's authority to bind the Bidder 4.2 Bid security 4 2.1 If so stated in the Advertisement or Notice of Call for Bids or in Bidding Documents each Bid shall be accompanied by a bid security in a.) cash b cashier's check /money order c certified check, or d.) Surety Bond in the amount of 5% of the total Bid amount. Bid security shall be in form required pledging that the Bidder will enter a Contract with the Owner on the terms stated in Bid and will furnish bonds covering the faithful performance of the Contract and payment of all obligations arising thereunder Bid security of the lowest three Bidders may be retained by Owner for a period not to exceed 30 days following opening of Bids All other Bidders securities shall be returned within ten days of date of receipt of bids. Should Bidder fail to enter into a Contract or furnish bonds where required the amount of Bid Security shall be forfeited to the Owner as liquidated damages not as a penalty 4.2.2 Surety Bond shall be written on required forms and the attorney -in -fact who executes the bond shall affix to the Bond a certified and current copy of the power -of- attorney 4.3 Submission of bids 4 3 1 Bids Bid Security and other documents required to be submitted with the Bid shall be enclosed in a sealed, opaque envelope marked with the notation SEALED BID' with project name clearly marked on the outside of the envelope The envelope shall be addressed to the party receiving Bids as identified in the Advertisement or Notice Call for Bids and include the Bidder's name and address If Bid is sent by mail the sealed envelope shall be enclosed in a separate mailing envelope with notation SEALED BID ENCLOSED' and the project name on the face thereof 4 3.2 Bids shall be deposited at the designated location prior to the time and date for receipt of Bids Bids received after time and date will be returned unopened The Bidders shall assume full responsibility for timely delivery at location designated for receipt of Bids 4 3 3 Oral, telephone telegraphic, or fax Bids are invalid and will not receive consideration 4 4 Modification or withdrawal of Bid 4 4 1 A Bid may not be modified withdrawn or canceled by the Bidder during the stipulated time period of thirty days following the time and date designated for the receipt of Bids and each Bidder so agrees in submitting a Bid 4 4 2 Prior to the time and date designated for receipt of Bids a Bid submitted may be modified or withdrawn by notice to the party receiving Bids at the place designated for receipt of Bids Such notice shall be in writing over the signature of the Bidder or by telegram if by telegram written confirmation over the signature of the Bidder shall be mailed and postmarked on or before the date and time set for receipt of Bids A change shall be so worded as not to reveal the amount of the original Bid 4 4 3 Withdrawn Bids may be resubmitted up to the date and time designated for the receipt of Bids provided that they are then fully in conformance with these instructions to Bidders 4 4 4 Bid Security if required shall be in an amount sufficient for the Bid as modified or resubmitted Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallanm County Parks, Fair Facilities March 2006 DIVISION ZERO Instructions to Bidders Section 00200 ARTICLE 5 CONSIDERATION OF BIDS 5.1 Bids received on time and properly identified will be opened and read aloud at the Board of Commissioners meeting held immediately after the time and date for receipt of Bids as advertised in Notice Call for Bids 5.2 The Owner shall have the right to reject any or all Bids reject a Bid not accompanied by a required Bid Security or by other data required by the Bidding Documents or reject a Bid which is in any way incomplete or irregular 5.3 The Owner may determine that a Bidder is not responsible and reject his proposal for any of the reasons found in Clallam County Code 3 12.060 5.4 Bid award 5 4 1 It is the intent of the Owner to award a Contract to the lowest responsible Bidder provided the Bid has been submitted in accordance with the requirements of the Bidding Documents and does not exceed the funds available The Owner shall have the right to waive informalities or irregularities in a Bid received and to accept the Bid which in the Owners judgment, is in the Owner's best interests 5 4.2 The Owner shall have the right to accept Alternates in any order or combination unless otherwise specifically provided in the Bidding Documents and to determine the low Bidder on the basis of the sum of the Base Bid and Alternates accepted ARTICLE 6 POST BID INFORMATION 6 1 Contractor's Qualification Statement Bidders to whom award of a Contract is under consideration shall submit to the Owner or Owner's representative Architect, upon request, a properly executed Contractor's Qualification Statement in the form requested by the Owner 6.2.1 Submittals The Bidder shall, within three days of notification of selection for the award of a Contract, furnish the Owner or Owner's representative Architect in writing if not required to be included on the Bid Proposal Form 1 Work to be performed by Bidders own forces 2 A complete list of sub bidders or sub contractors to be used to complete this project 3 Name of project superintendent or foreman to be used 4 Names of manufacturers products and supplies of principal items or systems proposed for the Work. 6.2.2 Prior to award of the Contract, the Owner or Owner's representative Architect, will notify Bidder if Owner has a reasonable objection to a person or entity proposed by Bidder If Owner has objection the Bidder may (1) withdraw the Bid or (2) submit an acceptable substitute person or entity with an adjustment in the Base Bid or Alternate Bid to cover the difference in cost, if any occasioned by the substitution The Owner may accept the adjusted bid price or disqualify the Bidder In the event of withdrawal or disqualification the Bid Security will not be forfeited 6 2.3 Persons and entities proposed by the Bidder and to whom the Owner has made no reasonable objection must be used on the work for which they were proposed and shall not be changed except with the written consent of the Owner 6 2.4 A copy of Contractor s UBI Certification shall be submitted with the signed agreement. Fairgrounds Home Arts Building Re Roof March 2006 Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO Instructions to Bidders Section 00200 ARTICLE 7 PERFORMANCE AND PAYMENT BOND 7 1 Bond requirements 7 1 1 The Bidder shall furnish bonds covering faithful performance and payment of all obligations and as described in the Bidding Documents and all bonds shall be paid for by the Bidder and costs shall be included in Bid 7.2 Time of delivery and form of bonds 7.2.1 The Bidder shall deliver the required bonds to the Owner not later than three days following the date of execution of the Contract. If the Work is to be commenced prior thereto in response to a letter of intent, the Bidder shall prior to commencement of the Work, submit evidence satisfactory to the Owner that such bonds will be furnished and delivered in accordance with this Subparagraph 7 2 1 7 2 2 Unless otherwise provided the bonds shall be written on forms provided by Owner Performance Bond and Payment Bond Both bonds shall be written in the amount of the Contract Sum plus sales tax. 7 2.3 The bonds shall be dated on or after the date of the Contract. 7 2.4 The Bidder shall require the attorney -in -fact who executes the required bonds on behalf of the surety to affix thereto a certified and current copy of the power of attorney ARTICLE 8 FORM OF AGREEMENT 8.1 Form to be used 8 1 1 The Agreement for the Work shall be the completed sample included in the Bidding Documents and shall be signed by the Bidder within ten days of notice by the Owner of award of Contract to the Bidder END OF SECTION 00200 Fairgrounds Home Arts Building Re Roof March 2006 Division 00 General Conditions Clallam Count Parks, Fair Facilities DIVISION ZERO Bid Proposal Form Section 00300 BID PROPOSAL FORM Project: Fairgrounds Home Arts Building Re Roof To CLALLAM COUNTY PARKS FAIR FACILITIES DIVISION Submission of this bid proposal certifies that the Undersigned has examined the project site and the conditions of work; and has carefully read and thoroughly understands the Bidding Documents governing the work embraced in this project, and the method by which payment will be made for said work. The Undersigned hereby proposes to undertake and complete the work embraced in this project in accordance with said Bidding Documents and agrees to accept as payment for said work the amounts indicated below under Bid Proposal. The base bid shall include all work except that indicated in the Alternates The Undersigned acknowledges that payment will be based on the actual work performed as measured or provided for in accordance with the said contract documents Base Bid Alternates and Unit Prices shall not include State of Washington Sales Tax. Appropriate sales tax is to be added to invoice amounts after award of bid BID PROPOSAL BASE BID AMOUNT OF ALTERNATES Circle One ADD DEDUCT BID GUARANTEE (See Bid Bond Form attached) dollars Alternate No 1 Remove existing composition roofing at lower roof and replace with new 40- year composition roofing dollars CONTRACTOR'S CERTIFICATION OF BIDDING CONTRACT DOCUMENTS Clallam County Parks, Fair Facilities March 2006 By signing this form the Contractor certifies that based on the Contractor's knowledge and review that the Contractor finds the Bidding Contract Documents sufficiently complete and in sufficient detail to perform the work required The Undersigned furnishes herewith a bid guarantee in the amount of 5% of the total Base Bid proposal lump sum amount and attaches same to the proposal This bid guarantee warrants that the undersigned will not withdraw his proposal for a period of thirty (30) days after the scheduled closing time for the receipt of proposals and that if this proposal is accepted the undersigned will enter into a formal contract (prepared by the Owner) and that the required performance bond and payment bond will be given In the event of the withdrawal of this proposal within the period stipulated above or the failure of the undersigned to enter into a contract and give the required bonds the undersigned will be liable to the Owner for the full amount of the bid guarantee as liquidated damages on account of the default of the undersigned Fairgrounds Home Arts Building Re Roof Division 00- General Conditions 324SON ZERO Seto D0300 itordixix.kal guaranty in an amount of five percent (5 of the total bid in the form as indicated below is gtslteci hereto k. /WASH IN THE AMOUNT OF KA PIER S CHECK/POSTAL MONEY ORDER (s }'eTIFIED CHECK PAYABLE TO CLALLAM COUNTY (a �IAPOSED BOND IN THE AMOUNT OF 5% OF THE BID NOM STATEMENT ljacng this proposal the Contractor certifies that he /she has not participated in any collusion or Men/Ilse taken action in restraint of free competitive bidding in connection with this project for which this psal is submitted NON DISCRIMINATION Bid Proposal Form %Contractor hereby agrees to not discriminate against any person on the basis of race creed political deology color national origin sex, marital status sexual orientation age or presence of any sensory mental or physical disability INDEPENDENT CONTRACTOR STATEMENT T eContractor certifies that services shall be furnished by the Contractor as an independent contractor andnothing herein contained shall be construed to create a relationship of employer /employee or master /servant, but all payments made hereunder and all services performed shall be made and peformed pursuant to this Agreement by the Contractor ADDENDA Receipt of Addenda(s) numbered is hereby acknowledged and all costs of the Work therefore have been included in the Bid Proposal BIDDER NAME AND SIGNATURE The name of the Bidder submitting this proposal the address and phone number to which all communications concerned with this proposal shall be made and the number which has been assigned mating the Bidder is licensed to do business in the State of Washington are as follows Emn Name Address: Telephone 1 Contractor's License No Exp Date Thefirm submitting this proposal is a Sole Proprietorship Corporation Partnership The names and titles of the principal officers of the corporation submitting this proposal or of the partnership or of all persons interested in this proposal as principals are as follows Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Claltam County Parks, Fair Facilities March 2006 DIVISION ZERO Bid Proposal Form Section 00300 SIGNATURE OF AUTHORIZED OFFICIAL(S) (PROPOSAL MUST BE SIGNED) END OF SECTION 00300 Fairgrounds Home Arts Building Re Roof Division 00- General Conditions FIRM NAME (Seal) Clallam Count Parks, Fair Facilities March 2006 DIVISION ZERO Supplemental Bid Forms Section 00400 SUPPLEMENTAL BID FORMS ARTICLE 1 The Bid Bond format listed below shall be used by Bidders when submitting their Bid Bond KNOW ALL MEN BY THESE PRESENTS that we as Principal hereinafter called the Principal and a corporation duly organized under the laws of the State of as Surety hereinafter called the Surety are held and firmly bound unto as Obligee hereinafter called the Obligee in the sum of (Witness) Fairgrounds Home Arts Building Re Roof Division 00- General Conditions (here insert full name address or legal title of Contractor) (here insert full name address or legal title of Surety) (here insert full name and address or legal title of Owner) Dollars for the payment of which sum well and truly to be made the said Principal and the said Surety bind ourselves our heirs executors, administrators successors and assigns jointly and severally firmly by these presents WHEREAS the Principal has submitted a bid for (here insert full name address and description of project) NOW THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding of Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the Prompt payment of labor and material furnished in the prosecution thereof or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this day of 20 (Principal) (Seal) (Witness) (Title) (Surety) (Seal) (Title) Clallam County Parks, Fair Facilities March 2006 DIVISION ZERO Suoolemental Bid Forms Section 00400 ARTICLE 2 STATEMENT OF BIDDER'S QUALIFICATIONS When requested by the Owner Contractor shall complete and submit the below information within three days of notification by Owner 1 Name of Bidder 2 Business Address. 3 How many years has said bidder been engaged in the contracting business under the present firm name? 4 Contracts now in hand (Gross Amount) 5 General character of work performed by said company 6 List of more important projects constructed by said company including approximate costs and dates 7 List of company's major equipment: 8 Bank References 9 Department of Labor and Industries Firm No 10 Department of Revenue Registration Name of Bidder By Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Title Date Clallam County Parks, Fair Facilities March 2006 DIVISION ZERO Supplemental Bid Forms Section 00400 ARTICLE 3 STATEMENT OF PROPOSED SUB CONTRACTORS AND MAJOR MATERIAL SUPPLIERS The Contractor shall submit a complete list of all major material suppliers and a sub contractor's list within three days of notification of Bid award or upon request by the Owner to provide it. Sub Contractor's List NAME ADDRESS DESCRIPTION OF WORK/MATERIAL MATERIAL SUPPLIERS Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallarn County Parks, Fair Facilities March 2006 DIVISION ZERO Supplemental Bid Forms Section 00400 ARTICLE 4 RETAINAGE INVESTMENT OPTION DECLARATION CONTRACTOR PROJECT NAME Fairgrounds Home Arts Building Re -Roof PROJECT NUMBER. 620610FG Pursuant to RCW 60 28 010 as amended you may choose how your Retainage under this contract will be held and invested Please complete and sign this form indicating your preference If you fail to do so the County will hold your Retainage as described in Current Expense Option 1 below 1 Current Expense. The County will retain the money in its Current Expense Fund Account until thirty days following final acceptance of the improvement or work as completed You will not receive interest earned on this money 2 Interest Bearino Account: The County will deposit Retainage checks in an interest bearing account in a bank, mutual savings bank, or savings and loan association not subject to withdrawal until after the final acceptance of the improvement or work is completed or until agreed to by both parties Interest on the account will be paid to you 3 Escrow /Investments. the County will place the Retainage checks in escrow with a bank or trust company until thirty days following the final acceptance to the improvement or work as completed When the moneys reserved are to be placed in escrow the County will issue a check representing the sum of the moneys reserved payable to the bank or trust company and you jointly This check will be converted into bonds and securities chosen by you and approved by the County and these bonds and securities will be held in escrow Interest on these bonds and securities will be paid to you as interest accrues 4 The Contractor may at his /her option choose to not submit a performance bond and agrees to a 50% Retainage in lieu of a performance bond Retainage to be released when Contract is complete and all paperwork submitted (Pertains to projects under $25 000 ONLY) Retainage is normally released 30 -40 days after final acceptance of work by the County or following receipt of Labor and Industries Department of Revenue clearance whichever takes longer Fairgrounds Home Arts Building Re Roof Division 00- General Conditions (Contractor's Signature) (Title) Clallam County Parks, Fair Facilities March 2006 DIVISION ZERO Supplemental Bid Forms Section 00400 ARTICLE 5 PERFORMANCE AND PAYMENT BOND FORM The Contractor will use AIA Document A312 Forms as revised as the acceptable forms when providing bonds. ARTICLE 6 INDUSTRIAL INSURANCE PREMIUMS AND CONFESSION OF JUDGMENT 1 The contractor shall pay and is responsible for payment of all industrial insurance premiums that become due and payable to the Washington State Department of Labor and Industries (Department) pursuant to Title 51 RCW whether such premiums are attributable to the contractor or its subcontractors 2. In the event that Clallam County is required to make industrial insurance premiums to the Department due to the failure, neglect or refusal of the contractor to make payment as required herein the contractor authorizes Clallam County to take judgment against it, and the contractor hereby confesses judgment, in the amount which Clallam County is required to pay the Department pursuant to Title 51 RCW to satisfy contractor's liabilities hereunder The contractor confesses judgment in an amount equal to the entire industrial insurance premium liability due to the Department on behalf of the contractor and its subcontractors hereunder less any premium payments previously made to the Department by the contractor 3 The contractor expressly agrees that the amount confessed herein was expressly negotiated and that the amount due to Clallam County for satisfying contractor's obligations to the Department hereunder is due justly due or to become due 4 Until such time as Clallam County is actually reimbursed for industrial insurance premiums paid to the Department due to the failure neglect or refusal of the contractor to meet its obligations hereunder the contractor shall be debarred from bidding on any projects for which Clallam County solicits bids State of County of Corporate On this day of 20 before me personally appeared to me known to be the (president, vice president, secretary treasurer or other authorized officer or agent, as the case may be) of the corporation that executed the within and foregoing instrument, and acknowledged said instrument to be the free and voluntary act and deed of said corporation for the uses and purposes therein mentioned and on oath stated that he was authorized to execute said instrument and that the seal affixed is the corporate seal of said corporation In witness whereof I have hereunto set my hand and affixed my official seal the day and year first above written (CORPORATE SEAL) ss Fairgrounds Home Arts Building Re Roof Division 00- General Conditions (Contractor's Signature) (Title) Notary Public in and for the State of Washington Residing at Clallam County Parks, Fair Facilities March 2006 DIVISION ZERO Supplemental Bid Forms Section 00400 State of County of Individual END OF SECTION 00400 20 ss On this day personally appeared before me to me known to be the individual or individuals described in and who executed the within and foregoing instrument, and acknowledged that he (she or they) signed the same as his (her or their) free and voluntary act and deed for the uses and purposes therein mentioned Given under my hand and official seal this day of Fairgrounds Home Arts Building Re Roof Division 00- General Conditions (Contractor's Signature) (Title) Notary Public in and for the State of Washington Residing at Clallam County Parks, Fair Facilities March 2006 DIVISION ZERO Form of Aareement Between Owner and Contractor Section 00500 FORM OF AGREEMENT BETWEEN OWNER AND CONTRACTOR Project Name FAIRGROUNDS HOME ARTS BUILDING RE -ROOF This agreement is entered into between Clallam County a political subdivision of the State of Washington hereafter called County' and Of (address) hereinafter called Contractor' The Owner and Contractor agree as set forth below 1 This Agreement is comprised of the Bidding Documents Contract Documents the Agreement, Plans and Specifications as described in the Contract Documents Addenda issued prior to execution of this Agreement and modifications issued after execution of this Agreement. 2 The Contractor shall execute the entire work described in the Bidding and Contract Documents 3 The date of commencement is the date the Contractor receives a signed copy of this Agreement by the Board of Commissioners which shall be considered the notice to proceed 4 The Contractor shall achieve Substantial Completion of the entire work no later than subject to adjustments provided for in the Contract Documents 5 The Owner shall pay the Contractor in current funds for Contractor's performance of the Contract the Contract Sum of dollars subject to additions and deductions as provided in the Contract Documents 6 The Contract Sum is based upon the following alternates if any which are described in the Contract Documents and hereby accepted by the Owner (state numbers and other identification) Alternates. Alternate No 1 Remove existing composition roofing at lower roof and replace with new 40- year composition roofing 7 Progress Payments a The Owner shall make progress payments to the Contractor on account of the Contract Sum as provided for below and elsewhere in the Contract Document. b The Contractor shall submit Application for Payment on AIA Document G702 forms not more than once per month. or Contractor's own form with same information found on G702 Forms c. The Contractor shall submit Application for Payment prior to the last day of each calendar month to the Owner or Owner's representative Architect. d The Owner shall make progress payments within 15 calendar days of receipt of Application for Payment and certification that work has progressed satisfactorily e Each Application for Payment shall be based upon the schedule of values submitted by the Contractor in accordance with the Contract Documents The schedule of values shall allocate the entire Contract Sum among the various portions of the Work and be prepared in such form and supported by such data to substantiate its accuracy as the Owner or Owner's Architect may require This schedule unless objected to by the Owner or Owner's Architect, shall be used as a basis for reviewing the Contractor's Applications for payment. Fairgrounds Home Arts Building Re Roof March 2006 Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO Form of Aareement Between Owner and Contractor Section 00500 CONTRACTOR: (Name) (By) (Its) f Applications for Payment shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. g Subject to the provisions of the Contract Documents the amount of each progress payment shall be computed as follows Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the total Contract sum allocated to that portion of the Work in the schedule of values less Retainage of five percent. Pending final determination of cost to the Owner of changes in the Work, amounts not in the dispute may be included as provided in the General Conditions even though the Contract Sum has not yet been adjusted by Change Order Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction less Retainage of five percent. Subtract the aggregate of previous payments made by the Owner and Subtract amounts if any for which the Owner or Architect has withheld or nullified a Certificate of Payment as provided in the General Conditions 8 Final payment, constituting the entire unpaid balance of the Contract Sum shall be made by the Owner to the Contractor when (1) the Contract has been fully performed by the Contractor except for the Contractor's responsibility to correct non conforming Work as provided in the General Conditions and to satisfy other requirements if any which necessarily survive final payment; and (2) a Final Certificate for Payment has been issued by the Owner or Owner's representative Architect; such final payment shall be made by the Owner not more than 30 days after the issuance of the Owner or Owner's representative Architect's final Certificate for Payment, punch list is completed and all close- out paperwork and documents have been submitted to the Owner including Department of Revenue clearance 9 Other documents, if any forming part of the Contract Documents are as follows A. UBI Certification (copy to be attached to Agreement) IN WITNESS WHEREOF the Parties have executed this Agreement on this day of 20 Date. ATTEST Clerk of the Board Trish Perrott, CMC END OF SECTION 00500 20 Clallam County Parks, Fair Facilities OWNER: BOARD OF CLALLAM COUNTY COMMISSIONERS Howard V Doherty Jr Chair Approved as to Form. Prosecuting Attorney s Office Fairgrounds Home Arts Building Re Roof March 2006 Division 00- General Conditions DIVISION ZERO General Conditions of the Contract Section 00600 GENERAL CONDITIONS OF THE CONTRACT ARTICLE 1 GENERAL PROVISIONS 11 Definitions 1 1 1 Contract Documents consist of Agreement between Owner and Contractor General Conditions of the Contract, Supplemental Conditions Bidding Documents, Bonds Drawings and Specifications Addenda, approved Alternates and modifications issued after execution of the Agreement. 1 1.2 The term Work means the construction and services required by the Contract Documents and includes all labor materials equipment and services provided by the Contractor to fulfill the Contractor's obligations. 1 1 3 The Drawinas are the graphic and pictorial portions of the Contract Documents showing the design location and dimensions of the Work. 1 1 4 The Specifications are that portion of the Contract Documents consisting of the written requirements for materials equipment construction systems standards and workmanship for the Work and performance of related services 1 1 5 The Proiect Manual is the volume assembled for the work which includes the Bidding Documents including Call for Bids and Instructions to Bidders, and Contract Documents 1 2 Execution Correlation and Intent 1.2.1 The Contract Documents shall be signed by the Owner and Contractor as provided in the Agreement. 1.2.2 Execution of the contract by the Contractor is a representation that the Contractor has visited the site become familiar with local conditions under which the Work is to be performed and correlated personal observations with requirements of the Contract Documents 1 2 3 The intent of the Contract Documents is to include all items necessary for the proper execution and completion of the Work by the Contractor The Contract Documents are complementary and what is required by one shall be as binding as if required by all. 1 2.4 Organization of the Specifications into divisions sections and articles and arrangement of Drawings shall not control the Contractor in dividing the Work among Subcontractors or in establishing the extent of Work to be performed by any trade 1.2 5 Unless otherwise stated in the Contract Documents words which have well -known technical or construction industry meanings are used in the Contract Documents in accordance with such recognized meanings 1 2.6 The apparent silence of the specifications or plans as to any detail or the apparent omission from them of a detailed description concerning any point shall be regarded as meaning that only the best general practice is to prevail and that only material and workmanship of first quality are to be used All interpretations of these specifications shall be made on the basis above stated Fairgrounds Home Arts, Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 1.3 OWNERSHIP OF DOCUMENTS 1 3.1 The Drawings Specifications and other documents prepared by the Owner or Owner's Architect are instruments of the Owner's service through which the Work to be executed by the Contractor is described The Owner shall be deemed the author of them and will retain all common law statutory and other reserved rights in addition to the copyright. ARTICLE 2 OWNER 2.1 1 The Owner is the person or entity identified as such in the Agreement and is referred to throughout the contract Documents as if singular in number The term 'Owner means the Owner or the Owner's authorized representative 2.1 2 The Owner shall furnish surveys utility locations or other records that the Owner has presently on file or presently knows of to the contractor upon request. The Owner will not provide additional surveys layouts or locations unless specifically stated elsewhere in the Contract Documents 2 1 3 The Owner shall secure and pay for the building permit. All other permits and fees for permits shall be paid for by the Contractor 2 1 4 The Owner shall have additional responsibilities enumerated herein 2.1 5 If the Contractor fails to correct Work or persistently fails to carry out Work in accordance with the Contract Documents the Owner by written order signed personally or by an agent specifically so empowered by the Owner in writing may order the Contractor to stop the work or any portion thereof until the cause for such order has been eliminated ARTICLE 3 CONTRACTOR 3 1 1 The Contractor is the person or entity identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number The term Contractor' means the Contractor or the Contractor's authorized representative 3 1.2 The Contractor shall carefully study and compare the Contract Documents with each other and with information furnished by the Owner and shall at once report to the Owner errors inconsistencies or omissions discovered The Contractor shall not be liable to the Owner for damage resulting from errors inconsistencies or omissions in the Contract Documents unless the Contractor recognized (or should have recognized) such error inconsistency or omission and knowingly failed to report it to the Owner If the Contractor performs any construction activity knowing it involves a recognized error inconsistency or omission in the Contract Documents without such notice to the Owner the Contractor shall assume appropriate responsibility for such performance and shall bear an appropriate amount of the attributable costs for correction 3 1 3 The Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to the Contractor with the Contract Documents before commencing activities. Errors inconsistencies or omissions discovered shall be reported to the Owner at once 3 1 4 The Contractor shall supervise and direct the Work using the Contractors best skill and attention The Contractor shall be solely responsible for and have control over construction means methods techniques sequences and procedures and for coordinating all portions of the Work under the Contract, unless Contract Documents give other specific instructions concerning these matters Fairgrounds I -tome Arts Building Re Roof Division 00- General Conditions CIaIIam County Parks, Fair Facilities 1 1 1 1 t DIVISION ZERO General Conditions of the Contract Section 00600 3.1 5 The Contractor shall be responsible to the Owner for acts and omissions of the Contractor's employees Subcontractors and their agents and employees and other persons performing portions of the Work under a contract with the Contractor 3.1 6 Unless otherwise provided in the Contract Documents the Contractor shall provide and pay for labor materials equipment, tools construction equipment and machinery water heat, utilities transportation and other facilities and services necessary for proper execution and completion of the Work, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work. 3.1 7 The Contractor shall enforce strict discipline and good order among the Contractor's employees and other persons carrying out the Contract. The Contractor shall not permit employment of unfit persons or persons not skilled in tasks assigned to them. 3 1 8 The Contractor warrants to the Owner that materials and equipment furnished under the Contract will be of good quality and new that the Work will be free from defects not inherent in the quality required or permitted and that the Work will conform with the requirements of the Contract Documents Work not conforming to these requirements including substitutions not properly approved and authorized may be considered defective The Contractor's warranty excludes remedy for damage or defect caused by abuse modifications not executed by the Contractor improper or insufficient maintenance improper operation or normal wear and tear under normal usage If required by the Owner the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. 3 1 9 The Contractor shall pay sales consumer use and similar taxes for the work or portions thereof provided by the Contractor which are legally enacted when bids are received or negotiations concluded whether or not yet effective or merely scheduled to go into effect. 3 1 10 Other than the Building Permit, the Contractor shall secure and pay for all permits and governmental fees licenses and inspections necessary for proper execution and completion of the Work. 3 1 11 The Contractor shall comply with and give notices required by laws ordinances rules regulations and lawful orders of public authorities bearing on performance of the Work. 3 1 12 If the Contractor observes that portions of the Contract Documents are at variance with codes the Contractor shall promptly notify the Owner in writing and necessary changes shall be accomplished by appropriate modification 3 1 13 If the Contractor performs Work knowing or should have known it to be contrary to laws statutes ordinances building codes and rules and regulations without such notice to the Owner the Contractor shall assume full responsibility for such Work and shall bear the attributable costs 3 1 14 The Contractor shall keep the premises and surrounding area free from accumulation of waste materials or rubbish caused by operations under the Contract. At completion of the work, the Contractor shall remove from and about the Project waste materials rubbish the Contractor's tools construction equipment, machinery and surplus materials 3 1 15 If the Contractor fails to clean up as provided in the Contract Documents the Owner may do so and the cost thereof shall be charged to the Contractor 3 1 16 The Contractor shall provide the Owner access to the Work in preparation and progress wherever located 3 1 17 To the fullest extent permitted by law the Contractor shall defend indemnify and hold harmless the Owner Architect, Architect's consultants and agents and employees of any of them from and against claims damages losses and expenses including but not limited to attorney's fees arising out of or resulting from performance of the Work, provided that such claim damage loss or expense is attributable Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 to bodily injury sickness disease or death or to injury to or destruction of tangible property (other than the work itself) including loss of use resulting therefrom but only to the extent caused in whole or in part by negligent acts or omissions of the Contractor a Subcontractor anyone directly or indirectly employed by them or anyone for whole acts they may be liable regardless of whether or not such claim damage loss or expense is caused in part by a party indemnified hereunder Such obligation shall not be construed to negate, abridge or reduce other rights or obligations of indemnity which would otherwise exist as to a party or person described in this Paragraph 3.1 18 With respect to performance of this agreement and as to claims against the county its elected and appointed officers, agents and employees the Contractor expressly waives its immunity under Title 51 RCW the Industrial Insurance Act, as now and hereafter amended for injuries to its employees and agrees that the obligations to indemnify defend and hold harmless provided in this agreement extend to any claim brought by or on behalf of any employee of the Contractor This waiver is mutually negotiated by the Owner and Contractor ARTICLE 4 ADMINISTRATION OF THE CONTRACT 4 1 The Owner's project manager shall be the administrator of the contract unless the Owner has agreement for architectural services 4 1 1 The Architect is the person lawfully licensed to practice architecture or an entity lawfully practicing architecture identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number The term Architect' means the Architect or the Architect's authorized representative 4 1.2 Duties responsibilities and limitations of authority of the Architect as set forth in the Contract Documents shall not be restricted modified or extended without written consent of the Owner Contractor and Architect. Consent shall not be unreasonably withheld 4 1 3 The Architect will provide administration of the Contract as described in the Contract documents and will be the Owner's representative (1) during construction (2) until final payment is due and (3) with the Owner's concurrence form time to time during the correction period The Architect will advise and consult with the Owner The Architect will have authority to act on behalf of the Owner only to the extent provided in the Contract Documents unless otherwise modified by written instrument in accordance with other provisions of the Contract. 4 1 4 The Architect will visit the site at intervals appropriate to the stage of construction to become generally familiar with the progress and quality of the completed Work and to determine in general if the Work is being performed in a manner indicating that the Work, when completed will be in accordance with the Contract Documents However the Architect will not be required to make exhaustive or continuous on -site inspections to check observations as an architect, the Architect will keep the Owner informed of progress of the Work, and will endeavor to guard the Owner against defects and deficiencies in the Work. 4 1 5 Except as otherwise provided in the Contract Documents or when direct communications have been specially authorized the Owner and Contractor shall endeavor to communicate through the Architect. Communications by and with the Architect's consultants shall be through the Architect. Communications by and with Subcontractors and material suppliers shall be through the Contractor Communications by and with separate contractors shall be through the Owner 4 1 6 Based on the Architect s observations and evaluations of the Contractor's Applications for Payment, the Architect will review and certify the amounts due the Contractor and will issue Certificates for Payment in such amounts to the Owner who has final approval and authority Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 4.1 7 The Architect, with Owner's approval will have authority to reject Work which does not conform to the Contract documents Whenever the Architect, with Owner's approval considers it necessary or advisable for implementation of the intent of the Contract Documents the Architect, with Owner's approval, will have authority to require additional inspection or testing of the work. However neither this authority of the Architect nor a decision made in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect to the Contractor Subcontractors material and equipment suppliers their agents or employees or other persons performing portions of the Work. 4.1 8 The Architect will review and with Owner's approval approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings Product Data and Samples but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents 4.1 9 The Architect, with the Owner's approval, will prepare Change Orders and Construction Change Directives and may authorize minor changes in the work as provided in Paragraph 7 1 4 4 1 10 The Architect will conduct inspections to determine the date or dates of Substantial Completion and the date of final completion will received and forward to the Owner for the Owner's review and records written warranties and related documents required by the Contract and assembled by the Contractor and will issue a final Certificate for Payment upon compliance with the requirements of the Contract Documents ARTICLE 5 SUBCONTRACTORS 51 Definitions 51 1 A Subcontractor is a person or entity who has a direct contract with the Contractor to perform a portion of the Work at the site 5 1.2 Unless otherwise stated in the Contract Documents or the bidding requirements the Contractor as soon as practicable after award of the Contract, shall furnish in writing to the Owner the names of persons or entities (including those who are to furnish materials or equipment fabricated to a special design) proposed for each principal portion of the Work. The Owner will promptly reply to the Contractor in writing stating whether or not, after due investigation the Owner has reasonable objection to any such proposed person or entity Failure of the Owner to reply promptly shall constitute notice of no reasonable objection. 5 1 3 The Contractor shall not contract with a proposed person or entity to whom the Owner has made reasonable and timely objection 5 1 4 If the Owner has reasonable objection to a person or entity proposed by the Contractor the Contractor shall propose another to whom the Owner has no reasonable objection The Contract Sum shall be increased or decreased by the difference in cost occasioned by such change and an appropriate Change Order shall be issued However no increase in the Contract Sum shall be allowed for such change unless the Contractor has acted promptly and responsively in submitting names as required 5 1 5 By appropriate agreement, written where legally required for validity the Contractor shall require each Subcontractor to the extent of the Work to be performed by the Subcontractor to be bound to the Contractor by terms of the Contract Documents and to assume toward the Contractor all the obligations and responsibilities which the Contractor by these Documents assumes toward the Owner and Architect. Each subcontract agreement shall preserve and protect the rights of the Owner and Architect under the Contract Documents with respect to the Work to be performed by the Subcontractor so that subcontracting thereof will not prejudice such rights and shall allow to the Subcontractor unless Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 specifically provided otherwise in the subcontract agreement, the benefit of all rights remedies and redress against the Contractor that the Contractor by the Contract Documents has against the Owner Where appropriate the Contractor shall require each Subcontractor to enter into similar agreements with Sub subcontractors The Contractor shall make available to each proposed Subcontractor prior to the execution of the subcontract agreement, copies of the Contract Documents to which the Subcontractor will be bound and upon written request of the Subcontractor identify to the Subcontractor terms and conditions of the proposed subcontract agreement which may be at variance with the Contract Documents Subcontractors shall similarly make copies of applicable portions of such documents available to their respective proposed Sub subcontractors ARTICLE 6 CONSTRUCTION BY OWNER 6.1 1 The Owner reserves the right to perform construction or operations related to the Project with the Owner's own forces and to award separate contracts in connection with other portions of the Project or other construction or operations on the site under Conditions of the Contract identical or substantially similar to these including those portions related to insurance and waiver of subrogation If the Contractor claims that delay or additional cost is involved because of such action by the Owner the Contractor shall make such Claim as provided elsewhere in the Contract Documents 6 1 2 The Owner shall provide for coordination of the activities of the Owner's own forces 6 1 3 If part of the Contractor's Work depends for proper execution or results upon construction or operations by the Owner or a separate contractor the Contractor shall prior to proceeding with that portion of the Work, promptly report to the Owner apparent discrepancies or defects in such other construction that would render it unsuitable for such proper execution and results Failure of the Contractor to so report shall constitute an acknowledgment that the Owner's or separate contractors completed or partially completed construction is fit and proper to receive the Contractor's Work, except as to defects not then reasonably discoverable ARTICLE 7 CHANGES IN THE WORK 7 1 1 Changes in the work may be accomplished after execution of the Contract, and without invalidating the Contract, by Change Order 7 1.2 A Change Order shall be based upon agreement among the Owner Contractor and Architect. 7 1 3 Changes in the Work shall be performed under applicable provisions of the Contract Documents and the Contractor shall proceed promptly unless otherwise provided in the Change Order 7 1 4 A Change Order is a written instrument prepared by the Owner or Architect and signed by the Owner Contractor and Architect stating their agreement upon all of the following 1 a change in the Work, 2 the amount of the adjustment in the Contract Sum if any and 3 the extent of the adjustment in the Contract Time if any ARTICLE 8 TIME AND LIQUIDATED DAMAGES 8 1 1 Contract time shall be as stated below from date of commencement established in the Agreement until final completion Contract Construction Timeline. June '19 to July 14, 2006 1 Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 8.12 Time limits stated in the Contract Documents are of the essence of the Contract. By executing the Agreement, the Contractor confirms that the Contract Time is a reasonable period for performing the Work. 8 1 3 The Contractor shall not knowingly except by agreement or instruction of the Owner in writing prematurely commence operations on the site or elsewhere prior to the effective date of insurance to be furnished by the Contractor The date of commencement of the Work shall be not changed by the effective date of such insurance Unless the date of commencement is established by a notice to proceed given by the Owner the Contractor shall notify the Owner in writing not less than five days or other agreed period before commencing the work to permit the timely filing of mortgages mechanic s liens and other security interests 8.1 4 If the Contractor is delayed at any time in progress of the Work by an act or neglect of the Owner or of an employee of either or of a separate contractor employed by the Owner or by changes ordered in the Work, or by labor disputes fire unavoidable casualties or other causes beyond the Contractor's control, or by delay authorized by the Owner then the Contract time shall be extended by Change Order 8 1 5 Should the Contractor fail to complete the Work within the Contract Time the Owner will sustain damage 8 1 6 Therefore the parties agree that the Contractor shall pay the Owner as liquidated damages and not as penalty an amount as follows which shall be considered to be the amount of the damage sustained by the Owner on account of the condition specified and shall continue to be paid until the condition specified is met. 8 1 7 It is agreed by the parties that time is of essence in this agreement and if the date of final completion is delayed the Owner will be damaged The exact amount of the damage will be difficult to calculate but will include such items as outside leases loss of efficient function and inconvenience to the public and to the Owner It is agreed between the parties that the amount of damages will be $100.00 per calendar day from Final Completion date as designated for each individual project as stated on the Form of Agreement Between Owner and Contractor The Owner may deduct the sum of such liquidated damages from any moneys due or that may become due the Contractor' or if such moneys are insufficient, the Contractor or his Surety or Sureties shall pay the difference ARTICLE 9 PAYMENTS AND COMPLETION 9 1 1 The Contract Sum is stated in the Agreement and including authorized adjustments is the total amount payable by the Owner to the Contractor for performance of the Work under the Contract Documents 9 1 2 Before the first Application for Payment, the Contractor shall submit to the Owner or Architect a schedule of values allocated to various portions of the work, prepared in such form and supported by such data to substantiate its accuracy as the Owner or Architect may require This schedule unless objected to by the Owner or Architect, shall be used as a basis for reviewing the Contractor's Applications for Payment. 9 1 3 At least ten days before the date established for each progress payment, the Contractor shall submit to the Owner or Architect, if one is used an itemized Application for Payment for operations completed in accordance with the schedule of values Such application shall be notarized if required and supported by such data substantiating the Contractor's right to payment as the Owner or Architect may require such as copies or requisitions from Subcontractors and material suppliers and reflecting Retainage if provided for elsewhere in the Contract Documents Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 9 1 4 Such applications may include requests for payment on account of changes in the work which have been properly authorized by Change Orders 9 1 5 Such applications may not include requests for payment of amounts the Contractor does not intend to pay to a Subcontractor or material supplier because of a dispute or other reason 9 1 6 Unless otherwise provided in the Contract Documents payments shall be made on account of materials and equipment delivered and suitably stored at the site for subsequent incorporation in the Work. 9 1 7 The Contractor warrants that title to all Work covered by an Application for Payment will pass to the Owner no later than the time of payment. The Contractor further warrants that upon submittal of an Application for Payment, all Work for which Certificates for Payment have been previously issued and payments received from the Owner shall to the best of the Contractor's knowledge information and belief be free and clear of liens claims security interests or encumbrances in favor of the Contractor Subcontractors material suppliers or other persons or entities making a claim by reason of having provided labor materials and equipment relating to the Work 9 1 8 The Owner shall determine the payment amount to be made to the Contractor 9 1 9 At the time each month stipulated in the Owner /Contractor Agreement, the Owner shall pay to the Contractor an amount equal to ninety -five percent (95 of the value of labor and material incorporated in the work, all as approved by the Architect in accordance with the provisions of the Contract Documents such amount paid to the Contractor shall be less the total of all previous payments and deductions provided for in the Contract Documents The five percent (5 withheld shall be Retainage which shall be paid as provided hereinafter The percentage of contract retained shall be five percent (5 pursuant to RCW Chapter 60 28 as amended Thirty days after final acceptance of the completed work, the balance due will be paid provided a. The work be fully completed b Certification has been received by the Owner from the State Department of Labor and Industries as to payment of prevailing wages in conformance with laws c. Certification has been received by the Owner from the State Department of Revenue that all taxes have been paid no tax lien may exist, and d. The Contractor warrants to the Owner all claims by materialmen and workmen if any for unpaid charges against the work have been satisfied and e To hold the Owner harmless from all liens on the completed work. In the event these provisions are not met, the Owner may pay a percentage of the Retainage holding back that quantity of money for materialmen and laborer's liens tax liens cost and attorney's fees to defray the cost of foreclosing all other liens costs and Architect's fee to defray cost of additional Construction Administration services After the award of a Contract for public improvement or work for which retained percentages are required to be reserved under the provisions of RCW 60 28 010 Owner shall require the Contractor to exercise in writing one of the options listed in RCW 60.20 010 Retained amounts shall be paid into an escrow account, if requested in a financial institution chosen by the Contractor and approved by the Owner the interest earnings from which shall accrue to the benefit of the Contractor 9 1 10 Final payment will not be made by the Owner until all contract conditions and requirements have been fulfilled and all forms and certificates are received in full Fairgrounds I -tome Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section D0600 9 1 11 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Owner or Architect will promptly make such inspection and when Owner and Architect finds the Work acceptable under the Contract Documents and the Contract fully performed the Architect will promptly issue a final Certificate for Payment. ARTICLE 10 PROTECTION OF PERSONS AND PROPERTY 10.1 1 The Contractor shall be responsible for initiating maintaining and supervising all safety precautions and programs in connection with the performance of the Contract. 10 1.2 In the event the Contractor encounters on the site material reasonably believed to be asbestos or polychlorinated biphenyl (PCB) which has not been rendered harmless the Contractor shall immediately stop Work in the area affected and report the condition to the Owner and Architect in writing The Work in the affected area shall not thereafter be resumed except by written agreement of the Owner and Contractor if in fact, the material is asbestos or polychlorinated biphenyl (PCB) and has not been rendered harmless The work in the affected area shall be resumed in the absence of asbestos or PCB or when it has been rendered harmless by written agreement of the Owner and Contractor 10 1 3 The Contractor shall take reasonable precautions for safety of and shall provide reasonable protection to prevent damage injury or loss to 1 employees on the Work and other persons who may be affected thereby 2. the work and materials and equipment to be incorporated therein whether in storage on or off the site under care, custody or control of the Contractor or the Contractor's Subcontractors or Sub subcontractors and 3 other property at the site or adjacent thereto such as trees shrubs lawns walks pavements roadways structures and utilities not designated for removal, relocation or replacement in the course of construction 10 1 4 The Contractor shall give notices and comply with applicable laws ordinances rules regulations and lawful orders of public authorities bearing on safety of persons or property or their protection from damage, injury or loss. 10 1 5 The Contractor shall erect and maintain as required by existing conditions and performance of the Contract, reasonable safeguards for safety and protection including posting danger signs and other warnings against hazards promulgating safety regulations and notifying owners and users of adjacent sites and utilities. 10 1 6 When use or storage of explosive or other hazardous materials or equipment or unusual methods are necessary for execution of the Work, the Contractor shall exercise utmost care and carry on such activities under supervision of properly qualified personnel 10.1 7 The Contractor shall promptly remedy damage and loss (other than damage or loss insured under property insurance required by the Contract Documents) to property caused in whole or in part by the Contractor a Subcontractor a Sub subcontractor or anyone directly or indirectly employed by any of them, or by anyone for whose acts they may be liable and for which the Contractor is responsible except damage or loss attributable to acts or omissions of the Owner or Architect or anyone directly or indirectly employed by either of them or by anyone for whose acts either of them may be liable and not attributable to the fault or negligence of the Contractor the foregoing obligations of the Contractor are in addition to the Contractor's obligations 10 1 8 The Contractor shall not load or permit any part of the construction or site to be loaded so as to endanger its safety Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 10 1 9 In an emergency affecting safety of persons or property the Contractor shall act, at the Contractor's discretion to prevent threatened damage injury or loss 10 1 10 The Contractor agrees to comply with Chapter 49 18 RCW providing that no laborer workman or mechanic in the employ of the Contractor Subcontractor or other person doing or contracting to do the work or any part of the work contemplated by the Contract, shall be permitted or required to work more than eight (8) hours in any one calendar day provided that, in cases of extraordinary emergency such as danger to life or property the hours of work may be extended but in such cases shall not be less than one and one -half times the rate allowed for this same amount of time during eight (8) hours service Any work necessary to be performed after regular working hours or Sunday or legal holidays shall be performed without additional expense to the Owner Contractor further agrees the said Contract is terminable in case the Contractor shall violate the provisions of such act. ARTICLE 11 INSURANCE BONDS 11 1 1 The Contractor shall purchase from and maintain in a company or companies lawfully authorized to do business in the jurisdiction in which the Project is located such insurance as will protect the Contractor from claims set forth below which may arise out of or result from the Contractor's operations under the Contract and for which the Contractor may be legally liable whether such operations be by the Contractor or by a Subcontractor or by anyone directly or indirectly employed by any of them or by anyone for whose acts any of them may be liable 1 claims under workers or workmen s compensation disability benefit and other similar employee benefit acts which are applicable to the Work to be performed 2 claims for damages because of bodily injury occupational sickness or disease or death of the Contractor's employees 3 claims for damages because of bodily injury sickness or disease or death of any person other than the Contractor's employees, 4 claims for damages insured by usual personal injury liability coverage which are sustained (1) by a person as a result of an offense directly or indirectly related to employment of such person by the Contractor or (2) by another person 5 claims for damages other than to the Work itself because of injury to or destruction of tangible property including loss of use resulting therefrom 6 claims for damages because of bodily injury death of a person or property damage arising out of ownership maintenance or use of a motor vehicle and 7 claims involving contractual liability insurance applicable to the Contractor's obligations 11 1 2 The Contractor shall name the Owner the Architect, their consultants and their officers agents and employees as additional insured on the insurance policies except the workers or workmen s compensation policy The Contractor shall obtain from the Owner and Architect the list of names to appear on the insurance policies 11 1 3 The insurance required by Subparagraph 11 1 1 shall be written for not less than the following or greater if required by law 1 Workers Compensation a. State Statutory b Applicable Federal (e g Longshoremen harbor Work, Work at or outside U S Boundaries) Statutory c Employer's Liability $500 000 00 d Benefits Required by Union labor contracts as applicable e Include all- states endorsement i Fairgrounds Rome Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 2. Comprehensive General Liability (Including Premises Operations Independent Contractor's Protective Products and Completed Operations Broad Form Property Damage) a Bodily Injury $500 000 00 Single Limit Per Occurrence Full Contract Amount Aggregate Products and Completed Operations b Property Damage Course of Construction Insurance Full Contract Amount Each Occurrence Full Contract Amount Aggregate c. Products and Completed Operations Insurance shall be maintained until 30 days after final completion d Property Damage Liability Insurance shall include coverage for the following hazards Vandalism Fire Explosion Collapse and Underground e Contractual Liability* 1 Bodily Injury $500 000 Each Occurrence 2 Property Damage Full Contract Amount Each Occurrence Full Contract Amount Aggregate f Personal Injury with Employment Exclusion Deleted $500 000 00 Aggregate 3 Comprehensive Automobile Liability (Owned Non -owned Hired) a Bodily Injury $500 000 00 Each Person $500 000 00 Each Occurrence b Property Damage. $100 000 00 Each Occurrence 4 If possible all of the above insurance coverage shall be carried with the same insurance company 11 1 4 Certificates of Insurance acceptable to the Owner shall be filed with the Owner and the Architect prior to commencement of the work. These Certificates shall contain a provision that coverage s afforded under the policies will not be canceled until at least thirty (30) days prior written notice has been given to the Owner the Architect, the Contractor and the Owner's insurer Certificates shall be furnished in duplicate and stipulate all coverage required and the Contractor shall furnish to the Owner and the Architect copies of all endorsements that area subsequently issued amending coverage or limits 11 1 5 The Contractor shall purchase and maintain in a company or companies lawfully authorized to do business in the jurisdiction in which the Project is located property insurance in the amount of the initial Contract sum as well as subsequent modifications thereto for the entire Work at the site on a replacement cost basis without voluntary deductibles Such property insurance shall be maintained unless otherwise provided in the Contract Documents or otherwise agreed in writing by all persons and entities who are beneficiaries of such insurance until final payment has been made 11 1 6 Property insurance shall be on an all -risk policy form and shall insure against the perils of fire and extended coverage and physical loss or damage including without duplication of coverage theft, vandalism malicious mischief collapse false work, temporary buildings and debris removal including demolition occasioned by enforcement of any applicable legal requirements and shall cover reasonable compensation for Architect's services and expenses required as a result of such insured loss Coverage for other perils shall not be required unless otherwise provided in the Contract Documents 11 1 7 The Contractor shall secure and pay for performance and payment bonds issued by a bonding company licensed to transact business in the locality of the project, on a Bond Form executed in pursuance to Chapter 39 08 Revised Code of Washington The Bond Form must comply with all requirements of the Owner's attorney Fairgrounds Home Arts Building Re Roof Division 00- General Conditions CIaIIam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 The surety bond shall be in the following penal sums Performance Bond 100% of agreement sum including Washington State Sales Tax Labor and Material 100% of agreement sum including Washington State Sales Tax Four copies of Bond Certification required 11 1 8 The Contract Bond or an equivalent Maintenance Bond shall continue in for force until final acceptance of the Work by the Owner 11 1 9 The Contractor guarantees the excellence of both workmanship and material, and the payment of all obligations incurred until the Work is finally accepted and for (30) days thereafter and until the provisions of the Contract Documents are fulfilled 11 1 10 For the projects under $25 000 00 Contractor may agree to a 50% Retainage fund in lieu of providing a performance bond The Retainage fund to be held by the County until work is complete all paperwork is turned in and state releases signed and returned to County ARTICLE 12 WARRANTY 12.1 1 The Contractor shall warranty all labor materials and work performed for a period of 1 year from date of final completion ARTICLE 13 LAW, SUCCESSORS, TESTS 13 1 1 The contract shall be governed by law of the place where project is located 13 1 2 The Owner and Contractor respectively bind themselves their partners successors assigns and legal representatives to the other party hereto and to partners successors assigns and legal representatives of such other party in respect to covenants agreements and obligations contained in the Contract Documents Neither party to the Contract shall assign the Contract as a whole without written consent of the other If either party attempts to make such as assignment without such consent, that party shall nevertheless remain legally responsible for all obligations under the Contract. 13 1 3 Duties and obligations imposed by the Contract Documents and rights and remedies available thereunder shall be in addition to and not a limitation of duties obligations rights and remedies otherwise imposed or available by law 13 1 4 No action or failure to act by the Owner Architect or Contractor shall constitute a waiver of a right or duty afforded them under the Contract, nor shall such action or failure to act constitute approval of or acquiescence in a breach thereunder except a may be specifically agreed in writing 13 1 5 Tests, inspections and approvals of portions of the Work required by the Contract Documents or by laws ordinances rules regulations or orders of public authorities having jurisdiction shall be made at an appropriate time Unless otherwise provided the Contractor shall make arrangements for such tests inspections and approvals with an independent testing laboratory or entity acceptable to the Owner or with the appropriate public authority and shall bear all related costs of tests inspections and approvals The contractor shall give the Owner timely notice of when and where tests and inspections are to be made so the Owner may observe such procedures The Owner shall bear costs of tests inspections or approvals which do not become requirements until after bids are received or negotiations concluded Fairgrounds I -tome Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities 1 1 DIVISION ZERO General Conditions of the Contract Section 00600 13 1 6 If the Owner or public authorities having jurisdiction determine that portions of the Work require additional testing inspection or approval, instruct the Contractor to make arrangements for such additional testing inspection or approval by an entity acceptable to the Owner and the Contractor shall give timely notice of when and where tests and inspections are to be made so the Owner may observe such procedures 13.1 7 If such procedures for testing inspection or approval reveal failure of the portions of the Work to comply with requirements established by the Contract Documents the Contractor shall bear all costs made necessary by such failure including those of repeated procedures 13.1 8 Required certificates of testing inspection or approval shall unless otherwise required by the Contract Documents be secured by the Contractor and promptly delivered to the Owner ARTICLE 14 TERMINATION 14 1 1 The Owner may terminate the Contract if the Contractor 1 refuses or fails to supply enough properly skilled workers or proper materials 2 fails to make payment to Subcontractors for materials or labor in accordance with the respective agreements between the Contractor and the Subcontractors 3 disregards laws ordinances or rules regulations or orders of a public authority having jurisdiction or 4 otherwise is guilty of substantial breach of a provision of the Contract Documents ARTICLE 15 PREVAILING WAGES 15 1 1 REQUIRED CONTRACTOR TO FILE STATEMENT OF INTENT TO PAY PREVAILING WAGES AND AFFIDAVIT OF WAGES PAID The prevailing rate of wage to be paid to all workmen laborers or mechanics employed in the performance of any part of this Contract shall be in accordance with the provisions of Chapter 39 12 RCW as amended and the rules and regulations of the Department of Labor and Industries of the State of Washington The prevailing wage rates for the locality or localities where this Contract will be performed shall be determined by the Industrial Statistician of the Department of Labor and Industries, and are by reference made a part of this contract as though fully set forth herein Current prevailing wage data is furnished by the Industrial Statistician 15 1.2 Statement of Intent to Pay Prevailing Wages The Contractor on or before the date of commencement of work, shall complete file and pay for a statement under oath with the Owner and with the Director of Labor and Industries certifying the rate of hourly wage paid and to be paid each classification of laborers workmen or mechanics employed upon the work by the Contractor or Subcontractor which shall be not less than the prevailing rate of wage (State Form LI 700 -29) State of Washington Department of Labor and Industries Statement of Intent to Pay Prevailing Wages on Public Contract' form Such statement and any subsequent statements shall be filed in accordance with the practices and procedures required by the Department of Labor and Industries Therefore the Contractor shall familiarize himself with this form and all its requirements. The Owner will not distribute any payments until all required certified copies of such forms are received 15 1 3 It is the responsibility of the Contractor to require all his Subcontractors to complete and pay for "Statement of Intent to Pay Prevailing Wages forms submit these documents to the Department of Labor and Industries for certification and forward certified copies to the Owner as proof that the prevailing wage requirements of RCW 39 12 040 have been satisfied Additional forms may be obtained from the Department of Labor and Industries Industrial Relations Division General Administration Building Olympia Washington 98504 and from all 15 service locations of the Department of Labor and Industries Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 15 1 5 The Contractor and Subcontractors shall further certify that: 15 1 4 Each voucher claim submitted by a Contractor for payment on.a project estimate shall state that prevailing wages have been paid in accordance with the pre -filed statement or statements of intent on file with the Department of Labor and Industrial Statistician a. He has not employed or retained any company or person (other than a full -time bona fide employee working solely for the offer or to solicit or receive this Contract and b He has not paid or agreed to pay any company or person (other than a full -time bona fide employee working solely for the offer or) any fee, commission percentage or brokerage fee contingent upon or resulting from the award of this Contract; and c He has not been asked or otherwise coerced either expressed or implied into contributing funds for any purpose as a condition to doing business with the Owner and d He agrees to furnish information relating to items 1,2 and 3 as requested by the contracting officer 15 1 6 It is further agreed that in case any dispute arises as to what are the prevailing wages for the work of a similar nature and such dispute cannot be adjusted by the parties involved the matter shall be referred for arbitration to the Director of the Department of Labor and Industries of the State and his decision therein shall be final binding and conclusive on all parties involved in the dispute 15 1 7 Upon completion of a Public Works Project, the Contractor for himself and on behalf of all Subcontractors shall file Affidavit of Wages Paid' forms. Forms properly executed by the Contractor and all Subcontractors shall be submitted with proper payment to Department of Labor and Industries Industrial Insurance Division Underwriting Section General Administration Building Olympia, WA 98504 Each Affidavit of Wages must be certified by the Industrial Statistician of the Department of Labor and Industries before it is submitted to the Owner Copies of all required statements must be on file with the Owner before the retained percentage is released 15 1 8 Upon completion of a Public Works project, the Contractor shall file a Release for the Protection of Property Owner and General Contractor' form (LI 206 -83 release 1 -67) with the Department of Labor and Industries The Owner will not disburse final payment or the Retainage to the Contractor until a release has been issued by the Department of Labor and Industries Contractor shall pay for all costs of obtaining and filing all Labor and Industries forms ARTICLE 16 OFFSHORE ITEMS 16 1 1 In compliance with RCW 39 25 the Contractor shall furnish the Owner a certified statement setting forth the nature and source to Offshore items in excess of $2,500 which have been utilized under each prime contract in the performance of the work. Offshore Items are those items procured from sources beyond the territorial boundaries of the United States including Alaska and Hawaii This certified statement is mandatory and shall be received before final payment is made on the contract. Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities 5 The Contractor will include the provisions of clauses 1 through 4 above in every Subcontract or purchase order so that such provisions will be upon each Subcontractor or vendor DIVISION ZERO General Conditions of the Contract Section 00600 ARTICLE 17 PREVENTION OF ENVIRONMENTAL POLLUTION AND PRESERVATION OF PUBLIC NATURAL RESOURCES 17 1 1 Pursuant to Chapter 62 Laws of 1973 1st Ex. Session those provisions of federal state and local statutes ordinances and regulations dealing with the prevention of environmental pollution and the preservation of public natural resources that affect, or are affected by the herein described project are to the extent they are reasonably obtainable as follows RCW 43.21 030 RCW 90 58 140 RCW 90 58 320 and RCW 70 94 152. Conform with the provisions thereof ARTICLE 18 DISCRIMINATION 18.1 1 The Contractor by entering this contract, agrees that Discrimination in all phases of employment is prohibited by Title VII of the Civil Rights Act of 1964 Presidential Executive Order 11375 the Washington State Law Against Discrimination Chapter 49 60 RCW and by Gubernatorial Executive Orders 66 -1 and 70 -01 among other laws and regulations 18 1.2 During the performance of this Contract, the Contractor agrees as follows 1 The Contractor will not discriminate against any employee or applicant for employment because of race creed color national origin sex, sexual orientation age marital status or the presence of any physical sensory or mental handicap nor shall the Contractor commit any of the other unfair practices defined in RCW 79 60 the Washington State Law Against Discrimination 2. The Contractor will in all solicitation or advertisements for employees placed by on without regard to race creed, color national origin sex, sexual orientation age marital status or the presence of any physical sensory or mental disability 3 The Contractor will send to each labor union employment agency or representative of workers with which the Contractor has a collective bargaining agreement or other contract or understanding a notice advising the labor union employment agency or workers representative of the Contractor's commitments under this contract and RCW 49 60 the Washington State Law Against Discrimination 4 The Contractor will permit access to its books records and accounts and to its premises by the Owner or the Washington State Human Rights Commission for the purpose of investigation to ascertain compliance with these specifications ARTICLE 19 COUNTY /CONTRACTOR RELATIONSHIP 19 1 1 In the event that either the state or federal government determines that an employer employee relationship exists rather than an independent contractor relationship such that Clallam County is deemed responsible for federal withholding social security contributions and the like the Contractor agrees to reimburse Clallam County for any payments made or required to be made by Clallam County Should any payments be due to the Contractor pursuant to this agreement, the Contractor agrees that reimbursement may be made by deducting from such future payments a pro rata share of the amount to be reimbursed based upon the following formula. Total amount to be reimbursed Deduction from payment Number of payments remaining Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ZERO General Conditions of the Contract Section 00600 Notwithstanding a determination by the state or federal government that employer employee relationship exists the Contractor its officers, employees and agents shall not be entitled to any benefits which Clallam County provides to its employees including but not limited to vacation and medical benefits 19 1 2 The status of the Contractor hereunder is that of an independent contractor and the Contractor shall not be construed to be an employee of Clallam County As an independent contractor the Contractor is not entitled to any benefits available to employees of Clallam County and the Contractor is responsible for withholding any moneys required to be withheld from the Contractor's employees pursuant to local, state or federal law including but not limited to worker's compensation social security and taxes. END OF SECTION 00600 Fairgrounds Home Arts Building Re Roof Division 00- General Conditions Clallam County Parks, Fair Facilities DIVISION ONE GENERAL REQUIREMENTS General Requirements Section 01001 GENERAL REQUIREMENTS 1 SUMMARY OF WORK A. Contract Description 1 Demolition and removal of existing roofing and Insulation 2. Installation of new R 13 vinyl faced insulation, new metal roofing rake fascia flashings gutters downspouts per drawings and specifications 3 Work typically associated with a project of this type and as described in the Contract Drawings and these specifications B The Contractor is responsible for verifying all systems assemblies and details of construction prepared by the Owner as being appropriate to and within the standard practices of the building trades involved The Contractor and all of his subcontractors and sub subcontractors shall have reviewed all documents thoroughly and shall report all discrepancies irregularities and items that differ from standard practices during the bidding phase The Contractor shall also be responsible to ensure proper coordination between all trades and all the corresponding documentation directing those trades. The Contractor shall also be responsible for confirmation of all manufacturers instructions and special requirements of the use and application of their products 2. WORK NOT IN CONTRACT A. NIC (Not in Contract) items are as follows 1 None 3 CONTRACTOR USE OF PREMISES A. The Contractor shall have access only to the areas where the new work is to be executed The Contractor shall coordinate with the Owner for staging construction and parking during construction which will be limited to the area of Work. Work times and dates shall be scheduled and approved by the Owner prior to start of work. 4 CUTTING AND PATCHING A. The Contractor shall execute all cutting and patching of existing conditions with the same skilled workmen with the same material supplies and with the same equipment as required for new work of the same type 5 UNIT PRICING 1 The cut and patched areas shall be left so that when the work of this Project is completed all evidence of the cutting and patching is removed 2 Texture finish and color of new or patched areas shall match that of the existing /adjacerfY construction A. Provide unit pricing for the following items 1 NONE Fairgrounds Home Arts Building Re Roof Division 0I General Requirements Clallam County Parks, Fair Facilities March 2006 DIVISION ONE GENERAL REQUIREMENTS General Requirements Section 01001 6 ALTERNATES A. Alternates quoted on Bid Forms will be reviewed and accepted or rejected at the Owner's option B Coordinate related Work as required for a proper installation of all the Work of this Contract. C Alternates Alternate No 1. Remove existing composition roofing at lower roof and replace with new 40- year composition roofing. 7 COORDINATION A. Coordinate scheduling submittals and Work of the various sections of specification to ensure efficient and orderly sequence of installation of interdependent construction elements with a minimum of public service disruption B Verify utility requirement characteristics of operating equipment are compatible with building utilities C Coordinate space requirements and installation of electrical work which is indicated diagrammatically on Drawings Follow routing shown for conduit and wiring as closely as practicable D In finished areas conceal pipes and wiring within the construction 8 EXAMINATION A. Verify that existing conditions and substrate surfaces are acceptable for subsequent Work. Submission of Bid means acceptance of existing conditions. 9 PREPARATION A. Clean substrate surfaces prior to applying next material or substance B Apply manufacturer required or recommended substrate primer sealer or conditioner prior to applying new material or substance in contact or bond 10 SUBMITTAL PROCEDURES A. Submittal form to identify Project, Contractor Subcontractor or supplier and pertinent Contract Document references B Apply Contractor's stamp signed or initialed certifying that review verification of Products required field dimensions adjacent construction Work, and coordination of information is in accordance with the requirements of the Work and Contract Documents prior to submitting the submittal for review by the Owner or Owner's representative Architect. C Identify variations from Contract Documents and Product or system limitations which may be detrimental to successful performance of the completed Work D Revise and submit submittals as required identify all changes made since previous submittal Fairgrounds Home Arts Building Re Roof Division 01 General Requirements Clallam County Parks, Fair Facilities March 2006 DIVISION ONE GENERAL REQUIREMENTS General Reouirements Section 01001 11 QUALITY ASSURANCE CONTROL OF INSTALLATION A. Monitor quality control over suppliers manufacturers products services site conditions and workmanship to produce Work of specified quality or when no level of quality is specified perform Work as would be standard for a custom installation B Comply with manufacturers instructions. C Comply with specified standards as minimum quality for the Work except when more stringent tolerances, codes or specified requirements indicate higher standards or more precise workmanship 12. TOLERANCES A. Monitor tolerance control of installed Products over suppliers manufacturers Products site conditions and workmanship to produce acceptable Work. Do not permit tolerances to accumulate B Comply fully with manufacturers tolerances 13 REFERENCES A. Conform to reference standards applicable for each system product, or assembly as commonly applied to each trade or discipline for this type of work and level of quality specified or implied by date of issue current as of date of Contract Documents B Should specified reference standard conflict with Contract Documents request clarification from Owner before proceeding 14 ELECTRICITY A. Cost: Contractor may use on site power for equipment related to this contract. B Provide power outlets for construction operations branch wiring distribution boxes and flexible power cords as required utilizing the existing building's power source or adjacent sources C Contractor shall be responsible for Electrical Permit and inspections as required 15. LIGHTING FOR CONSTRUCTION PURPOSES A. Provide and maintain lighting for construction operations 16 WATER A. Contractor may use on -site water 17 SANITARY FACILITIES A. The Contractor may use the on -site restroom facilities for the duration of the project. However it is expected that they will be kept clean and orderly Fairgrounds Home Arts Building Re Roof Division 01 General Requirements Clallam County Parks, Fair Facilities March 2006 DIVISION ONE GENERAL REQUIREMENTS General Reauirements Section 01001 18. ENCLOSURES A. Provide temporary closures for protection of adjacent existing conditions and barriers to protect the public from construction hazards Provide adequate fencing to secure site from public users. 19 PROTECTION OF INSTALLED WORK A. Protect installed Work and provide special protection where specified in individual specification sections. 20 SECURITY A. Provide security and facilities to protect Work and Owner's operations from unauthorized entry vandalism or theft. 21 PROGRESS CLEANING AND WASTE REMOVAL A. Collect and maintain areas free of waste materials debris and rubbish Maintain construction area in a clean and orderly condition Contractor responsible for all costs involved in waste removal. 22. REMOVAL OF UTILITIES, FACILITIES, AND CONTROLS A. Remove temporary utilities equipment, facilities materials prior to Final Completion review B Clean and repair damage caused by installation or use of temporary work. C Restore existing facilities used during construction to original condition Restore permanent facilities used during construction to specified condition 23. PRODUCTS A. Products means new material machinery components equipment, fixtures and systems forming the Work, but does not include machinery and equipment used for preparation fabrication conveying and erection of the work. Products may also include existing materials or components specifically identified for reuse B Do not use materials and equipment removed from existing premises except as specifically identified or allowed by the Contract Documents C Provide interchangeable components of the same manufacture for components being replaced and /or added in addition to existing components e g lighting switches receptacles etc 24 TRANSPORTATION HANDLING STORAGE AND PROTECTION A. Transport, handle store and protect Products in accordance with manufacturer's instructions 25. CONTRACT CLOSE -OUT PROCEDURES A. Submit written certification the Contract Documents have been reviewed Work has been inspected and that Work is complete in accordance with the General Conditions and the Contract Documents and ready for Owner inspection Fairgrounds Home Arts Building Re Roof Division 0I General Requirements Clallam County Parks, Fair Facilities March 2006 DIVISION ONE GENERAL REQUIREMENTS General Reauirements Section 01001 B Submit final Application for Payment identifying total adjusted Contract Sum /Price previous payments and amount remaining due C Complete and submit all required documentation covered in this Project Manual and the drawings 26. FINAL CLEANING A. Execute final cleaning prior to final inspection B Thoroughly clean interior and exterior surfaces exposed to view C Remove waste and surplus materials rubbish and construction facilities from the site 27 ADJUSTING A. Adjust operating Products and equipment to ensure smooth and unhindered operation 28 WARRANTIES A. Provide duplicate notarized copies B Execute and assemble transferable warranty documents from Subcontractors suppliers and manufacturers C Submit prior to final Application for Payment. END OF SECTION 01001 Fairgrounds Home Arts Building Re Roof Division 01 General Requirements Clallam County Parks, Fair Facilities March 2006 DIVISION SIX Section 06100 PART 1 GENERAL 11 SUMMARY A. Section Includes. 1 Miscellaneous lumber for attachment and support of other work. 2 Wood furring B Related Sections. 1 Section 07600 Flashing and Sheet Metal 1 2 DELIVERY STORAGE AND HANDLING A. Deliver and store the products to prevent excessive exposure and damage by other trades Protect from direct element exposure during storage Elevate one end of panels to drain any accumulated moisture PART 2 PRODUCTS 2.1 MISCELLANEOUS LUMBER Rouah Carpentry A. General. Provide lumber for support or attachment of other construction including the following 1 Blocking 2. Furring 3 Repair /replacement of existing construction B For items of dimensional lumber size provide Construction Stud or No 2 grade lumber with 19 percent maximum moisture content and any of the following species 1 Hem -fir or Hem -fir (north) NLGA, WCLIB or WWPA 2. Northern Species. NLGA 3 Western Woods WCLIB or WWPA C For items exposed to exterior provide pressure treated material of sizes appropriate for application PART 3 EXECUTION 31 EXAMINATION A. Upon removal of existing roofing and insulation inspect entire surface for any signs of rot or insect damage Notify Owner immediately upon discovery B Review existing roof structure to receive metal panels for obstructions loose framing members or voids Repair or replace unacceptable work which may affect proper material installation C Discrepancies between job site conditions and drawings (if provided) as approved shall be brought to the attention of the Owner's representative for resolution D Install new roofing per approved submittal drawings only E Caulk, seal and fasten so as to provide a complete weather -tight installation Fairgrounds Home Arts Building Re Roof Division 06- Wood Plastics Clallam County Parks, Fair Facilities March 2006 I I I I I I 1 I I I I I I I I I I I I DIVISION SIX Section 06100 3.2 CLEANING Rouah Caroentry A. Remove construction debris from roof surfaces and surrounding areas on a daily basis END OF SECTION 06100 Fairgrounds Home Arts Building Re Roof Division 06- Wood Plastics Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Buildme Insulation Section 07210 PART 1 GENERAL 1 1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division I Specification Sections, apply to this Section. 1.2 SUMMARY A. This Section includes the following: 1 Vinyl faced, glass fiber blanket insulation (metal building insulation) B Related Sections include the following: 1 Division 7 Section `Metal Roofing 1.3 SUBMITTALS A. Product Data. For each type of product indicated. 1 4 QUALITY ASSURANCE A. Source Limitations. Obtain each type of building insulation through one source B Fire Test Response Characteristics. Provide insulation and related materials with the fire- test response characteristics indicated, as determined by testing identical products per test method indicated below by UL or another testing and inspecting agency acceptable to authorities having jurisdiction. Identify materials with appropriate markings of applicable testing and inspecting agency l Surface Burning Characteristics ASTM E 84 2 Fire Resistance Ratings. ASTM E 119 3 Combustion Characteristics. ASTM E 136 1.5 DELIVERY STORAGE, AND HANDLING A. Protect insulation materials from physical damage and from deterioration by moisture, soiling, and other sources. Store inside and in a dry location. Comply with manufacturer's written instructions for handling, storing, and protecting during installation. Fairgrounds Home Arts Building Re Roof Division 07 Thermal 7 Moisture Protection Clallam County Parks, Fair Facilities March 2006 1 1 DIVISION SEVEN Buildine Insulation Section 07210 PART 2 PRODUCTS 2.1 ACCEPTABLE MANUFACTURERS A. Manufacturers Subject to compliance with requirements, provide products of one of the following: 1 Manufacturers of Glass Fiber Insulation. CertainTeed Corp Owens Corning Fiberglass Corp Guardian Fiberglass. 2.2 INSULATING MATERIALS A Faced, glass fiber blanket insulation ASTM C 665 type Ill Class A membrane faced blanket. Surface to have a flame- spread index of 25 or less Membrane face comprised of vinyl film facing with fiberglass- polyester blend fabric backing 1 R value /thickness R 13 4 blankets PART 3 EXECUTION 3 1 INSTALLATION GENERAL A. Comply with insulation manufacturer's written instructions applicable to products and application indicated. B Install insulation that is undamaged, dry and unsoiled and that has not been left exposed at any time to ice and snow C Extend insulation in thickness indicated to envelop entire area to be insulated Cut and fit tightly around obstructions and fill voids with insulation. Remove projections that interfere with placement. D Water Piping Coordination If water piping is located on inside of insulated exterior walls, coordinate location of piping to ensure that it is placed on warm side of insulation and insulation encapsulates piping. 3.2 INSTALLATION OF GENERAL BUILDING INSULATION A. Apply insulation units to substrates by method indicated, complying with manufacturer's written instructions. If no specific method is indicated, bond units to substrate with adhesive or use mechanical anchorage to provide permanent placement and support of units. B Set vapor retarder to warm side of construction, unless otherwise indicated. Do not obstruct ventilation spaces, except for firestopping. 1 Tape joints and ruptures in vapor retarder and seal each continuous area of insulation to surrounding construction to ensure airtight installation Fairgrounds Home Arts Building Re Roof Division 07 Thermal 7 Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Building_ Insulation Section 07210 3.3 INSTALLATION OF VAPOR RETARDERS C General Extend vapor retarder to extremities of areas to be protected from vapor transmission. Secure in place with adhesives or other anchorage system as indicated. Extend vapor retarder to cover miscellaneous voids in insulated substrates, including those filled with loose fiber insulation. D Seal vertical joints in vapor retarders over framing by lapping not less than 16' Fasten vapor retarders to framing at top, end, and bottom edges, at perimeter of wall openings and at lap joints. Space fasteners 16 inches o c. E. Firmly attach vapor retarders to substrates with mechanical fasteners or adhesives as recommended by vapor- retarder manufacturer F Seal joints caused by pipes, conduits, electrical boxes, and similar items penetrating vapor retarders with vapor- retarder tape to create an airtight seal between penetrating objects and vapor retarder G Repair any tears or punctures in vapor retarders immediately before concealment by other work. Cover with vapor- retarder tape or another layer of vapor retarder 3.3 PROTECTION A Protect installed insulation and vapor retarders from damage due to harmful weather exposures, physical abuse, and other causes. Provide temporary coverings or enclosures where insulation is subject to abuse and cannot be concealed and protected by permanent construction immediately after installation. END OF SECTION 07210 Fairgrounds Home Arts Building Re -Roof Division 07 Thermal 7 Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Metal Roofina Section 07400 PART 1 GENERAL 11 SUMMARY A. Section Includes 1 Preformed metal roof panels 2. Accessories including fasteners sealant, sealant tape closures and flashing B Related Sections. 1 Section 07600 Flashing and Sheet Metal 1.2 SUBMITTALS A. Product Data. Manufacturer's written technical information and installation instructions which demonstrate that materials to be installed with Contract Documents B Product Samples Submit samples for color selection 1 Submit manufacturer's standard profile sample color chips and published information as applies C Submit letter of compliance and conformance from the manufacturer 1 3 QUALITY ASSURANCE A. Installer Must be a certified applicator of the approved product and system with a minimum of ten (10) years of experience installing the products specified B Regulatory agency Requirements Comply with Building Code requirements if more restrictive than those specified herein C Testing and Certification Wind Up -Lift UL580 Class 90 Construction #130 UL Building Materials Directory B Reference Standard Flashing and gutters per recommendations of Sheet Metal and Air Conditioning Contractors National Association Inc. Architectural Sheet Metal Manual latest edition 14 WARRANTY A. Submit manufacturer's standard warranty guaranteeing to correct failures in product which may occur during the warranty period without reducing or otherwise limiting any other rights to correction which the Owner may have under the Contract Documents 1 Warrant the finish performance against crack, check, peel or flake changing color or chalking for twenty (20) years from date of substantial completion B Contractor's Guarantee The General Contractor and Metal Panel Sub Contractor shall jointly and unconditionally guarantee in writing the water- tightness of the total assembly for a period of three (3) years from the date of substantial completion This warranty constitutes a guarantee that the Contractor will furnish all labor and materials which may be necessary for repairs during this period The only exceptions to this guarantee are damages caused by the Owner or others and by fire smoke lightning and hail Fairgrounds Home Arts Building Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Metal Roofing Section 07400 1 5 DELIVERY STORAGE AND HANDLING A. Deliver and store the products to prevent excessive exposure and damage by other trades Protect from direct element exposure during storage. Elevate one end of panels to drain any accumulated moisture B Product shall be shipped with factory applied strippable plastic. C Handle products carefully so as to minimize damage from hoisting handling and installation Metal product and cartons /crafting shall not be used as a storage or work platform 1 6 PROJECT CONDITIONS A. Examine the conditions and substrates in which metal roofing is to be installed Substrate shall be level flat and true to avoid panel stresses B Field measurements shall be taken prior to fabrication of panels C Proceed with roofing installation only after satisfactory conditions are met. PART 2 PRODUCTS 21 MATERIALS A. Approved Manufacturer 1 Metal roofing as manufactured by Champion Metal of Washington Inc 2. Approved equal. None B Roof panel designation (specifications are based on Champion s Steel Snap -Loc) 1 Base Metal a. Material Steel b Manufacturing Standard ASTM A- 653 -94 Grade D or E. c. Thickness 26 gauge. d Minimum Yield Strength Min 50 000 psi for Grade E. e Protective Coating Galvanized G90 coating Min 1 25 oz. Of pure zinc per square foot. 2 Configuration a Panel Length Full length from ridge to eaves and from wall to eaves b Panels profile shall be Hi -Rib by Champion 3 Exterior Finish a. Panel Finish Galvanized Mill Finish b Salt Spray resistance ASTM B 117 humidity Resistance ASTM D -2247 and ASTM D -714 Abrasion Resistance ASTM D 968, Formability Test ASTM D 1737 C Fasteners 1 As per manufacturer's recommendations D Sealant: Fairgrounds Home Arts Building Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Section 07400 1 Use sealant with primer or sealant per manufacturer's recommendations E Profile Closures 1 Use material to match gauge and finish of roofing panel 2 Use neoprene or polyethylene foam die -cast or formed to panel configuration F Flashing Provide all Rake Corner Ridge Valley and all other miscellaneous trims and flashings required for a complete installation 1 Provide Rake Trim with profile and color to match existing 2 Use material of same gauge and finish 3 Dissimilar materials will not be allowed PART 3 EXECUTION 31 EXAMINATION A. Review substrate to receive metal panels for obstructions loose framing membranes or voids Repair or replace unacceptable work which may affect proper material installation B Install per approved submittal drawings only C Caulk, seal and fasten so as to provide a complete weather -tight installation Metal Roofing D Discrepancies between job site conditions and drawings (if provided) as approved shall be brought to the attention of the Owner's representative for resolution 3 2 PREPARATION A. General. 1 Remove projections and debris from substrate before starting installation 2 Secure all vent stacks curbs and other penetrations to substrate before starting panel installation 3 3 INSTALLATION A. General 1 Install roofing panels per manufacturer's specifications and NRCA s 'The NRCA Steep Roofing Manual' 2 Layout work with horizontal and vertical chalk lines B Flashing Materials and fabrication specified in 07600 1 Install flashing and edge protection to conform with installation details and instructions of The NRCA Steep Roofing Manual' and to provide a weathertight installation 3 4 CLEANING A. Remove construction debris from roof surfaces and surrounding areas on a daily basis B Touch -up areas as required or directed with manufacturer s standard touch -up paint. Follow instructions for application Fairgrounds Rome Arts Building Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Metal Roofing Section 07400 C Clean out gutters and downspouts of ALL debris whether organic or construction related D At completion leave project free from stains scraps scrapes and scratches E. Final inspection will be at the discretion of the Owner's representative END OF SECTION 07400 Fairgrounds Home Arts Building Re Roof Division 07 Thermal Moisture Protection CIaIIam County Parks, Fair Facilities March 2006 DIVISION SEVEN Flashina and Sheet Metal Section 07600 PART 1 GENERAL 11 SUMMARY A. Section Includes 1 Sheet metal flashing and trim 2. Gutters and downspouts. 3 Fasteners and attachment devices. 4 Coatings and slip- sheets to isolate sheet metal from dissimilar materials B Related Sections. 1 Section 07400 Metal Roofing 2. Section 07900 Sealant. 12 SUBMITTALS A. Shop Drawings Submit shop drawings showing layout, joining profiles and anchorages of fabricated work, layouts at scale of 1/4 inch per foot, details at scale of 3 inches per foot, as required for a proper installation PART 2 PRODUCTS 2 1 SHEET METAL A. Concealed Flashings Galvanized steel sheet, ASTM A 526 commercial quality G90 hot -dip galvanized 1 Minimum thickness 28 gauge (0 0239 inch) unless indicated otherwise B Exposed Flashings From the same materials as the metal roof and wall panels 1 Minimum thickness. 29 gauge unless indicated otherwise C Plumbing Stack and Electrical Mast Flashing As recommended by metal roof panel manufacturer D Gutters 5' wide J' style continuous aluminum Slope 1/8' per foot to downspout. 1 0 027' thick anodized aluminum 2 Color To be selected by Owner from standard color palette 3 Provide leaf strainers at downspout headers 4 Provide 2' x 3' square inserts at downspouts Seal with Elasto Capopolymer and rivet in place 5 Provide concrete splash blocks at all downspouts E. Downspouts 2' x 3' Aluminum anodized to match Gutters 1 Provide anchor straps at 30' o c. 2.2 ACCESSORY MATERIALS A. Fasteners Corrosion resistant metal of same material or as recommended by manufacturer of metal being fastened Exposed fastener heads where permitted to match color and finish of sheet material B Solder ASTM B 32 50/50 tin -lead rosin flux unless recommended otherwise by sheet metal manufacturer Fairgrounds Home Arts Building Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Flashina and Sheet Metal Section 07600 C Sealant: As specified in Section 07900 or as recommended by other material manufacturers 1 Use non curing type for concealed joints 2 Use non -sag elastomeric type for exposed joints 2.3 FABRICATION GENERAL A. From sheet metal work true to line and profiles indicated substantially free from oil canning buckling tool marks and other defects. B Comply with applicable portions of SMACNA Architectural Sheet Metal Manual C Provide for thermal expansion of exposed sheet metal work exceeding 15 feet running length 1 Flashing and trim Provide movement joints at maximum spacing of 10 feet; no joints allowed within 2 feet of corner or intersection 2 Gutters Provide movement joints at maximum spacing of 30 feet on center centered between downspouts D Conceal fasteners and expansion provisions wherever possible 1 Exposed fasteners are not allowed on faces of sheet metal exposed to public view E. Form a'A inch hem on underside of exposed edges F Fabricate cleats and attachment devices from same material as sheet metal component being anchored or from compatible non corrosive metal recommended by sheet metal manufacturer 1 Gauge As recommended by SMACNA or metal manufacturer for application but in no case less than gauge of metal being secured PART 3 EXECUTION 31 EXAMINATION A. Examine substrates and conditions under which products of this section are to be installed and verify that work may properly commence Do not proceed with the work until unsatisfactory conditions have been fully resolved 1 Verify that nailers blocking and other attachment provisions for sheet metal work are properly located and securely fastened to resist effects of wind and thermal stresses 3 2 PREPARATION A. Verify shapes and dimensions of surfaces to be covered before fabricating sheet metal B Isolate dissimilar metals by means of a heavy bituminous coating adhered polyethylene sheet, or other means approved by the Architect. 3 3 INSTALLATION A. General Except as otherwise indicated comply with manufacturer's installation instructions and recommendations and with SMACNA Architectural Sheet Metal Manual Anchor units of work securely in place by methods indicated providing for Fairgrounds Home Arts Building Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 1 1 1 1 1 1 1 1 1 1 1 1 DIVISION SEVEN Flashina and Sheet Metal Section 07600 thermal expansion in metal units Set units true to line and level indicated Install work with laps joints and seams permanently weatherproof and watertight. B Sealed Joints Form minimum 1 -inch hooked joints and embed flange into sealant or adhesive Form metal to completely conceal sealant or adhesive 1 Moving joints When ambient temperature is moderate (40 -70 degrees Fahrenheit) at time to installation set joined members for 50 per cent movement either way Adjust setting position of joined members proportionally for temperatures above 70 degrees Fahrenheit. Do not install sealant at temperatures below 40 degrees Fahrenheit. Refer to section on sealants elsewhere in Division 7 for handling and installation requirements for joint sealers C Soldered Joints 1 Do not solder prefinished sheet metal 2 Clean surfaces to be soldered removing oils and foreign matter 3 Pretin edges of sheets to be soldered to a width of 1 1/2 inches except where pretinned surface would show in the finished work 4 Do not use torches for soldering 5 Heat surfaces to receive solder and flow into joint. Fill joint completely 6 Rivet joints where additional strength is required 7 Completely remove flux and spatter from exposed surfaces 3 4 CLEANING AND PROTECTION A. Repair or replace work that is damaged or defaced as directed by the Architect. B Provide final protection in a manner which is acceptable to the installer and which ensures that sheet metal work will be without damage or deterioration at time of substantial completion END OF SECTION 07600 Fairgrounds Home Arts Building Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Sealant Section 07900 PART 1 GENERAL 11 SUMMARY A. Section Includes 1 The sealing of joints indicated on schedule at the end of this section 2 The sealing of other joints indicated on drawings B Joints of similar nature to those indicated on the schedule shall be sealed with same sealer whether indicated on drawings to be sealed or not. 1 2 PROJECT CONDITIONS A. Environmental Conditions Do not proceed with installation of sealers under the following conditions 1 When ambient and substrate temperature conditions are outside the limits permitted by sealer manufacturer or below 40 degrees Fahrenheit (4 4 degrees Centigrade) 2 When substrates are wet due to rain frost, condensation or other causes B Joint Dimension Conditions Do not proceed with installation of sealers when joint dimensions are less than recommended by joint sealer manufacturer for application indicated PART 2 PRODUCTS 2 1 MATERIALS GENERAL A. General Provide only products which are recommended and approved by their manufacturer for the specific use to which they are put, and which comply with all requirements of the Contract Documents. 1 Single source responsibility Obtain sealer materials from a single manufacturer for each generic product required 2 Compatibility Provide sealers fillers and other related materials that are compatible with one another and with joint substrates under conditions of service and application as demonstrated by testing and field experience 3 Colors of exposed sealers As indicated or if not otherwise indicated as selected by the Architect from manufacturer's standard colors B Products The products listed for each generic type provided they comply with requirements of the Contract Documents will be among those considered acceptable 2 2 ELASTOMERIC JOINT SEALERS A. Non Skinning Butyl: One -part, synthetic rubber sealant intended for concealed use on metal substrates. 1 Products a '757 Butyl Sealant' Protective Treatments Inc b JS 779' Tremco Inc B One -Part Nonsag Urethane Sealant: ASTM C 920 Type S Grade NS Class 25 Use NT 1 Products Fairgrounds Home Arts Building. Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Sealant Section 07900 a. Chem -Calk 900 Bostik Construction Products Division /ChemRex, Inc b Spec 3000' Geocel Corporation c 'Vulkem 116' Mameco International Inc. d Dynatrol I Pecora Corporation e Sikaflex 1A Sika Corporation f Sonolastic SP 1 Sonneborn Building Products Division /ChemRex, Inc. g Dymonic Tremco Inc. C One -Part Pourable Urethane Sealant: ASTM C 920 Type S Grade P Class 25 Use T 1 Products a 'Chem -Calk 950' Bostik Construction Products Division /Emhart Corporation b 'Vulkem 45 Mameco International, Inc. c Urexpan NR 201 Pecora Corporation d Sonolastic SL 1 Sonneborn Building Products Division /ChemRex Inc 2 3 LATEX JOINT SEALANT A. Acrylic -Latex Emulsion Sealant: One -part, nonsag mildew- resistant, acrylic emulsion sealant complying with ASTM C 834 formulated to be paintable and recommended for exposed applications on interior and on protected exterior exposures involving joint movement of not more than plus or minus 1 1/2 percent. 1 Products a Chem -Calk 600' Bostik Construction Products Division /Emhart Corporation b AC -20' Pecora Corporation c Sonolac Sonneborn Building Products Division /ChemRex, Inc d Tremco Acrylic Latex Caulk 834 Tremco Inc 2 4 JOINT FILLERS AND BACKING A. Plastic Foam Joint Filler Open cell polyurethane foam or nongassing closed -cell polyurethane foam subject to approval of sealant manufacturer B Bond Breaker Tape Plastic tape as recommended by sealant manufacturer for preventing bond between sealant and other materials at back (third) surface of joint. Provide self- adhesive tape where applicable PART 3 EXECUTION 3 1 PREPARATION A. Surface Cleaning of Joints 1 Remove all foreign material from joint substrates that could interface with adhesion of joint sealer 2. Clean porous joint substrate surfaces by brushing grinding blast cleaning mechanical abrading washing or a combination of these methods to produce a clean sound substrate capable of developing optimum bond with joint sealers 3 Remove laitance and form releaser agents from concrete 4 Clean nonporous substrate surfaces by chemical cleaners or other means that are not harmful to substrates or leave residues capable of interfering with adhesion of joint sealers Fairgrounds Home Arts Building. Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Sealant Section 07900 B Joint Priming Prime joint substrates where recommended by joint sealer manufacturer Apply primer to comply with joint sealer manufacturer's recommendations C Masking Tape Use masking tape where required to prevent contact of sealant with adjoining surfaces which otherwise would be permanently stained or damaged by such contact or by cleaning methods required to remove sealant smears Remove tape immediately after tooling without disturbing joint seal 3.2 INSTALLATION A. Comply with joint sealer manufacturer's printed installation instructions applicable to products and applications indicated except where more stringent requirements apply B Installation of Sealant Backings. 1 Install joint filler to provide support of sealant during application and at position required to produce the cross sectional shape and depth of installed sealant which allows optimum sealant movement capability a Do not leave gaps between ends of joint fillers b Do not stretch twist, puncture or tear joint fillers c. Remove absorbent joint fillers that have become wet prior to sealant application and replace with dry material 2 Install bond breaker tape between sealants and filler or back of joints where required to prevent third -side adhesion of sealant. C Installation of Sealants Install sealants by proven techniques that result in sealants directly contacting and fully wetting joint substrates completely filling recesses provided and providing uniform cross sectional shapes form optimum sealant movement capability D Tooling of Nonsag Sealants Immediately after sealant application and prior to time skinning or curing begins tool sealants to form smooth uniform beads of configuration indicated to eliminate air pockets and to ensure contact and adhesion of sealant with sides of joint. 3 3 PROTECTION AND CLEANING A. Protect joint sealers during and after curing period from contact with contaminating substances or from damage resulting from construction operations. Remove damaged or deteriorated joint sealers immediately and reseal joints with new materials to produce joint sealer installations with repaired areas indistinguishable from original work. B Clean off excess sealants or sealant smears adjacent to joints as work progresses by methods and with cleaning materials approved by manufacturers of joint sealers and of products in which joint occur 3 4 SCHEDULE OF JOINT SEALERS A. Exposed Non Traffic Exterior Joints 1 One -part nonsag urethane sealant. 2 Backer Plastic foam joint filler 3 Joint shape Concave joint configuration Fairgrounds Home Arts Building. Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 i DIVISION SEVEN Sealant Section 07900 B Exposed Non Traffic Interior Joints 1 Acrylic- emulsion latex sealant. 2. Backer Plastic foam joint filler 3 Joint shape Concave joint configuration C Concealed Metal to Metal Joints (within sheet metal roof accessory skylight, window and similar work) 1 Non skinning butyl sealant. 2 Joint shape Fillet or lap END OF SECTION 07900 Fairgrounds Home Arts Building. Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Asphalt Shingles Section 073111 SECTION 07311 ASPHALT SHINGLES PART 1 GENERAL 1 1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division 1 Specification Sections, apply to this Section 12 SUMMARY A This Section includes the following. 1 Asphalt shingles 2 Felt underlayment. B Related Sections include the following 1 Division 6 Section Rough Carpentry' for roof deck wood structural panels. 2 Division 7 Section Sheet Metal Flashing and Trim for metal roof penetration flashings and counterflashings not part of this Section. 1.3 SUBMITTALS A Product Data. For each type of product indicated B Samples for Verification For the following products, of sizes indicated, to verify color selected 1 Asphalt Shingle Full -size asphalt shingle strip 2 Ridge and Hip Cap Shingles Full -size ridge and hip cap asphalt shingle. 1 4 DELIVERY STORAGE, AND HANDLING A Store roofing materials in a dry well ventilated, weathertight location according to asphalt shingle manufacturer's written instructions Store underlayment rolls on end on pallets or other raised surfaces. Do not double -stack rolls. 1 Handle, store, and place roofing materials in a manner to avoid significant or permanent damage to roof deck or structural supporting members B Protect unused underlayment from weather sunlight, and moisture when left overnight or when roofing work is not in progress Fairgrounds Home Arts Building Re Roof March 2006 Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities DIVISION SEVEN Asphalt Shingles Section 0731 1 1 1 5 PROJECT CONDITIONS A. Weather Limitations. Proceed with installation only when existing and forecasted weather conditions permit asphalt shingle roofing to be performed according to manufacturer's written instructions and warranty requirements 16 WARRANTY A. Special Warranty Manufacturer's standard form in which manufacturer agrees to repair or replace asphalt shingles that fail in materials or workmanship within specified warranty period Materials failures include manufacturing defects and failure of asphalt shingles to self -seal after a reasonable time I Material Warranty Period 40 years from date of Substantial Completion, prorated with first 5 years nonprorated 2 Wind Speed Warranty Period Asphalt shingles will resist blow -off or damage caused by wind speeds up to 80 mph for 5 years from date of Substantial Completion 3 Algae Discoloration Warranty Period Asphalt shingles will not discolor 10 years from date of Substantial Completion 4 Workmanship Warranty Period 10 years from date of Substantial Completion B Special Project Warranty Roofing Installer's warranty on warranty form at end of this Section, signed by roofing Installer covering Work of this Section, in which roofing Installer agrees to repair or replace components of asphalt shingle roofing that fail in materials or workmanship within the following warranty period 1 Warranty Period Five years from date of Substantial Completion PART 2 PRODUCTS 2 1 GLASS -FIBER REINFORCED ASPHALT SHINGLES A Laminated -Strip Asphalt Shingles ASTM D 3462, laminated, multi -ply overlay construction, glass -fiber reinforced, mineral- granule surfaced, and self sealing. 1 Manufacturers. a. Celotex Corporation b CertainTeed Corporation c Elk Corporation of Dallas d. GAF Materials Corporation e Georgia Pacific Corporation f Owens Corning g. PABCO Roofing Products h TAMKO Roofing Products, Inc 2 Butt Edge Straight cut. 3 Strip Size Manufacturer's standard Fairgrounds Home Arts Building Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Asphalt Shingles Section 073111 4 Algae Resistance Granules treated to resist algae discoloration 5 Color and Blends: As selected by Architect from manufacturer's full range B Hip and Ridge Shingles Manufacturer's standard units to match asphalt shingles 2.2 UNDERLAYMENT MATERIALS A. Felts ASTM D 226 or ASTM D 4869 Type I, asphalt saturated organic felts, nonperforated 2.3 ACCESSORIES A Asphalt Roofing Cement: ASTM D 4586 Type II asbestos free B Roofing Nails ASTM F 1667 aluminum, stainless steel copper or hot -dip galvanized steel wire shingle nails, minimum 0 120-inch diameter smooth shank, sharp pointed with a minimum 3/8 inch- diameter flat head and of sufficient length to penetrate 3/4 inch into solid wood decking or extend at least 1/8 inch through OSB or plywood sheathing. 1 Where nails are in contact with metal flashing, use nails made from same metal as flashing. 2 4 METAL FLASHING AND TRIM A Sheet Metal Flashing and Trim Comply with requirements in Division 7 Section Sheet Metal Flashing and Trim. B Fabricate sheet metal flashing and trim to comply with recommendations in SMACNA s Architectural Sheet Metal Manual that apply to design, dimensions, metal, and other characteristics of item C Vent Pipe Flashings ASTM B 749 Type L51121 at least 1/16 inch thick. Provide lead sleeve sized to slip over and turn down into pipe, soldered to skirt at slope of roof and extending at least 4 inches from pipe onto roof PART 3 EXECUTION 31 EXAMINATION A Examine substrates, areas, and conditions, with Installer present, for compliance with requirements for installation tolerances and other conditions affecting performance of work. 1 Examine roof sheathing to verify that sheathing Joints are supported by framing and blocking or metal clips and that installation is within flatness tolerances 2 Verify that substrate is sound, dry smooth, clean sloped for drainage and completely anchored, and that provision has been made for flashings and penetrations through asphalt shingles Fairgrounds Home Arts Building Re Roof March 2006 Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities DIVISION SEVEN Asphalt Shingles Section 073111 B Proceed with installation only after unsatisfactory conditions have been corrected 3.2 UNDERLAYMENT INSTALLATION A Single Layer Felt Underlayment: Install single layer of felt underlayment on roof deck perpendicular to roof slope in parallel courses Lap sides a minimum of 2 inches over underlying course Lap ends a minimum of 4 inches Stagger end laps between succeeding courses at least 72 inches Fasten with felt underlayment nails 3.3 METAL FLASHING INSTALLATION A General Install metal flashings and other sheet metal to comply with requirements in Division 7 Section Sheet Metal Flashing and Trim Install metal flashings according to recommendations in ARMA s Residential Asphalt Roofing Manual and asphalt shingle recommendations in NRCA s 'The NRCA Roofing and Waterproofing Manual 3 4 ASPHALT SHINGLE INSTALLATION A Install asphalt shingles according to manufacturer's written instructions, recommendations in ARMA's Residential Asphalt Roofing Manual, and asphalt shingle recommendations in NRCA's 'The NRCA Roofing and Waterproofing Manual B Install starter strip along lowest roof edge, consisting of an asphalt shingle strip with tabs removed at least 7 inches wide with self sealing strip face up at roof edge 1 Extend asphalt shingles 3/4 inch over fascia at eaves and rakes 2 Install starter strip along rake edge C Install first and remaining courses of asphalt shingles stair stepping diagonally across roof deck with manufacturer's recommended offset pattern at succeeding courses, maintaining uniform exposure D Install asphalt shingles by single strip column or racking method, maintaining uniform exposure Install full length first course followed by cut second course, repeating alternating pattern in succeeding courses. E Fasten asphalt shingle strips with a minimum of six roofing nails located according to manufacturer's written instructions. 1 Where roof slope is less than 4 12, seal asphalt shingles with asphalt roofing cement spots 2 When ambient temperature during installation is below 50 deg F seal asphalt shingles with asphalt roofing cement spots Fairgrounds Home Arts Building Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Asphalt Shingles Section 073111 F Ridge Cap Shingles Maintain same exposure of cap shingles as roofing shingle exposure Lap cap shingles at ridges to shed water away from direction of prevailing winds Fasten with roofing nails of sufficient length to penetrate sheathing. 1 Fasten ridge cap asphalt shingles to cover ridge vent without obstructing airflow 3 5 ROOFING INSTALLER'S WARRANTY A WHEREAS of herein called the `Roofing Installer has performed roofing and associated work "work') on the following project. 1 Owner Clallam County 2 Address 223 East 4` Street, Suite 7 Port Angeles, WA 98362 3 Area of Work replacement roofing 4 Acceptance Date 5 Warranty Period 6 Expiration Date B AND WHEREAS Roofing Installer has contracted (either directly with Owner or indirectly as a subcontractor) to warrant said work against leaks and faulty or defective materials and workmanship for designated Warranty Period. C NOW THEREFORE Roofing Installer hereby warrants, subject to terms and conditions herein set forth, that during Warranty Period he will at his own cost and expense, make or cause to be made such repairs to or replacements of said work as are necessary to correct faulty and defective work and as are necessary to maintain said work in a watertight condition D This Warranty is made subject to the following terms and conditions 1 Specifically excluded from this Warranty are damages to work and other parts of the building, and to building contents, caused by a. lightning; b peak gust wind speed exceeding 80 mph, c fire, d failure of roofing system substrate, including cracking, settlement, excessive deflection, deterioration, and decomposition, e faulty construction of parapet walls, copings, chimneys, skylights, vents, equipment supports, and other edge conditions and penetrations of the work, f vapor condensation on bottom of roofing; and g. activity on roofing by others, including construction contractors, maintenance personnel, other persons, and animals, whether authorized or unauthorized by Owner 2 When work has been damaged by any of foregoing causes, Warranty shall be null and void until such damage has been repaired by Roofing Installer and until cost and expense thereof have been paid by Owner or by another responsible party so designated 3 Roofing Installer is responsible for damage to work covered by this Warranty but is not liable for consequential damages to building or building contents resulting from leaks or faults or defects of work. Fairgrounds Home Arts Building Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION SEVEN Asphalt Shingles Section 073111 4 During Warranty Period, if Owner allows alteration of work by anyone other than Roofing Installer including cutting, patching, and maintenance in connection with penetrations, attachment of other work, and positioning of anything on roof this Warranty shall become null and void on date of said alterations, but only to the extent said alterations affect work covered by this Warranty If Owner engages Roofing Installer to perform said alterations, Warranty shall not become null and void unless Roofing Installer before starting said work, shall have notified Owner in writing, showing reasonable cause for claim that said alterations would likely damage or deteriorate work, thereby reasonably justifying a limitation or termination of this Warranty 5 During Warranty Period, if original use of roof is changed, this Warranty shall become null and void on date of said change but only to the extent said change affects work covered by this Warranty 6 Owner shall promptly notify Roofing Installer of observed, known or suspected leaks, defects, or deterioration and shall afford reasonable opportunity for Roofing Installer to inspect work and to examine evidence of such leaks, defects, or deterioration 7 This Warranty is recognized to be the only warranty of Roofing Installer on said work and shall not operate to restrict or cut off Owner from other remedies and resources lawfully available to Owner in cases of roofing failure Specifically this Warranty shall not operate to relieve Roofing Installer of responsibility for performance of original work according to requirements of the Contract Documents, regardless of whether Contract was a contract directly with Owner or a subcontract with Owner's General Contractor E. IN WITNESS THEREOF this instrument has been duly executed this day of 2006 1 Authorized Signature 2 Name 3 Title END OF SECTION 07311 Fairgrounds Home Arts Building Re Roof Division 07 Thermal Moisture Protection Clallam County Parks, Fair Facilities March 2006 DIVISION NINE Exterior Painting Section 09900 PART 1 GENERAL 11 SUMMARY A. Provide All preparation and finishing as scheduled and specified Painting is required on all new areas of work and areas damaged or discolored due to demolition or other construction related mishaps Existing adjacent surfaces to match new 1 2 A. Finishing work of this Section as a system includes but is not limited to the following 1 Preparation of all surfaces required to be painted 2 Performance and completion of painting and finishing of all required exterior surfaces. B Definitions 1 Acceptable or Accepted' means acceptable to or by the Owner 2 Provide as used in this Section means Furnish and install or apply complete in place 3 Specialist' means an individual or firm of established reputation (or if newly organized whose personnel have previously established a reputation in the same field) This individual or firm must be regularly engaged in and maintain a regular force of workmen skilled in performing required work. 1 3 QUALITY ASSURANCE A. Sub Contractor /Applicator to be a 'Specialist' as defined in this Section B Manufacturers and Products Qualifications As listed in referenced manual 1 4 DELIVERY STORAGE AND HANDLING A. Delivery Deliver materials to project site in original, new unopened packages and containers bearing the manufacturer's name with label and the following information 1 Name or title of material. 2. Manufacturer's stock number and date of manufacture 3 Manufacturer's name 4 Contents by volume for major pigment and vehicle constituents 5 Thinning instructions 6 Application instructions 7 Color name and number B Store materials in tightly covered containers 1 Maintain containers in a clean condition free of foreign materials and residue. 2 Store materials at ambient temperature of between 45 degrees Fahrenheit minimum and 90 degrees Fahrenheit maximum in a well ventilated are or as specified by manufacturer 3 Ensure that storage area is neat and orderly Remove oily rags and waste daily C Take precautionary measures to prevent fire and health hazards Fairgrounds Home Arts Building March 2006 Division 09 Finishes Clallam County Parks, Fair Facilities DIVISION NINE Exterior Painting Section 09900 1 5 MAINTENANCE STOCK A. At time of completing application deliver stock of maintenance material to the Owner Furnish not less than one properly labeled and sealed one gallon can of each type of finish coat of each color taken from lots furnished for the Work. 1 6 ENVIRONMENTAL REQUIREMENTS A. Temperature Do no work of this Section when surfaces or air temperatures are below manufacturer's recommended temperature for conditions of installation B Weather Do no exterior work on unprotected surfaces if it is raining or moisture from any source is present or expected before finishes can dry or attain proper cure 17 WARRANTY A. Warranty period to extend for one years from date of Final Completion of the Project Work. PART 2 PRODUCTS 2.1 MANUFACTURERS A. Unless otherwise indicated all products are manufactured by Pittsburgh or Parker Paints Company 2.2 SCHEDULE OF COATINGS FOR BUILDING EXTERIOR /MISC TOUCH -UP A. Wood Trim 1 Primer 6 -609 Latex Wood Primer One (1) Coat. 2 Finish 77 -447 Series Latex Stain Two (2) Coats Note 1 After surface preparation apply primer only in locations where wood is exposed 2 3 COLOR A. Base building /trim color shall match existing PART 3 EXECUTION 3 1 INSPECTION A. Verify that all conditions and substrates are ready for Work of this Section including but not limited to heat and ventilation and moisture contents of the various substrates. 3 2 SURFACE PREPARATION A. Painted surfaces for each individual surface to be painted shall be prepared for each condition in accordance with the current industry standards Fairgrounds Home Arts Building March 2006 Division 09 Finishes Clallam County Parks, Fair Facilities DIVISION NINE Exterior Painting Section 09900 B Each area of deterioration shall be identified and confirmed by Owner prior to the execution of any preparation work. C Care shall be taken to not penetrate or damage existing siding /substrate materials. 1 In the event a material is severely damaged or penetrated during the preparation work, it shall be repaired per the prior approval of the Owner or replaced matching detail and material the existing and adjacent substrates B Test patches of all coating systems are required and to be approved by the Owner or their representatives. 3 3 PROTECTION A. Protect surrounding areas and surfaces to preclude damage during work of this section 1 As work proceeds and on completion of work, promptly remove all spilled splashed or splattered products by methods not damaging to surfaces 2 During work progress, keep premises free from any unnecessary accumulation of tools, equipment, surplus materials debris and the like 3 Protect completed work at the end of each work day 3 4 APPLICATION A. Perform the work in accordance with Quality Assurance provisions References Specifications and Manufacturer's directions Where these may be in conflict, the more stringent requirements shall govern B Do not paint over any code required labels, equipment identification or performance rating name or nomenclature plates. C Allow proper drying time between coats as recommended by paint manufacturer 3 5 CLEANING A. Cleaning Upon completion of Work, clean window glass and other areas of paint splatter or over -spray B Remove all debris from painting process such as tape cans brushes paper rags etc. END OF SECTION 09900 Fairgrounds Home Arts Building March 2006 Division 09- Finishes Clallam County Parks, Fair Facilities 1 I 1 1 1 1 1 1 1 1 1 1 State of Washington DEPARTMENT OF LABOR AND INDUSTRIES Prevailing Wage Section Telephone (360) 902 5335 PO Box 44540 Olympia, WA 98504 -4540 Washington State Prevailing Wage Rates For Public Works Contracts The PREVAILING WAGES listed here include both the hourly wage rate and the hourly rate of fringe benefits On public works projects, workers wage and benefit rates must add to not less than this total. A brief description of overtime calculation requirements is provided on the Benefit Code Key CLALLAM COUNTY Effective 03 -03 -06 Classification ASBESTOS ABATEMENT WORKERS JOURNEY LEVEL $33 46 1N 5D BOILERMAKERS JOURNEY LEVEL $46 32 1C 5N BRICK AND MARBLE MASONS JOURNEY LEVEL $41 17 1M 5A CABINET MAKERS (IN SHOP) JOURNEY LEVEL $14 67 1 CARPENTERS ACOUSTICAL WORKER $40.23 1M 5D BRIDGE, DOCK AND WARF CARPENTERS $40 07 1M 5D CARPENTER $40 07 1M 5D CREOSOTED MATERIAL $40 17 1M 5D DRYWALL APPLICATOR $40 22 1M 5D FLOOR FINISHER $40 20 1M 5D FLOOR LAYER $40.20 1M 5D FLOOR SANDER $40.20 1M 5D MILLWRIGHT AND MACHINE ERECTORS $41 07 1M 5D PILEDRIVERS, DRIVING PULLING, PLACING COLLARS AND WELDING $40.27 1M 5D SAWFILER $40.20 1M 5D SHINGLER $40.20 1M 5D STATIONARY POWER SAW OPERATOR $40 20 1M 5D STATIONARY WOODWORKING TOOLS $40.20 1M 5D CEMENT MASONS JOURNEY LEVEL $33 46 1N 5D DIVERS TENDERS DIVER $83 19 1M 5D 8A DIVER TENDER $39 51 1M 5D DREDGE WORKERS ASSISTANT ENGINEER $40 77 1T 5D 8L ASSISTANT MATE (DECKHAND) $40 28 1T 5D 8L BOATMEN $40 77 1T 5D 8L ENGINEER WELDER $40 82 1T 5D 8L LEVERMAN, HYDRAULIC $42.34 1T 5D 8L MAINTENANCE $40.28 1T 5D 8L MATES $40 77 1T 5D 8L OILER $40 40 1T 5D 8L DRYWALL TAPERS JOURNEY LEVEL $40.29 1E 5P ELECTRICAL FIXTURE MAINTENANCE WORKERS JOURNEY LEVEL $9 37 1 Page 1 (See Benefit Code Key) Over PREVAILING Time Holiday Note WAGE Code Code Code Classification ELECTRICIANS INSIDE CABLE SPLICER CABLE SPLICER (TUNNEL) CERTIFIED WELDER CERTIFIED WELDER (TUNNEL) CONSTRUCTION STOCK PERSON JOURNEY LEVEL JOURNEY LEVEL (TUNNEL) ELECTRICIANS MOTOR SHOP CRAFTSMAN JOURNEY LEVEL ELECTRICIANS POWERLINE CONSTRUCTION CABLE SPLICER CERTIFIED LINE WELDER GROUNDPERSON HEAD GROUNDPERSON HEAVY LINE EQUIPMENT OPERATOR JACKHAMMER OPERATOR JOURNEY LEVEL LINEPERSON LINE EQUIPMENT OPERATOR POLE SPRAYER POWDERPERSON ELECTRONIC TECHNICIANS ELECTRONIC TECHNICIANS JOURNEY LEVEL ELEVATOR CONSTRUCTORS MECHANIC MECHANIC IN CHARGE FABRICATED PRECAST CONCRETE PRODUCTS ALL CLASSIFICATIONS FENCE ERECTORS FENCE ERECTOR FENCE LABORER FLAGGERS JOURNEY LEVEL GLAZIERS JOURNEY LEVEL HEAT FROST INSULATORS AND ASBESTOS WORKERS MECHANIC HEATING EQUIPMENT MECHANICS MECHANIC HOD CARRIERS MASON TENDERS JOURNEY LEVEL INDUSTRIAL ENGINE AND MACHINE MECHANICS MECHANIC INDUSTRIAL POWER VACUUM CLEANER JOURNEY LEVEL INLAND BOATMEN CAPTAIN COOK DECKHAND ENGINEER/DECKHAND MATE, LAUNCH OPERATOR CLALLAM COUNTY Effective 03 -03 -06 Page 2 (See Benefit Code Key) Over PREVAILING Time Holiday Note WAGE Code Code Code $50 60 1D 5A $54 40 1D 5A $48 88 1D 5A $52.50 1D 5A $26 72 10 5A $4715 10 5A $50 60 1D 5A $15 37 2A 6C $14 69 2A 6C $52.38 4A 5A $47 88 4A 5A $34 87 4A 5A $36 75 4A 5A $47 88 4A 5A $36 75 4A 5A $47 88 4A 5A $40 87 4A 5A $47 88 4A 5A $36.75 4A 5A $12.07 1 $55.22 4A 6Q $60 60 4A 6Q $13 50 1 $13 80 1 $11 60 1 $28 78 1N 5D $41 15 1H 5G $43 68 1S 5J $16 00 1 $33 94 1N 5D $15 65 1 $9 07 1 $36.83 1K 5B $31.21 1K 5B $30 58 1K 5B $33.25 1K 5B $34 87 1K 5B CLALLAM COUNTY Effective 03 -03 -06 (See Benefit Code Key) Over PREVAILING Time Holiday Note Classification WAGE Code Code Code INSPECTION /CLEANING /SEALING OF SEWER WATER SYSTEMS BY REMOTE CONTROL CLEANER OPERATOR, FOAMER OPERATOR $9 73 1 GROUT TRUCK OPERATOR $11 48 1 HEAD OPERATOR $12.78 1 TECHNICIAN $7 63 1 TV TRUCK OPERATOR $10 53 1 INSULATION APPLICATORS JOURNEY LEVEL $20 50 1 IRONWORKERS JOURNEY LEVEL $44 61 10 5A LABORERS ASPHALT RAKER $33 94 1N 5D BALLLASTREGULATOR MACHINE $33 46 1N 5D BATCH WEIGHMAN $28 78 IN 5D BRUSH CUTTER $33 46 1N 5D BRUSH HOG FEEDER $33 46 1N 5D BURNERS $33 46 1N 5D CARPENTER TENDER $33 46 1N 5D CASSION WORKER $34 30 1N 5D CEMENT DUMPER /PAVING $33 94 1N 5D CEMENT FINISHER TENDER $33 46 1N 5D CHANGE -HOUSE MAN OR DRY SHACKMAN $33 46 1N 5D CHIPPING GUN (OVER 30 LBS) $33 94 1N 5D CHIPPING GUN (UNDER 30 LBS) $33 46 1N 5D CHOKER SETTER $33 46 1N 5D CHUCK TENDER $33 46 1N 5D CLEAN -UP LABORER $33 46 1N 5D CONCRETE DUMPER /CHUTE OPERATOR $33.94 1N 5D CONCRETE FORM STRIPPER $33 46 1N 5D CONCRETE SAW OPERATOR $33 94 1N 5D CRUSHER FEEDER $28.78 1N 5D CURING LABORER $33 46 1N 5D DEMOLITION, WRECKING MOVING (INCLUDING CHARRED $33.46 1N 5D DITCH DIGGER $33 46 1N 50 DIVER $34 30 1N 5D DRILL OPERATOR (HYDRAULIC DIAMOND) $33 94 1N 5D DRILL OPERATOR, AIRTRAC $34 30 1N 5D DUMPMAN $33.46 1N 5D EPDXY TECHNICIAN $33 46 1N 5D EROSION CONTROL WORKER $33 46 1N 5D FALLER/BUCKER, CHAIN SAW $33 94 1N 5D FINAL DETAIL CLEANUP (i.e. dusting, vacuuming, window cleaning NOT $26 46 1N 5D construction debris cleanup) FINE GRADERS $33 46 1N 5D FIRE WATCH $28 78 1N 5D FORM SETTER $33 46 1N 5D GABION BASKET BUILDER $33 46 1N 5D GENERAL LABORER $33.46 1N 5D GRADE CHECKER TRANSIT PERSON $33.94 1N 5D GRINDERS $33 46 1N 5D GROUT MACHINE TENDER $33 46 1N 5D Page 3 Classification CLALLAM COUNTY Effective 03 -03 -06 GUARDRAIL ERECTOR $33 46 1N 5D HAZARDOUS WASTE WORKER LEVEL A $34 30 1N 5D HAZARDOUS WASTE WORKER LEVEL B $33 94 1N 5D HAZARDOUS WASTE WORKER LEVEL C $33 46 1N 5D HIGH SCALER $34 30 1N 5D HOD CARRIER /MORTARMAN $33 94 1N 5D JACKHAMMER $33 94 1N 5D LASER BEAM OPERATOR $33.94 1N 5D MANHOLE BUILDER- MUDMAN $33 94 1N 5D MATERIAL YARDMAN $33 46 1N 5D MINER $34 30 1N 5D NOZZLEMAN, CONCRETE PUMP GREEN CUTTER WHEN USING HIGH $33 94 1N 5D PRESSURE AIR WATER ON CONCRETE ROCK, SANDBLAST GUNITE, SHOTCRETE, WATER BLASTER PAVEMENT BREAKER $33 94 1 N 5D PILOT CAR $28 78 1N 5D PIPE POT TENDER $33 94 1 N 5D PIPE RELINER (NOT INSERT TYPE) $33 94 1N 5D PIPELAYER CAULKER $33 94 1N 5D PIPELAYER CAULKER (LEAD) $34 30 1N 5D PIPEWRAPPER $33 94 1 N 50 POT TENDER $33 46 1N 5D POWDERMAN $34 30 1N 5D POWDERMAN HELPER $33 46 1N 5D POWERJACKS $33 94 1N 5D RAILROAD SPIKE PULLER (POWER) $33 94 1N 5D RE TIMBERMAN $34 30 IN 5D RIPRAP MAN $33 46 1N 5D RODDER $33 94 1N 5D SCAFFOLD ERECTOR $33 46 1N 5D SCALE PERSON $33 46 1N 5D SIGNALMAN $33 46 1N 5D SLOPER (OVER 20 $33 94 1N 5D SLOPER SPRAYMAN $33 46 1N 5D SPREADER (CLARY POWER OR SIMILAR TYPES) $33 94 1N 5D SPREADER (CONCRETE) $33 94 1N 5D STAKE HOPPER $33 46 1N 5D STOCKPILER $33.46 IN 5D TAMPER SIMILAR ELECTRIC, AIR GAS $33 94 1N 5D TAMPER (MULTIPLE SELF PROPELLED) $33.94 1N 5D TOOLROOM MAN (AT JOB SITE) $33 46 1N 5D TOPPER TAILER $33 46 1N 5D TRACK LABORER $33 46 1N 5D TRACK LINER (POWER) $33 94 1N 5D TRUCK SPOTTER $33 46 1N 5D TUGGER OPERATOR $33 94 1N 5D VIBRATING SCREED (AIR, GAS, OR ELECTRIC) $33.46 1N 5D VIBRATOR $33.94 1N 5D VINYL SEAMER $33.46 1N 5D WELDER $33 46 1N 5D WELL -POINT LABORER $33 94 1N 5D Page 4 (See Benefit Code Key) Over PREVAILING Time Holiday Note WAGE Code Code Code I I CLALLAM COUNTY Effective 03 -03 -06 (See Benefit Code Key) Over PREVAILING Time Holiday Note Classification WAGE Code Code Code LABORERS UNDERGROUND SEWER WATER GENERAL LABORER $33 46 1N 5D PIPE LAYER $33 94 1N 5D LANDSCAPE CONSTRUCTION IRRIGATION OR LAWN SPRINKLER INSTALLERS $11 42 1 LANDSCAPE EQUIPMENT OPERATORS OR TRUCK DRIVERS $7 81 1 LANDSCAPING OR PLANTING LABORERS $7 93 1 LATHERS JOURNEY LEVEL $40.22 1M 5D METAL FABRICATION (IN SHOP) FITTER/WELDER $15 16 1 LABORER $11 13 1 MACHINE OPERATOR $10 66 1 PAINTER $1 1 41 1 PAINTERS JOURNEY LEVEL $32.63 2B 5A PLASTERERS JOURNEY LEVEL $25 83 1 PLAYGROUND PARK EQUIPMENT INSTALLERS JOURNEY LEVEL $7 93 1 PLUMBERS PIPEFITTERS JOURNEY LEVEL $53 39 1G 5A POWER EQUIPMENT OPERATORS ASSISTANT ENGINEERS $38 42 1T 5D 8L BACKHOE, EXCAVATOR, SHOVEL (3 YD UNDER) $41 12 IT 5D 8L BACKHOE, EXCAVATOR, SHOVEL (OVER 3 YD UNDER 6 YD) $41 59 1T 5D 8L BACKHOE, EXCAVATOR, SHOVEL (6 YD AND OVER WITH $42.13 IT 5D 8L BACKHOES, (75 HP UNDER) $40 71 1T 5D 8L BACKHOES, (OVER 75 HP) $41 12 1T 5D 8L BARRIER MACHINE (ZIPPER) $41 12 1T 5D 8L BATCH PLANT OPERATOR, CONCRETE $41 12 1T 5D 8L BELT LOADERS (ELEVATING TYPE) $40 71 1T 5D 8L BOBCAT (SKID STEER) $38 42 1T 5D 8L BROOMS $38 42 1T 5D 8L BUMP CUTTER $41 12 1T 5D 8L CABLEWAYS $41 59 1T 5D 8L CHIPPER $41 12 1T 5D 8L COMPRESSORS $38 42 1T 5D 8L CONCRETE FINISH MACHINE LASER SCREED $38 42 1T 5D 8L CONCRETE PUMPS $40 71 1T 5D 8L CONCRETE PUMP TRUCK MOUNT WITH BOOM ATTACHMENT $41 12 1T 5D 8L CONVEYORS $40 71 1T 5D 8L CRANES THRU 19 TONS WITH ATTACHMENTS $40 71 1T 5D 8L CRANES, 20 44 TONS WITH ATTACHMENTS $41 12 1T 50 8L CRANES, 45 TONS 99 TONS, UNDER 150 FT OF BOOM (INCLUDING $41 59 1T 5D 8L JIB WITH ATACHMENTS) CRANES, 100 TONS 199 TONS OR 150 FT OF BOOM (INCLUDING JIB $42.13 1T 5D 8L WITH ATTACHMENTS) CRANES, 200 TONS TO 300 TONS, OR 250 FT OF BOOM (INCLUDING JIB $42.68 1T 50 8L WITH ATTACHMENTS) CRANES, A- FRAME, 10 TON AND UNDER $38 42 1T 5D 8L CRANES, A- FRAME, OVER 10 TON $40 71 1T 5D 8L Page 5 Classification CLALLAM COUNTY Effective 03 -03 -06 CRANES, OVER 300 TONS OR 300' OF BOOM INCLUDING JIB WITH ATTACHMENTS CRANES, OVERHEAD BRIDGE TYPE (20 44 TONS) CRANES, OVERHEAD BRIDGE TYPE (45 99 TONS) CRANES, OVERHEAD BRIDGE TYPE (100 TONS OVER) CRANES, TOWER CRANE UP TO 175' IN HEIGHT BASE TO BOOM CRANES, TOWER CRANE OVER 175' IN HEIGHT BASE TO BOOM CRUSHERS DECK ENGINEER /DECK WINCHES (POWER) DERRICK, BUILDING DOZERS, D -9 UNDER DRILL OILERS AUGER TYPE, TRUCK OR CRANE MOUNT DRILLING MACHINE ELEVATOR AND MANLIFT PERMANENT AND SHAFT TYPE EQUIPMENT SERVICE ENGINEER (OILER) FINISHING MACHINE/BIDWELL GAMACO AND SIMILAR EQUIP FORK LIFTS (3000 LBS AND OVER) FORK LIFTS, (UNDER 3000 LBS) GRADE ENGINEER GRADECHECKER AND STAKEMAN GUARDRAIL PUNCH HOISTS, OUTSIDE (ELEVATORS AND MANLIFTS) AIR TUGGERS HORIZONTAUDIRECTIONAL DRILL LOCATOR HORIZONTAUDIRECTIONAL DRILL OPERATOR HYDRALIFTS /BOOM TRUCKS (10 TON UNDER) HYDRALIFTS /BOOM TRUCKS (OVER 10 TON) LOADERS, OVERHEAD (6 YD UP TO 8 YD) LOADERS, OVERHEAD (8 YD OVER) LOADERS, OVERHEAD (UNDER 6 YD), PLANT FEED LOCOMOTIVES, ALL MECHANICS, ALL MIXERS, ASPHALT PLANT MOTOR PATROL GRADER (FINISHING) MOTOR PATROL GRADER (NON- FINISHING) MUCKING MACHINE, MOLE, TUNNEL DRILL AND /OR SHIELD OIL DISTRIBUTORS, BLOWER DISTRIBUTION AND MULCH SEEDING OPERATOR PAVEMENT BREAKER PILEDRIVER (OTHER THAN CRANE MOUNT) PLANT OILER (ASPHALT CRUSHER) POSTHOLE DIGGER, MECHANICAL POWER PLANT PUMPS, WATER QUAD 9, D -10 AND HD -41 REMOTE CONTROL OPERATOR ON RUBBER TIRED EARTH MOVING EQUIP RIGGER AND BELLMAN ROLLAGON ROLLER, OTHER THAN PLANT ROAD MIX ROLLERS, PLANTMIX OR MULTILIFT MATERIALS ROTO -MILL, ROTO- GRINDER SAWS, CONCRETE Page 6 (See Benefit Code Key) Over PREVAILING Time Holiday Note WAGE Code Code Code $43.22 1T 5D 8L $41 12 1T 5D 8L $41 59 IT 5D 8L $42.13 1T 5D 8L $42.13 1T 5D 8L $42.68 1T 5D 8L $41 12 1T 5D 8L $41 12 1T 5D 8L $41 59 1T 5D 8L $40 71 1T 5D 8L $40 71 1T 5D 8L $41 12 1T 5D 8L $38 42 1T 5D 8L $40 71 1T 5D 8L $41 12 1T 5D 8L $40 71 IT 5D 8L $38 42 1T 5D 8L $40 71 1T 5D 8L $38 42 1T 5D 8L $41 12 1T 5D 8L $40 71 1T 5D 8L $40 71 1T 5D 8L $41 12 1T 5D 8L $38.42 1T 5D 8L $40 71 1T 5D 8L $41 59 1T 5D 8L $42.13 1T 5D 8L $41 12 1T 5D 8L $41 12 1T 5D 8L $41 59 1T 5D 8L $41 12 1T 5D 8L $41 12 1T 5D 8L $40 71 1T 5D 8L $41 59 1T 5D 8L $38 42 1T 5D 8L $38 42 1T 5D 8L $41 12 1T 5D 8L $40 71 1T 5D 8L $38 42 1T 5D 8L $38.42 1T 5D 8L $38.42 1T 5D 8L $41 59 1T 5D 8L $41 59 1T 5D 8L $38.42 1T 5D 8L $41 59 IT 5D 8L $38 42 1T 5D 8L $40 71 1T 5D 8L $41 12 1T 5D 8L $40 71 1T 5D 8L 1 i 1 CLALLAM COUNTY Effective 03 -03 -06 (See Benefit Code Key) Over PREVAILING Time Holiday Note Classification WAGE Code Code Code SCRAPERS SELF PROPELLED HARD TAIL END DUMP ARTICULATING $41 12 1T 5D 8L OFF -ROAD EQUIPMENT UNDER 45 YD) SCRAPERS SELF PROPELLED HARD TAIL END DUMP ARTICULATING $41 59 1T 5D 8L OFF -ROAD EQUIPMENT (45 YD AND OVER) SCRAPERS, CONCRETE AND CARRY ALL $40 71 1T 5D 8L SCREED MAN $41 12 1T 5D 8L SHOTCRETE GUNITE $38 42 1T 5D 8L SLIPFORM PAVERS $41 59 1T 5D 8L SPREADER, TOPSIDE OPERATOR BLAW KNOX $41 12 1T 50 8L SUBGRADETRIMMER $41 12 1T 5D 8L TOWER BUCKET ELEVATORS $40 71 1T 5D 8L TRACTORS, (75 HP UNDER) $40 71 1T 5D 8L TRACTORS, (OVER 75 HP) $41 12 1T 5D 8L TRANSFER MATERIAL SERVICE MACHINE $41 12 1T 5D 8L TRANSPORTERS ALL TRACK OR TRUCK TYPE $41 59 1T 5D 8L TRENCHING MACHINES $40 71 1T 5D 8L TRUCK CRANE OILER /DRIVER UNDER 100 TON) $40 71 1T 5D 8L TRUCK CRANE OILER /DRIVER (100 TON OVER) $41 12 1T 5D 8L TRUCK MOUNT PORTABLE CONVEYER $41 12 1T 5D 8L WHEEL TRACTORS FARMALL TYPE $38 42 1T 5D 8L YO YO PAY DOZER $41 12 1T 5D 8L POWER EQUIPMENT OPERATORS- UNDERGROUND SEWER (SEE POWER EQUIPMENT OPERATORS) POWER LINE CLEARANCE TREE TRIMMERS JOURNEY LEVEL IN CHARGE $34 75 4A 5A SPRAY PERSON $33 00 4A 5A TREE EQUIPMENT OPERATOR $33 43 4A 5A TREE TRIMMER $31 10 4A 5A TREE TRIMMER GROUNDPERSON $23 43 4A 5A REFRIGERATION AIR CONDITIONING MECHANICS MECHANIC $27 68 1 RESIDENTIAL BRICK MARBLE MASONS JOURNEY LEVEL $41 17 1M 5A RESIDENTIAL CARPENTERS JOURNEY LEVEL $17 85 1 RESIDENTIAL CEMENT MASONS JOURNEY LEVEL $25 63 1 RESIDENTIAL DRYWALL TAPERS JOURNEY LEVEL $18 00 1 RESIDENTIAL ELECTRICIANS JOURNEY LEVEL $27 78 1 RESIDENTIAL GLAZIERS JOURNEY LEVEL $16 84 1 RESIDENTIAL INSULATION APPLICATORS JOURNEY LEVEL $9 86 1 RESIDENTIAL LABORERS JOURNEY LEVEL $18 08 1 RESIDENTIAL PAINTERS JOURNEY LEVEL $15 97 1 RESIDENTIAL PLUMBERS PIPEFITTERS JOURNEY LEVEL $14 60 1 Page 7 CLALLAM COUNTY Effective 03 -03 -06 Classification RESIDENTIAL REFRIGERATION AIR CONDITIONING JOURNEY LEVEL RESIDENTIAL SHEET METAL WORKERS JOURNEY LEVEL (FIELD OR SHOP) RESIDENTIAL SOFT FLOOR LAYERS JOURNEY LEVEL RESIDENTIAL SPRINKLER FITTERS (FIRE PROTECTION) JOURNEY LEVEL ROOFERS JOURNEY LEVEL USING IRRITABLE BITUMINOUS MATERIALS SHEET METAL WORKERS JOURNEY LEVEL (FIELD OR SHOP) SIGN MAKERS INSTALLERS (ELECTRICAL) JOURNEY LEVEL SIGN MAKERS INSTALLERS (NON- ELECTRICAL) JOURNEY LEVEL SOFT FLOOR LAYERS JOURNEY LEVEL SOLAR CONTROLS FOR WINDOWS JOURNEY LEVEL SPRINKLER FITTERS (FIRE PROTECTION) JOURNEY LEVEL STAGE RIGGING MECHANICS (NON STRUCTURAL) JOURNEY LEVEL SURVEYORS CHAIN PERSON INSTRUMENT PERSON PARTY CHIEF TELECOMMUNICATION TECHNICIANS TELECOMMUNICATION TECHNICIANS JOURNEY LEVEL TELEPHONE LINE CONSTRUCTION OUTSIDE CABLE SPLICER HOLE DIGGER/GROUND PERSON INSTALLER (REPAIRER) JOURNEY LEVEL TELEPHONE LINEPERSON SPECIAL APPARATUS INSTALLER I SPECIAL APPARATUS INSTALLER II TELEPHONE EQUIPMENT OPERATOR (HEAVY) TELEPHONE EQUIPMENT OPERATOR (LIGHT) TELEVISION GROUND PERSON TELEVISION LINEPERSON /INSTALLER TELEVISION SYSTEM TECHNICIAN TELEVISION TECHNICIAN TREE TRIMMER TERRAZZO WORKERS TILE SETTERS JOURNEY LEVEL TILE, MARBLE TERRAZZO FINISHERS FINISHER TRAFFIC CONTROL STRIPERS JOURNEY LEVEL Page 8 (See Benefit Code Key) Over PREVAILING Time Holiday Note WAGE Code Code Code $51 01 1G 5A $31 02 1E 6L $10 88 1 $19 67 1 $34 53 1R 5A $37 53 1R 5A $48 22 1E 6L $19 29 1 $12.15 1 $33 04 1B 5A $10 31 1B 50 $19 67 1 $13.23 1 $9 35 1 $11 40 1 $13.40 1 $28.24 10 5A $28.92 2B 5A $16.22 2B 5A $27 74 2B 5A $26 90 2B 5A $28 92 2B 5A $28.34 2B 5A $28.92 2B 5A $26 90 2B 5A $15 39 2B 5A $20 45 2B 5A $24 32 2B 5A $21 88 2B 5A $26 90 2B 5A $38.43 1B 5A $32.26 1B 5A $33.40 1K 5A CLALLAM COUNTY Effective 03 -03 -06 Classification TRUCK DRIVERS ASPHALT MIX (TO 16 YARDS) $37 94 1T 5D 8L ASPHALT MIX (OVER 16 YARDS) $38 52 1T 5D 8L DUMP TRUCK $20.23 1 DUMP TRUCK TRAILER $20.23 1 OTHER TRUCKS $38 52 1T 5D 8L TRANSIT MIXER $23 73 1 WELL DRILLERS IRRIGATION PUMP INSTALLERS IRRIGATION PUMP INSTALLER $11 60 1 OILER $9 45 1 WELL DRILLER $11 60 1 Page 9 (See Benefit Code Key) Over PREVAILING Time Holiday Note WAGE Code Code Code